Project Superintendent definition

Project Superintendent means the Design-Builder’s on-site designated representative who oversees the construction of the Design-Build Contract, including directing and coordinating the activities of the Design-Builder’s workforce and all subcontractors, ensuring that the work progresses according to schedule, and ensuring that material and equipment are delivered to the site on time, etc.

Split View

AI-Powered Contracts

Draft, Review & Redline at the Speed of AI

Get StartedBook a Demo

Project Superintendent. A minimum of three (3) years' experience with the Manager.

Project Superintendent means the Design-Builder’s on-site designated representative who oversees the construction of the Design-Build Contract, including directing and coordinating the

Examples of Project Superintendent in a sentence

• The Project Superintendent shall not be changed except with the consent of the Owner and the Design Professional unless the superintendent proves to be unsatisfactory to the Contractor and ceases to be in his employ.

• The Contractor shall keep on this work during its progress and until the Final Certificate has been executed by the Design Professional a competent Project Superintendent and any necessary assistants, all satisfactory to the Design Professional and Owner.

• If the Contractor terminates the Project Superintendent or, if the Contractor, for any reason, engages a Project Superintendent different from the one originally assigned to the Project, Contractor must ensure that the replacement Project Superintendent has similar qualifications and experience as the originally identified Project Superintendent.

• Furthermore, the Contractor must obtain the Owner's prior written approval before engaging a permanent replacement Project Superintendent.

• Such plan shall include, without limitation, an estimate of the manpower requirements for each trade and the anticipated availability of such manpower, a schedule prepared using the critical path method that will amplify and support the schedule required in Article 2.1.5 below, and the Submittal Schedule as required in Article 2.2.3. The Contractor shall include in his plan the names and resumés of the Project Superintendent, Project Manager and the person in charge of Safety.

More Definitions of Project Superintendent

Project Superintendent means the person appointed by BHBB CCT JV from time as the Project's

Project Superintendent has the meaning set forth in Section 2.2.3.

Project Superintendent means the person designated by the Governing Body to have responsibility to supervise the acquisition, construction and equipping of the Projects and any successor to such person.

Project Superintendent means an employee of the Construction Management firm with full-time responsibility for supervision of all on-site employees of the CM and coordination of all subcontractors activities.

Project Superintendent means the Design-Builder’s on-site designated representative who oversees the construction of the Design-Build Contract, including directing and coordinating the activities of the Design-Builder’s workforce and all subcontractors, ensuring that the work

Project Superintendent means the Contractor's Project Superintendent assigned to the Project. The initial Project Superintendent is ▇▇▇▇ ▇▇▇▇▇▇. The Project Superintendent shall be changed only as specified in Section 6 of this Agreement and its subsections. 1.24 "Qualified Arbitrator" shall mean a person who has had experience with construction the size of Project, include Owners and General Contractors, and experience in construction and remodeling of healthcare facilities. The chair of Page 2 of 53 r„ VVellStar Health System,Inc. GC-101, Stipulated Sum General Contractor Afro M60t, 2010 Edition 44.

Project Superintendent means the person designated by the Contractor to function as his representative in the field with full authority to direct the work in the field for the Contractor.