SUBCONTRACTOR’S RESPONSIBILITIES. The Subcontractor shall furnish all of the materials and perform all the Work described in the specifications and shown on the drawings for the project entitled: title of project shown on documents prepared by Architect - Engineer firm name, for the specification sections here described: list all sections- for this subcontract only- by number and name. Not used. The Subcontractor shall comply with all laws, codes and regulations applicable to the Work. Not used. The Subcontractor shall remain an independent agent for the duration of this subcontract, shall not become an employee of the State of Maine, and shall assure that no State employee will be compensated by, or otherwise benefit from, this subcontract.
SUBCONTRACTOR’S RESPONSIBILITIES. 3.1 OBLIGATIONS The Contractor and Subcontractor are hereby mutually bound by the terms of this Subcontract. To the extent the terms of the prime contract between the Owner and Contractor apply to the work of the Subcontractor, then the Contractor hereby assumes toward the Subcontractor all the obligations, rights, duties, and redress that the Owner under the prime contract assumes toward the Contractor. In an identical way, the Subcontractor hereby assumes toward the Contractor all the same obligations, rights, duties, and redress that the Contractor assumes toward the Owner and Architect under the prime contract. In the event of an inconsistency among the documents, the specific terms of this Agreement shall govern.
SUBCONTRACTOR’S RESPONSIBILITIES. 4.1 Responsibilities The Subcontractor shall furnish its best skill and judgment in the performance of the Subcontract Work and shall perform its work to the satisfaction of the Contractor, the Owner and the Architect/Engineer, so the Contractor may fulfill its obligations to the Owner. The Subcontractor shall furnish all of the labour, materials, equipment, and services, including but not limited to, competent supervision, shop drawings, samples, tools, and scaffolding as are necessary for the proper performance of the Subcontract Work. The Subcontractor shall be responsible for taking field dimensions, providing tests, obtaining required permits, ordering of materials and all other actions as required to meet the Schedule of Work.
SUBCONTRACTOR’S RESPONSIBILITIES. A. Subcontractor shall be responsible for reviewing the site and being familiar with all existing site conditions affecting the services required under the specifications contained herein.
SUBCONTRACTOR’S RESPONSIBILITIES. You shall ensure that all Subcontracts impose obligations on the Subcontractors equivalent to the obligations under this clause.
SUBCONTRACTOR’S RESPONSIBILITIES. 4.1 Subcontractor acknowledges that it will be performing the Work as an independent contractor and is responsible for including any required sales taxes in the Subcontract Sum and remitting same to the collecting authority. Subcontractor is solely responsible for the acts and omissions of its employees and sub-subcontractors, for directing their work, and for the payment of all their wages, taxes, and sub-subcontract amounts.
SUBCONTRACTOR’S RESPONSIBILITIES. 3.1 OBLIGATIONS The Constructor and the Subcontractor are hereby mutually bound by the terms of this Agreement. To the extent the terms of the prime agreement apply to the Subcontract Work, then the Constructor hereby assumes toward the Subcontractor all the obligations, rights, duties, and redress that the Owner under the prime agreement assumes toward the Constructor. In an identical way, the Subcontractor hereby assumes toward the Constructor all the same obligations, rights, duties, and redress that the Constructor assumes toward the Owner and Design Professional under the prime contract.
SUBCONTRACTOR’S RESPONSIBILITIES. 2.1 The Subcontract Work includes, but is not limited to, such of the following as may be necessary to perform and complete the Subcontract Work: all plant, materials, tools, equipment (whether for temporary or permanent use), scaffolding, supplies, transportation cartage, loading, hoisting, forms, patterns, models, shop drawings, measurements and other facilities; all labor, work, supervision, cutting; patching, cleaning, temporary construction, protection and other services; and all insurance, warranties, taxes, benefits, royalties, temporary utilities and other related costs except as otherwise provided in this Agreement. It is intended that the Subcontract Work include all work and things necessary to produce a completed job in all respects, and including all warranties required by the Prime Contract; no Claim shall be made by Subcontractor based upon a change in the scope of the Subcontract Work if such work was set forth in or reasonably implied by this Agreement or the Subcontract Documents.
SUBCONTRACTOR’S RESPONSIBILITIES. Subcontractor shall give all notices related to the Services to applicable Governmental Bodies and obtain and pay for all licenses, permits and inspections that Subcontractor is legally required to obtain for the performance of the Services. Xcel and XXX shall have the right to inspect and obtain copies of all written licenses, permits or approvals, issued by any Governmental Body to Subcontractor or its subcontractors that are applicable to the performance of the Agreement. In the event that Subcontractor performs services on or at the Site, Subcontractor shall comply with all applicable provisions of Xcel's plant, Project, facility or Site policies and procedures, including but not limited to any instructions and procedures pertaining to plant or facility Site security, industrial safety, environmental directives, work authorization, equipment control and hazardous materials. In addition, Subcontractor, its employees and subcontractors shall comply with and enforce, among Subcontractor’s employees and subcontractors, plant or facility Site conditions and job Services rules which affect the performance of the Services, including but not limited to Services hours, smoking regulations, check-in and check-out procedures, job Site safety and security regulations, and emergency plans and procedures. Completion of Contractor Safety Program documentation is at Subcontractor’s cost. In addition to these obligations, any special conditions or restrictions, required by Xcel under its Contractor Safety Program as part of Xcel's supplier qualification process or to qualify Subcontractor to do the Services, shall be given in writing to Subcontractor and are hereby expressly incorporated into the Agreement and made a part hereof. If Subcontractor performs services on or at the Site, Subcontractor shall be deemed the “controlling employer” for its Personnel and for its Subcontractors, for the purposes of the Federal Occupational Safety and Health Act (OSHA) and its implementing regulations. Subcontractor shall comply with the quality management requirements contained in the Quality Management Special Conditions, if such Special Conditions are included. Delivery of Goods shall be completed by Subcontractor in compliance with the terms of the Agreement, or, if unspecified, Subcontractor shall deliver Goods to the Site. Subcontractor shall be responsible for and shall bear any and all risk of loss or damage to the Services in progress and to all Goods delivered to the Site...
SUBCONTRACTOR’S RESPONSIBILITIES. Subcontractor shall adequately furnish and secure all labor, material, taxes, services, equipment, tools, materials, storage, permits, licenses and inspections, shop drawings/submittals as required by the Contractor, and safety equipment in order to provide and perform complete, fully functional Work. Subcontractor shall comply with all applicable laws, statutes, ordinances, rules and regulations relating to the performance of Subcontractor’s Work, including but not limited to immigration, environmental, tax, social security, unemployment, insurance, safety and workers’ compensation requirements. Subcontractor shall perform all Work in a timely manner so as not to delay Contractor, the Project, or the work of others at the Project site. Subcontractor shall protect the work of others and property at the Project site from damage caused by Subcontractor’s operation and shall be responsible to immediately correct and repair any damage, at its cost, should any occur. Subcontractor is fully responsible for, and shall ensure, the safety of persons and property in connection with its COLONIALWEBB CONTRACTORS CO 0000 XXXXXX XXX RICHMOND, VA 23228 Purchase Order Number: 907647 Issue Date: 01/14/2019 Page: 4 of 8 Phone: (000) 000-0000 Work. Subcontractor shall not create or allow, and shall promptly report to Contractor and be fully responsible for, any unsafe conditions relating to its Work and shall comply with all applicable safety laws, regulations, and ordinances. Subcontractor agrees to comply with the safety requirements and protocols stated in Contractor’s companywide safety programs, including without limitation, Contractor's Safety Manual. Subcontractor further agrees to comply with the Project’s site specific safety program. Subcontractor agrees to comply with all safety requirements and protocols established by the Owner or General Contractor for the Project. Subcontractor also agrees to prepare for, attend and participate in all Project programs and meetings addressing safety issues, including orientations sessions, tool box safety training meetings, compliance reviews and jobsite inspections by Contractor’s Safety Inspector. Unsafe performance and/or lack of adherence to the safety program can result in immediate action by Contractor, Prime Contractor or Owner which may include but is not limited to removal of Subcontractor’s personnel, cessation of Subcontractor’s work, suspension of payment, and termination of Subcontractor. Equipment furnished by the...
