Sanctions for non compliance with records and worker access requirements. If the contractor or subcontractor fails to submit the required records or to make them available, or refuses to permit worker interviews during working hours on the job, the Federal agency may, after written notice to the contractor, sponsor, applicant, owner, or other entity, as the case may be, that maintains such records or that employs such workers, take such action as may be necessary to cause the suspension of any further payment, advance, or guarantee of funds. Furthermore, failure to submit the required records upon request or to make such records available, or to permit worker interviews during working hours on the job, may be grounds for debarment action pursuant to § 5.12. In addition, any contractor or other person that fails to submit the required records or make those records available to WHD within the time WHD requests that the records be produced will be precluded from introducing as evidence in an administrative proceeding under 29 CFR part 6 any of the required records that were not provided or made available to WHD. WHD will take into consideration a reasonable request from the contractor or person for an extension of the time for submission of records. WHD will determine the reasonableness of the request and may consider, among other things, the location of the records and the volume of production.
Sanctions for non. COMPLIANCE Should sub‐grantee fail to fulfill any of its contractual duties in a timely manner, the Lead Agency shall notify sub‐grantee in writing as to such deficiencies. Such notification shall be sent by certified mail, return receipt requested. Sub‐grantee shall have 30 days to resolve such deficiencies, unless otherwise stated by the Lead Agency. “The opinion, findings, and conclusions expressed in this publication are those of the author and not necessarily those of the State of Ohio, the National Highway Traffic Safety Administration, the Federal Highway Administration, or the Lead Agency.” IX. SIGNATURES Approved as to form: Xxx X’Xxxxx, Xxxxxxxx County Prosecutor Assistant Prosecuting Attorney Franklin County Sheriff: Xxxx Xxxxx, Sheriff For the BOARD OF COUNTY COMMISSIONERS: Xxx X. Xxxxx, County Administrator CITY / TOWNSHIP / VILLAGE, COUNCIL / BOARD, OR DESIGNATED CONTRACT SIGNATURE AUTHORITY: Printed Name, Title Signature Printed Name, Title Signature Printed Name, Title Signature Printed Name, Title Signature Printed Name, Title Signature Printed Name, Title Signature The following are Provisions that shall be used by the sub‐grantee (lead agency) when entering into an agreement contract when funds administered by the Ohio Traffic Safety Office (OTSO) that total $5,000 or more are used. This provision includes requirements of both the federal or state government. Note: for clarification purposes the work contactor is the agency, vendor, individual, etc., that the sub‐grantee is contracting with for the desired scope of service.
Sanctions for non. Compliance with the Set Conditions Should the Contractor fail to comply with the delivery time of Goods under this Agreement, the Contractor shall pay to the Client a contractual penalty in the amount of 0.5% of the price of undelivered quantity of Goods excluding VAT for each commenced day of delay, however at least CZK 500 per day, until the full fulfilment of the obligation. Should the Contractor fail to comply with the time limit for removing a defect of Goods, the Contractor shall pay to the Client a contractual penalty in the amount of 0.5% of the price of claimed Goods excluding VAT for each day of delay, however at least CZK 500 per day, until the full fulfilment of the obligation. Should the Client be in delay with the payment of invoices to pay the purchase price duly issued by the Contractor, the Contractor may charge the Client a late interest in the amount determined by generally binding legal regulation. The obliged Party shall pay the contractual penalty regardless of whether or to what extent any demonstrable damages were incurred by the second Party. Such damages shall be recoverable separately, in addition to the contractual penalty. No compensation for damages shall be paid if the obliged Party can prove that the breach in its obligations has been caused by any circumstances which exclude liability of such Party. The contractual penalty or late interest shall be paid within 30 days following the receipt of the respective tax document. No Party shall be responsible for damages caused by circumstances excluding liability within the meaning of the CC. Each Party undertakes to notify the other Party without undue delay of the occurrence of circumstances excluding liability which prevent proper implementation of this Agreement and undertakes to make every effort to avert and overcome such circumstances.
Sanctions for non. Consensual Intercourse That Involves the Use of Physical Force, Threat o Force, or Purposeful Incapacitation will result in Dismissal from Brandeis University. In addition to the nature or severity of behaviors for which a respondent is found responsible, sanctions will also be affected by the frequency of these behaviors and the previous conduct history of the responsible student. (section 22, Sanctions, pages 61) (Rationale: clarifying language) Does not exist in 2015-‐2016 edition.
Sanctions for non payment Tuition fees
Sanctions for non compliance. In the event of Special Counsel’s noncompliance with the Non‐discrimination provisions of this Contract, the Authority will impose such contract sanctions as it or the FAA may determine to be appropriate, including, but not limited to:
Sanctions for non. Consensual Intercourse That Does Not Include the Use of Force will usually be Suspension or Dismissal. See section 20 for definitions of specific sanctions.
Sanctions for non. Compliance with the Set Conditions Should the Contractor fail to comply with the delivery time of Goods under this Agreement, the Contractor shall pay to the Client a contractual penalty in the amount of 0.5% of the price of undelivered quantity of Goods excluding VAT or the amount of 500,- CZK depending on which amount is higher for each commenced day of delay until the full fulfilment of the obligation. Should the Contractor fail to comply with the time limit for removing a defect of Goods, the Contractor shall pay to the Client a contractual penalty in the amount of 0.5% of the price of claimed Goods excluding VAT or the amount of 500,- CZK depending on which amount is higher for each day of delay until the full fulfilment of the obligation. Should the Client be in delay with the payment of invoices to pay the purchase price duly issued by the Contractor, the Contractor may charge the Client a late interest in the amount determined by generally binding legal regulation. The obliged Party shall pay the contractual penalty regardless of whether or to what extent any demonstrable damages were incurred by the second Party. Such damages shall be recoverable separately, in addition to the contractual penalty. No compensation for damages shall be paid if the obliged Party can prove that the breach in its obligations has been caused by any circumstances which exclude liability of such Party. The contractual penalty or late interest shall be paid within 30 days following the receipt of the respective tax document. No Party shall be responsible for damages caused by circumstances excluding liability within the meaning of the CC. Each Party undertakes to notify the other Party without undue delay of the occurrence of circumstances excluding liability which prevent proper implementation of this Agreement and undertakes to make every effort to avert and overcome such circumstances.
