Expansion Effective Date Sample Clauses

Expansion Effective Date. As used herein, “Expansion Effective Date” means the earlier of (i) the first date on which Tenant conducts business in the Expansion Space, or (ii) the date on which the Tenant Improvement Work (defined in Exhibit B attached hereto) is Substantially Complete (defined in Exhibit B attached hereto), which is anticipated to be April 1, 2020 (the “Target Expansion Effective Date”). The adjustment of the Expansion Effective Date and, accordingly, the postponement of Tenant’s obligation to pay rent for the Expansion Space shall be Tenant’s sole remedy if the Tenant Improvement Work is not Substantially Complete on the Target Expansion Effective Date. If the Expansion Effective Date is delayed, the Extended Expiration Date shall not be similarly extended.
AutoNDA by SimpleDocs
Expansion Effective Date. As used herein, “Expansion Effective Date” means the later of (a) the Expansion Delivery Date, or (b) the earlier of (i) the date on which Tenant first conducts business in the Expansion Space, or (ii) April 1, 2016. As used herein, “Expansion Delivery Date” means the date on which Landlord tenders possession of the Expansion Space to Tenant free from any possessory interest of or occupancy by any other party. Landlord shall cause the Expansion Delivery Date to occur promptly after (i) Landlord’s recovery of possession of the Expansion Space from the current tenant thereof (the “Current Suite 300 Tenant”) or its successor in interest (it being acknowledged that the Current Suite 300 Tenant’s lease of the Expansion Space (the “Current Suite 300 Lease”) is scheduled to expire on March 31, 2016, subject to an existing extension option), and (ii) the passage of such time as may be reasonably required for Landlord to put the Expansion Space into the condition required hereunder. If the Current Suite 300 Tenant does not surrender possession of the Expansion Space on or before March 31, 2016, Landlord shall use commercially reasonable efforts to recover such possession as soon thereafter as reasonably possible (including, if necessary in Landlord’s reasonable judgment, by commencing and pursuing an unlawful detainer action). During the period, if any, beginning on the Expansion Delivery Date and ending on the date immediately preceding the Expansion Effective Date, all provisions of this Amendment relating to the Expansion Space (including the provisions hereof giving Tenant the right to possess the Expansion Space) shall apply to the Expansion Space as if the Expansion Effective Date had occurred; provided, however, that during such period Tenant shall not conduct business in, or be required to pay Monthly Rent for, the Expansion Space. If the Expansion Effective Date is delayed, no expiration date under the Lease, whether for the Existing Premises or the Expansion Space, shall be similarly extended.
Expansion Effective Date. As used herein, “Expansion Effective Date” means the third (3rd) business day following the date of mutual execution and delivery of this Amendment. Landlord shall tender possession of the Expansion Space to Tenant in vacant, broom-clean condition on the Expansion Effective Date.
Expansion Effective Date. As used herein, “Expansion Effective Date” means:
Expansion Effective Date. As used herein, “Expansion Effective Date” means the earlier to occur of (i) the date on which Tenant first commences to conduct business in the Expansion Space pursuant to this Amendment, or (ii) the date on which the Expansion Space becomes Ready for Occupancy (defined in the Expansion Work Letter attached hereto as Exhibit B), which is anticipated to be July 15, 2010 (the “Target Expansion Effective Date”). The adjustment of the Expansion Effective Date and, accordingly, the postponement of Tenant’s obligation to pay rent for the Expansion Space shall be Tenant’s sole remedy if the Expansion Space is not Ready for Occupancy on the Target Expansion Effective Date. If the Expansion Effective Date is delayed, the expiration date under the Lease shall not be similarly extended.
Expansion Effective Date. As used herein, “Expansion Effective Date” means the date on which Landlord delivers to Tenant the Expansion Space in broom clean condition (which date is anticipated to be June 1, 2019). Any delay in the Expansion Effective Date shall not subject Landlord to any liability for any loss or damage resulting therefrom. If the Expansion Effective Date is delayed, the Expiration shall not be similarly extended.
Expansion Effective Date. The Expansion Effective Date is ___________, 2019.
AutoNDA by SimpleDocs
Expansion Effective Date. As used herein, “Expansion Effective Date” means the earlier of (i) the date on which Tenant first occupies the Expansion Space for the purpose of conducting its business operations therein, or (ii) April 1, 2016.
Expansion Effective Date. The Premises shall be expanded to include a space consisting of 3,076 rentable square feet adjacent to the Premises on the sixth (6th) floor of the Building,
Expansion Effective Date. As used herein, “Expansion Effective Date” means the earlier to occur of (i) the date on which Tenant first conducts business in the Expansion Space, or (ii) June 1, 2013 Landlord shall tender possesion of the the Expansion Space to Tenant free from occupancy by any party (the date of such tender shall be referred to hereinafter as the “Delivery Date”) on the first business day following mutual execution and delivery hereof. During the period beginning on the Delivery Date and ending on the date immediately preceding the Expansion Effective Date, the provisions of this Amendment shall apply to the Expansion Space as if the Expansion Effective Date had occurred; provided, however, that during such period Tenant shall not be required to pay Monthly Rent for the Expansion Space.
Time is Money Join Law Insider Premium to draft better contracts faster.