Anticipated Project Schedule. The schedule will be verified upon approval of the Schematic Design and phasing plans. The following project milestones as referenced in Section 1.1.1 and Section 1.1.2 are as follows:
Anticipated Project Schedule. 1. PEC shall commence its services on the Project within 7 days after receiving CLIENT’s notice to proceed.
Anticipated Project Schedule. A. Site Visit – Early April 2021.
Anticipated Project Schedule. 1. Wood shall commence its services on the supplemental scope within 7 days after receiving CLIENT’s notice to proceed.
Anticipated Project Schedule. The following schedule is proposed for the Scope of Services described above, with the assumption of an Authorization to Proceed date of July 18, 2023 and provides for a 27-month construction schedule and additional 3-months to achieve final completion for a total of 30 months: Task Anticipated Start Date Anticipated Completion Date Approximate Duration Remarks Notice to Proceed July 2023 N/A N/A Dilution Modeling July 2023 July 2024 12 Months SEPA/EA Preparation for Clearinghouse Review July 2023 October 2024 3 Months Concurrent with Dilution Modeling Engineering Alternatives Analysis July 2023 October 2024 3 Months Submit EA Review & Obtain FONSI October 2023 April 2024 6 Months FONSI Approval 5-9 Months per NCDEQ Guidelines 30% Design July 2023 October 2023 3 Months Concurrent with Dilution Modeling, SEPA EA and EAA Preparation 60% Design October 2023 January 2024 3 Months 90% Design January 2024 April 2024 3 Months Submit All Non-ATC Permits April 2024 October 2024 6 Months Erosion Control, Stormwater, NCDOT, CAMA, Corps of Engineers, etc. Submit NPDES Permit (after FONSI is approved) May 2024 October 2024 6 Months NPDES Permit Approval - 6 Months per NCDEQ Guidelines Submit Plans for ATC Permit December 2024 March 2025 3 Months ATC Approval 3 Months per NCDEQ Guidelines Bid Phase April 2025 July 2025 3 Months Advertise, Open Bids, Notice of Award Construction Phase August 2025 January 2028 30 Months 27 Months Substantial/3 Months Final
Anticipated Project Schedule. The schedule will be verified upon approval of the Schematic Design and phasing plans. The following project milestones as referenced in Section 1.1.1 and Section 1.1.2 are as follows: Task Completed On Or Before Begin design Scope-to-Budget/Program Verification 100% Schematic Design 100% Design Development 60% Construction Documents 60% Cost review 100% Construction Documents 100% Cost review Obtain permit; revise documents after permitting and HISD review; issue Bid Documents Obtain pricing; negotiate and execute contract; issue Notice to Proceed Substantial Completion / Obtain C-of-O Complete punch list Texas Department of Licensing and Regulations (TDLR) inspection, resolution of issues, and approval
Anticipated Project Schedule. The anticipated time line is as follows: July 5, 2018 Issuance of RFQ/SOI July 31, 2018 Last date for respondents to request a meeting with the Borough agent(s)-such a meeting is not required. August 10, 2018 Responses are due. September 10, 2018 (week of) Response conference(s) and review by the Borough. September 17, 2018 Notification of Potential Qualified Respondents October, 2018 Borough Council Review and Due Diligence The project timetable relating to authorization and/or implementation will be established at the conclusion of this step.
Anticipated Project Schedule. The Anticipated Project Schedule includes HISD’s project milestone dates. The Project Milestones as referenced in Article 1, Section 1, Paragraph 2 are as follows:
Anticipated Project Schedule. The anticipated project schedule, included as Attachment 2, assumes approval of an Interlocal Agreement between the City and TCRPC in October, with project initiation in October 2020 and completion in May 2021. The schedule identifies tasks, lead entity (e.g., TCRPC, City staff), and anticipated timeframe for completion of work.
Anticipated Project Schedule. Anticipated timeline for completing the Project in accordance with the estimated project budget.
