E-PAYMENT Contractor/Vendor agrees to accept all payments in United States currency via the State of Mississippi’s electronic payment and remittance vehicle. The agency agrees to make payment in accordance with Mississippi law on “Timely Payments for Purchases by Public Bodies,” which generally provides for payment of undisputed amounts by the agency within forty-five (45) days of receipt of invoice. Mississippi Code Annotated § 31-7-301 et seq.
Down Payment The Mortgagor has contributed at least 5% of the purchase price for the Mortgaged Property with his/her own funds.
Returned Payment Fee If your account is subject to a Returned Payment Fee, the fee will be charged to your account when a payment is returned for any reason.
PRE-PAYMENT The Tenant shall: (check one) ☐ - Pre-Pay Rent in the amount of $[PRE-PAY RENT AMOUNT] for the term starting on [START DATE] and ending on [END DATE]. The Pre-Payment of Rent shall be due upon the execution of this Agreement. ☐ - Not be required to Pre-Pay Rent.
Upfront Payment Upon the execution of this Agreement, the Lessee shall pay to the Lessor the following: (check one) ☐ - First Month’s Rent of: _ Dollars ($ _) ☐ - Last Month’s Rent of: ___ _ Dollars ($ _) ☐ - Security Deposit of: _ _ Dollars ($ _)
Non-Payment The Borrower or any other Loan Party fails to pay (i) when and as required to be paid herein, any amount of principal of any Loan or any L/C Obligation, or (ii) within three days after the same becomes due, any interest on any Loan or on any L/C Obligation, or any fee due hereunder, or (iii) within five days after the same becomes due, any other amount payable hereunder or under any other Loan Document; or
Payment Amount Payment for the Services shall be as follows: (choose one) ☐ - $______________________ for the Services (“Payment”). ☐ - At an hourly rate of $____ per hour (“Payment”). ☐ - Other. ______________________________________________ (“Payment”) If the Subcontractor asserts a claim which involves, in whole or in part, acts or omissions which are the responsibility of the Client or another person for whom a claim may be submitted, including but not limited to, claims for failure to pay, an extension of time, impacts, delay damages, or extra work, the Contractor shall present the Subcontractor's claim to the Client or other responsible party provided the Subcontractor presents to Contractor competent supporting evidence and in sufficient time for the Contractor to do so. The Subcontractor shall cooperate fully with the Contractor in any and all steps the Contractor takes in connection with prosecuting such a claim and shall hold harmless and reimburse the Contractor for all expenses, including legal expenses, incurred by the Contractor which arise out of the Contractor's submission of the Subcontractor's claims to the Client or other responsible party(ies). The Subcontractor shall be bound by any adjudication or award in any action or proceeding resolving such a claim.
Additional Payment In addition to any Spousal Support, in the event of Divorce: (check one) ☐ - There shall be No Additional Payment made by either Spouse to the other than those listed in this Agreement. ☐ - There shall be an Additional One (1) Time payment in the amount of $ made by the ☐ Husband ☐ Wife to the ☐ Husband ☐ Wife (“Additional Payment”). The Additional Payment shall be made within thirty (30) days after a divorce judgment, decree, or similar document that certifies the Divorce. ☐ - Other. .
Advance Payment The right to indemnification conferred in this Article VII shall include the right to be paid or reimbursed by the Company the reasonable expenses incurred by a Person of the type entitled to be indemnified under Section 7.3 who was, is or is threatened to be made a named defendant or respondent in a Proceeding in advance of the final disposition of the Proceeding and without any determination as to the Person’s ultimate entitlement to indemnification; provided, however, that the payment of such expenses incurred by any such Person in advance of the final disposition of a Proceeding shall be made only upon delivery to the Company of a written affirmation by such Person of his or her good faith belief that he has met the standard of conduct necessary for indemnification under Article VII and a written undertaking, by or on behalf of such Person, to repay all amounts so advanced if it shall ultimately be determined that such indemnified Person is not entitled to be indemnified under this Article VII or otherwise.
Late Payment Fee If your account is subject to a Late Payment Fee, the fee will be charged to your account when you do not make the required minimum payment by or within the number of days of the statement Payment Due Date set forth on the Disclosure accompanying this Agreement.
