Completion Period. 5.1 The Contractor shall mobilize all necessary and appropriate resources and coordinate all work activities with IOM to ensure commencement of the Works on [insert date] and completion and turn-over of the Works to IOM by [insert date] (“Completion Date”).
Completion Period. Time is essence of the contract. The work should be completed in all respect accordance with the terms of contract within a period of 60 days from the date of award of work.
Completion Period. The completion period of the project shall be from receipt of sanction letter from <IMPLEMENTING AGENCY/EXPERT PSU>
Completion Period. 3.1 The contract work shall be duly completed in all respect and handed over to N.F.L. within stipulated time schedule from the date of issue of Letter of Intent. The time mentioned herein shall be the essence of the contract.
Completion Period. 13.1. A completion period is only binding when accepted in a written agreement that also covers, in particular, the scope of the Services to be provided. The completion period begins as soon as, in ABB’s opinion, all preliminary requirements for the commencement of the provision of the Services have been fulfilled.
Completion Period. Work will be manned with sufficient competent trade force in order to complete the project in a continuous and timely fashion as related to the Contractor's overall schedule. Failure to staff the job with adequate resources to achieve schedule requirements will result in termination without reimbursement. In the event Subcontractor fails to maintain the schedule, Subcontractor shall, without additional compensation, work such overtime as Contractor may direct until Subcontractor is in compliance with such schedule. Any disputes arising from changes in the work, scope of work, specifications, financial matters, change orders, etc. shall be resolved through negotiations with Contractor without delay to the project schedule. Any delays in the project schedule shall result in backcharges to the responsible party(ies). Failure to continue work until completion shall subject Subcontractor to penalty. Subcontractor understands there may be both union and open shop labor utilized on the project and is responsible for maintaining the schedule. Subcontractor and it's workforce shall not participate in work stoppages, slowdowns or protests on this site.
Completion Period. Section 1. The CONTRACTOR shall perform and complete the PROJECT to the satisfaction of the PROCURING ENTITY within sixty (60) calendar days reckoned from the date of issuance of, or the date stated in, the Notice to Proceed, whichever is earlier.
Completion Period. In the event the Transferring Shareholder and the Non-Transferring Shareholder reach an agreement with respect to all of the Subject Shares within the ROFO Negotiation Period, (i) within twenty-one (21) days after the date of the foregoing agreement, the foregoing Non-Transferring Shareholder shall pay to the Transferring Shareholder a non-refundable deposit in an amount of 10% of the transfer price set forth in the Sale Notice; and (ii) the relevant Shareholders shall enter into a share transfer agreement and an instrument of transfer and complete the Transfer of all of the Subject Shares within Forty-five (45) days of entry into such agreement (subject to extensions of up to 120 days as required to obtain requisite regulatory approvals) (the “ROFO Completion Period”).
Completion Period a. The “Completion Period” shall be a period of 24 (twenty-four) months commencing from the Effective Date for the Project. However, it is being clarified here that the Concessionaire shall, within the Completion Period:
Completion Period. 10.6 Notwithstanding paragraph 10.5, CETI may, during the nine month period immediately following termination of this Agreement, complete uses or operations in progress, finish items of Licensed Applications then in the process of being manufactured and liquidate its inventory, all in accordance with the terms and conditions of this Agreement. Adverse Judgment not Default
