Additional Terms for Defect Liability Sample Clauses

Additional Terms for Defect Liability i) In addition to Clause 12 it is hereby agreed between the parties hereto that the Promoter shall not be liable to compensate if the defect is attributable to any acts or omissions or commissions of the Allottee (or any person appointed by him or acting under him or under his instructions) or arising due to any normal wear and tear or due to reasons not solely attributable to the Promoter. ii) Notwithstanding anything contained in Clause 12 it is hereby expressly agreed and understood that in case the Allottee, without first notifying the Promoter and without giving the Promoter the reasonable opportunity to inspect, assess and determine the nature of purported defect in the Apartment, alters the state and condition of the area of the purported defect, then the Promoter shall be relieved of its obligations contained hereinabove in this clause.
View SourceView Similar (8)
Additional Terms for Defect Liability i) In addition to Clause 12 it is hereby agreed between the parties hereto that the Developer shall not be liable to compensate if the defect is attributable to any acts or omissions or commissions of the Allottee (or any person appointed by him or acting under him or under his instructions) or arising due to any normal wear and tear or due to reasons not solely attributable to the Developer. ii) Notwithstanding anything contained in Clause 12 it is hereby expressly agreed and understood that in case the Allottee, without first notifying the Developer and without giving the Developer the reasonable opportunity to inspect, assess and determine the nature of purported defect in the Apartment, alters the state and condition of the area of the purported defect, then the Developer shall be relieved of its obligations contained hereinabove in this clause.
View Source

Related to Additional Terms for Defect Liability

  • CLAIMS FOR ADDITIONAL COST 12.3.1 If the Contractor wishes to make a claim for an increase in the Contract Sum, he shall give the Architect written notice thereof within twenty days after the occurrence of the event giving rise to such claim. This notice shall be given by the Contractor before proceeding to execute the Work, except in an emergency endangering life or property in which case the Contractor shall proceed in accordance with Paragraph 10.3 of these General Conditions. No such claim shall be valid unless so made. If the State and the Contractor cannot agree on the amount of the adjustment in the Contract Sum, it shall be determined by the Architect. Any change in the Contract Sum resulting from such claim shall be authorized by Change Order. 12.3.2 If the Contractor claims that additional cost is involved because of, but not limited to, (1) any order by the State to stop the Work pursuant to Paragraph 3.3 of these General Conditions where the Contractor was not at fault, or (2) failure of payment by the State pursuant to Paragraph 9.7(of these General Conditions), the Contractor shall make such claim as provided in Subparagraph 12.3.1 of this agreement. 12.3.3 The Architect will have authority to order minor changes in the Work not involving an adjustment in the Contract Sum or an extension of the Contract Time and not inconsistent with the intent of the Contract Documents. Such changes shall be effected by written order and shall be binding on the State and Contractor within 10 days unless the Contractor or the State objects to the change in writing.

  • CLAIMS FOR DAMAGES 7.4.1 Should either party to the Contract suffer injury or damage to person or property because of any act or omission of the other party or of any of his / her employees, agents or others for whose acts he / she is legally liable, claim shall be made in writing to such other party within a reasonable time after the first observance of such injury or damage.

  • Indemnification Procedures for Third Party Claims If a claim by a third party (including claims for breaches of fiduciary duties) is made against an Indemnified Party and such Indemnified Party intends to seek indemnity with respect thereto from the Company (in the case of a Purchaser Indemnified Party seeking such indemnity) or the Purchaser (in the case of a Company Indemnified Party seeking indemnity) (each of the Company or the Purchaser, as the case may be, in such capacity, an “Indemnifying Party”), such Indemnified Party shall give notice in writing as promptly as reasonably practicable to such Indemnifying Party of any Proceeding commenced against or by it in respect of which indemnity may be sought hereunder, but failure to so notify such Indemnifying Party shall not relieve such Indemnifying Party from any liability that it may have on account of this Article VI, so long as such failure shall not have materially prejudiced the position of such Indemnifying Party. Upon such notification, the Indemnifying Party shall assume the defense of such Proceeding brought by a third party, and, after such assumption, the Indemnified Party shall not be entitled to reimbursement of any expenses thereafter incurred by it in connection with such Proceeding, except as described below. In any such Proceeding, any Indemnified Party shall have the right to retain its own counsel (including local counsel), but the fees and expenses of such counsel shall be at the expense of such Indemnified Party unless (i) the Indemnifying Party shall have failed to promptly assume and thereafter conduct such defense, (ii) the Indemnifying Party and the Indemnified Party shall have mutually agreed to the contrary, (iii) in the reasonable determination of counsel for the Indemnified Party, representation of such Indemnified Party by counsel obtained by the Indemnifying Party would be inappropriate due to actual or potential conflicting interests between such Indemnified Party and any other party represented by such counsel in such proceeding. No Indemnifying Party, in the defense of a third-party claim, shall, except with the consent of the Indemnified Party, consent to entry of any judgment or enter into any settlement that does not include as an unconditional term thereof the giving by the claimant or plaintiff to such Indemnified Party of a release from all liability in respect of such claim. The Indemnifying Party shall not be liable for any settlement of any Proceeding effected without its written consent (which shall not be unreasonably withheld, delayed or conditioned by such Indemnifying Party), but if settled with such consent or if there be final judgment for the plaintiff, the Indemnifying Party shall indemnify the Indemnified Party from and against any Loss by reason of such settlement or judgment. The Indemnifying Party will advance expenses to an Indemnified Party as reasonably incurred so long as such indemnified party shall have provided the indemnifying party with a written undertaking to reimburse the indemnifying party for all amounts so advanced if it is ultimately determined that the indemnified party is not entitled to indemnification hereunder (which shall include breaches of fiduciary duty if permitted above).

  • Claims for Additional Time § 14.1.6.1 If the Design-Builder intends to make a Claim for an increase in the Contract Time, written notice as provided herein shall be given. The Design-Builder’s Claim shall include an estimate of cost and of probable effect of delay on progress of the Work. In the case of a continuing delay, only one Claim is necessary. § 14.1.6.2 If adverse weather conditions are the basis for a Claim for additional time, such Claim shall be documented by data substantiating that weather conditions were abnormal for the period of time, could not have been reasonably anticipated, and had an adverse effect on the scheduled construction.

  • ADDITIONAL TERMS OF SETTLEMENT 24. This settlement is agreed upon in accordance with section 24.4 of MFDA By-law No. 1 and Rules 14 and 15 of the MFDA Rules of Procedure. 25. The Settlement Agreement is subject to acceptance by the Hearing Panel which shall be sought at a hearing (the “Settlement Hearing”). At, or following the conclusion of, the Settlement Hearing, the Hearing Panel may either accept or reject the Settlement Agreement. MFDA Settlement Hearings are typically held in the absence of the public pursuant to section 20.5 of MFDA By-law No. 1 and Rule 15.2(2) of the MFDA Rules of Procedure. If the Hearing Panel accepts the Settlement Agreement, then the proceeding will become open to the public and a copy of the decision of the Hearing Panel and the Settlement Agreement will be made available at ▇▇▇.▇▇▇▇.▇▇. 26. The Settlement Agreement shall become effective and binding upon the Respondent and Staff as of the date of its acceptance by the Hearing Panel. Unless otherwise stated, any monetary penalties and costs imposed upon the Respondent are payable immediately, and any suspensions, revocations, prohibitions, conditions or other terms of the Settlement Agreement shall commence, upon the effective date of the Settlement Agreement. 27. Staff and the Respondent agree that if this Settlement Agreement is accepted by the Hearing Panel: a) the Settlement Agreement will constitute the entirety of the evidence to be submitted respecting the Respondent in this matter; b) the Respondent waives any rights to a full hearing, a review hearing before the Board of Directors of the MFDA or any securities commission with jurisdiction in the matter under its enabling legislation, or a judicial review or appeal of the matter before any court of competent jurisdiction; c) Staff will not initiate any proceeding under the By-laws of the MFDA against the Respondent in respect of the contraventions described in this Settlement Agreement. Nothing in this Settlement Agreement precludes Staff from investigating or initiating proceedings in respect of any contraventions that are not set out in this Settlement Agreement. Furthermore, nothing in this Settlement Agreement shall relieve the Respondent from fulfilling any continuing regulatory obligations; d) the Respondent shall be deemed to have been penalized by the Hearing Panel pursuant to