Long Lead Work definition
Long Lead Work means any item which is not a stock item and must be specially manufactured, fabricated or installed or is of such an unusual, delicate or fragile nature that there is a substantial risk that
Long Lead Work means any item which is not a stock item and must be specially manufactured, fabricated or installed or is of such an unusual, delicate or fragile nature that there is a substantial risk that (i) there will be a delay in its manufacture, fabrication, delivery or installation, or (ii) after delivery of such item will need to be reshipped or redelivered or repaired so that, in Landlord’s reasonable judgment, the item in question cannot be completed when the standard items are completed even though the items of Long Lead Work in question are (1) ordered together with the other items required and (2) installed or performed (after the manufacture or fabrication thereof) in order and sequence that such Long Lead Work and other items are normally installed or performed in accordance with good construction practice. In addition, Long Lead Work shall include any standard item, which in accordance with good construction practice should be completed after the completion of any item of work in the nature of the items described in the immediately preceding sentence.
Long Lead Work shall have the meaning given to such term in Section 15.2.
Examples of Long Lead Work in a sentence
Upon the substantial completion of such repairs (excluding Long Lead Work), Landlord shall diligently prosecute to completion any items of Long Lead Work remaining to be completed.
In addition, Long Lead Work shall include any standard item, which in accordance with good construction practice should be completed after the completion of any item of work in the nature of the items described in the immediately preceding sentence.
If, in Landlord’s commercially reasonable judgment, any items of Landlord’s 7th Floor Work or any Additional 7th Floor Work shall involve Long Lead Work, or will otherwise delay completion of Landlord’s 7th Floor Work, then Landlord may require Tenant to agree on a fixed 7th Floor Substantial Completion Date (allowing a reasonable time for the performance of Landlord’s 7th Floor Work, as applicable, in absence of the necessity of performing the Long Lead Work).
If the parties cannot agree upon a fixed 7th Floor Substantial Completion Date, as applicable, then Landlord shall have the right to decline to perform such Long Lead Work, and Tenant shall be responsible for the performance thereof (subject to the terms of this Lease) after the completion of Landlord’s 7th Floor Work and any other (non-objected to by Landlord) Additional 7th Floor Work.
Landlord shall promptly and diligently in a good and workmanlike manner complete the Long Lead Work.
More Definitions of Long Lead Work
Long Lead Work means any item which is not a stock item and must be specially manufactured, fabricated or installed, or is not part of a customary office installation (such as kitchen equipment) to the extent that such installation is reasonably anticipated to cause an actual delay in the substantial completion of Landlord’s Work, Landlord’s Additional Premises Work, and/ or Landlord’s 7th Floor Work or is of such an unusual, delicate or fragile nature that there is a substantial risk that (i) there will be a delay in its manufacture, fabrication, delivery or installation, or (ii) after delivery, such item will need to be reshipped or redelivered or repaired, so that in Landlord’s reasonable judgment, such item will delay the substantial completion of Landlord’s Work, Landlord’s Additional Premises Work or Landlord’s 7th Floor Work. as applicable, beyond the date on which Landlord’s Work, Landlord’s Additional Premises Work or Landlord’s 7th Floor Work, as applicable, would have otherwise been substantially completed. In addition, Long Lead Work shall include any item which in accordance with good construction practice should be completed after the completion of any item of work in the nature of the items described in the immediately preceding sentence.”
Long Lead Work means any item which is not a stock item and must be specially manufactured, fabricated or installed, or is not part of a customary office installation (such as kitchen equipment) to the extent that such installation is reasonably anticipated to cause an actual delay in the substantial completion of Landlord’s Work or Landlord’s Additional Premises Work, or is of such an unusual, delicate or fragile nature that there is a substantial risk that (i) there will be a delay in its manufacture, fabrication, delivery or installation, or (ii) after delivery, such item will need to be reshipped or redelivered or repaired, so that in Landlord’s reasonable judgment, such item will delay the substantial completion of Landlord’s Work, or Landlord’s Additional Premises Work, as applicable, beyond the date on which Landlord’s Work or Landlord’s Additional Premises Work, as applicable, would have otherwise been substantially completed.
Long Lead Work means any item that is not a stock item and must be specially manufactured, fabricated or installed or is of such an unusual, delicate or fragile nature that there is a substantial risk that (a) there will be a delay in its manufacture, fabrication, delivery or installation, or (b) after delivery, such item will need to be reshipped or redelivered or repaired, so that in Landlord’s reasonable judgment the item in question cannot be completed when the standard items are completed even though the item of Long Lead Work in question is (i) ordered together with the other items required, and (ii) installed or performed (after the manufacture or fabrication thereof) in the order and sequence that such Long Lead Work and other items are normally installed or performed in accordance with good construction practice. In addition, “Long Lead Work” shall include any standard item that in accordance with good construction practice should be completed after the completion of any item of work in the nature of the items described in the immediately preceding sentence.
Long Lead Work means any item, other than an item which is, or is a component of, a Building-wide Building System which is necessary for the normal operation of office space, which is not a stock item and must be specially manufactured, fabricated or installed or is of such an unusual, delicate or fragile nature that there is a substantial risk that
Long Lead Work means any item of repair to Tenant's Alterations which is not a stock item and must be specifically manufactured, fabricated or installed or is of such an unusual, delicate or fragile nature that there is a substantial risk that (i) there will be a delay in its manufacture, fabrication, delivery or installation, or (ii) after delivery, such item will need to be reshipped or redelivered, so that the item of work in question would delay the completion of the standard items of such work even though the items of Long Lead Work in question are (A) ordered together with the other items required for such work and (B) then installed or performed (after the manufacture or fabrication thereof) in order and sequence that such Long Lead Work and other items of work are normally installed or performed in accordance with good construction practice.
Long Lead Work shall include any standard item which in accordance with good construction practice should be completed after the completion of any item of work in the nature of the items described in the immediately preceding sentence.
Long Lead Work means any item which is not a stock item and must be specially manufactured, fabricated or installed or is of such an unusual, delicate or fragile nature that there is a substantial risk that: (i) there will be a delay in its manufacture, fabrication, delivery or installation, or (ii) after delivery, such item will need to be reshipped or redelivered or repaired so that in Landlord’s reasonable judgment the item in question cannot be completed when the standard items are completed even though the item of Long Lead Work in question is (x) ordered together with the other items required and (y) installed or performed (after the manufacturer or fabrication thereof) in the order and sequence that such Long Lead Work and other items are normally installed or performed in accordance with good construction practice. Notwithstanding the foregoing, if any Landlord required Long Lead Work is required for Landlord to obtain a certificate of occupancy for the Building or for Tenant to obtain a certificate of occupancy for its tenant improvements, or if any Long Lead Work precludes Tenant’s use of the Building, Premises, and Garage, Base Building Systems, cafeteria or conference facility to conduct its business, then Landlord shall provide temporary improvements sufficient to allow Landlord to procure a certificate of occupancy for the Building and Tenant to procure a certificate of occupancy for its Premises (after Tenant has performed its own improvements to the Premises) and the reasonable use of all such facilities for conducting Tenant’s business until the Long Lead Work can be completed with the Landlord using reasonably diligent efforts to complete the Long Lead Work as soon as reasonably possible thereafter.