Project Documents The words "Project Documents" mean the Plans and Specifications, all studies, data and drawings relating to the Project, whether prepared by or for Borrower, the Construction Contract, the Architect's Contract, and all other contracts and agreements relating to the Project or the construction of the Improvements.
Construction Contract On each Borrowing Date, the Borrower shall have certified that all conditions and requirements under the Construction Contract required to be satisfied on such Borrowing Date, including in connection with the respective payment installments to be made to the Yard on such Borrowing Date, shall have been satisfied (including, but not limited to, the Borrower’s payment to the Yard of the portion of the payment installment on the Vessel that is not being financed with proceeds of the Loans), other than those that are not materially adverse to the Lenders, it being understood that any litigation between the Yard and the Parent and/or Borrower shall be deemed to be materially adverse to the Lenders.
Amendment Documents This Amendment and any other instrument, document or certificate required by the Administrative Agent to be executed or delivered by the Borrower or any other Person in connection with this Amendment, duly executed by such Persons (the “Amendment Documents”);
Amendments to Operative Documents Party B agrees that it will obtain Party A’s written consent (which consent shall not be unreasonably withheld) prior to amending or supplementing the Pooling and Servicing Agreement (or any other transaction document), if such amendment and/or supplement would: (a) materially adversely affect any of Party A’s rights or obligations hereunder; or (b) modify the obligations of, or impact the ability of, Party B to fully perform any of Party B’s obligations hereunder.
Construction Contracts Lessee has entered into contracts with the Contractors or separate contracts with materialmen and laborers providing for the construction of the Improvements. Lessee will cause the Contractors to promptly furnish Lessor with the complete list of all Sub-contractors or entities as and when under contract, which Contractors propose to engage to furnish labor and/or materials in constructing the Improvements (such list containing the names, addresses, and amounts of such sub-contracts as written in excess individually of $5,000, and prior to disbursement of funds to or for the benefit of such Subcontractors, affidavits of authorized signatory and other documents commercially reasonably required by Title to insure that the Leased Premises remain lien free) and will from time to time furnish Lessor or Title with true copies of all Contracts entered into by Lessee and with the terms of all verbal agreements therefor, if any, and as to subcontractors, letters signed by sub-contractors whose contracts are in excess of $5,000 setting forth the present amount of their contract and the amounts remaining to be paid under that contract, if the same information is not stated on a lien waiver reflecting the most currently requested payment to such subcontractor.
Modification Agreements The Servicer or the related Subservicer, as the case may be, shall be entitled to (A) execute assumption agreements, substitution agreements, and instruments of satisfaction or cancellation or of partial or full release or discharge, or any other document contemplated by this Servicing Agreement and other comparable instruments with respect to the Mortgage Loans and with respect to the Mortgaged Properties subject to the Mortgages (and the Company shall promptly execute any such documents on request of the Servicer) and (B) approve the granting of an easement thereon in favor of another Person, any alteration or demolition of the related Mortgaged Property or other similar matters, if it has determined, exercising its good faith business judgment in the same manner as it would if it were the owner of the related Mortgage Loan, that the security for, and the timely and full collectability of, such Mortgage Loan would not be adversely affected thereby. A partial release pursuant to this Section 3.05 shall be permitted only if the Combined Loan-to-Value Ratio for such Mortgage Loan after such partial release does not exceed the Combined Loan-to-Value Ratio for such Mortgage Loan as of the Cut-Off Date. Any fee collected by the Servicer or the related Subservicer for processing such request will be retained by the Servicer or such Subservicer as additional servicing compensation.
Amendment to Material Documents The Borrower will not, and will not permit any Subsidiary to, amend, modify or waive any of its rights in a manner materially adverse to the Lenders under its certificate of incorporation, bylaws or other organizational documents.
Construction Documents Tenant shall cause Tenant’s Architect to prepare a concept plan and program for the entire Premises that is consistent with first class office and laboratory use (the “Concept Plan”), schematic design drawings, design development drawings, and construction documents for the Finish Work in accordance with the provisions of this Exhibit 3.1 and Article 8 of the Lease (such plans, and any interim plans submitted to Landlord in connection therewith, together with the Concept Plan, shall be referred to collectively herein as the “Construction Documents”). All Construction Documents shall comply with Applicable Laws and with the drawing format and specifications provided by Landlord, and shall be subject to Landlord’s review and approval, such approval not to be unreasonably withheld or delayed. Tenant shall be responsible for Landlord’s third party plan review fees. Tenant shall deliver the following to Landlord in accordance with the following schedule (the “Time Deadlines”): Concept Plan Within 30 days of the Effective Date Schematic Design May 15, 2019 Design Development June 15, 2019 Construction documents For pricing/permits and GMP July 15, 2019 The Construction Documents shall be based on the approved Concept Plan and shall not deviate therefrom in any material respect without Landlord’s approval, to be given or withheld in accordance with the terms of this Exhibit 3.1 with respect to approval of plans. Landlord shall review and approve, or disapprove by written notice in sufficient detail for Tenant to be able to reply, within ten (10) business days following the proper submission of any Construction Documents. In the event that Landlord does not approve or disapprove Tenant’s proposed Construction Documents within ten (10) business days after receipt thereof, then Tenant may send a second notice to Landlord with a legend in bold and prominent print stating that “FAILURE TO REPLY TO THIS REQUEST FOR APPROVAL OF THE TENANT PLANS WITHIN FIVE (5) BUSINESS DAYS MAY BE DEEMED TO BE LANDLORD’S APPROVAL” and, if Landlord fails to approve or disapprove of such Tenant plans within five (5) business days following delivery of such second notice, then Landlord shall be deemed to have approved the Construction Documents in question. All approvals, inspections, and requirements of Landlord with respect to any Construction Documents and Finish Work shall be for Landlord’s benefit only, may not be relied on by Tenant (other than for purposes of evidencing Landlord’s consent), and shall not affect Tenant’s responsibility for the same. The Finish Work shall mean the work shown on the final, approved Construction Documents, as affected by any approved Finish Work Change Orders (as defined below), and shall include all work in the “Tenant” column on the allocation of responsibility attached as Attachment 1. Where more than one type of material or structure is indicated on the approved Construction Documents as permitted substitutions, the decisions regarding the selection of which type of material or structure among those shown will be within Tenant’s reasonable discretion if the matter concerns the Finish Work, and within Landlord’s reasonable discretion if the matter affects the structural components of the Building or any Building systems.
Amendment to Loan Documents The Borrower shall not amend any of the Loan Documents except pursuant to the applicable terms thereof and Section 12.5 of this Agreement.
Material Project Documents (a) The Borrower shall at all times (i) perform and observe all of the covenants under the Material Project Documents to which it is a party, (ii) take reasonable actions to enforce all of its rights thereunder, and (iii) maintain the Leases to which it or any of its Subsidiaries is a party in full force and effect, except to the extent the same could not reasonably be expected to have a Material Adverse Effect.
