Long Lead Items definition

Long Lead Items means the Satellite components, materials, hardware, equipment and other related items that Contractor shall procure in performance of the Long-Lead Activities.

Long Lead Items means those satellite components purchased by the Contractor pursuant to Article 19.

Long Lead Items means improvements, items, materials, finishes or installations that Landlord, the Architect, or the Contractor advises Tenant in writing (in connection with the review of the Test Fit Plans, Permit Set Plans, Construction Set Plans and/or the review of proposed Tenant Change Orders) are not generally available as needed to meet the milestone dates set forth on the Construction Schedule.

Examples of Long Lead Items in a sentence

• List of Long Lead Items that could adversely impact the Project’s schedule and recommendations for purchase.

• Long Lead Items: Prepare an index of construction related items and equipment that will require long lead time for acquisition.

• Upon purchase, the Construction Manager shall safeguard the Long Lead Items until installed as part of the Project.

• The Construction Manager shall make such adjustments to the Master Schedule as necessary to accommodate the procurement process for the Long Lead Items.

• In support of this urgency with the understanding of NASA’s inability to fund Long Lead Items in the Base Period CLIN 0003, Blue Origin provided limited funding to the National Team to start Long Lead Item procurements in the Base Period, but this was a very small set of what was initially proposed in the base period CLIN 0003.22Blue Origin continued to calculate the subcontract requirements for such Long Lead Items would need to start such purchases at the beginning of Option A.

More Definitions of Long Lead Items

Long Lead Items means any components which the Authority has given the Contractor written approval to purchase in advance of the date of execution of the Contract.

Long Lead Items means improvements, items, materials, finishes or installations that are not available as needed to meet Lessor’s or Contractor’s schedule for Substantial Completion of the Addendum No. 6 Expansion Space Improvements.

Long Lead Items has the meaning given to it in the LLI Agreement.

Long Lead Items. As defined in Section 1.42. -----------------

Long Lead Items means any items of Work for which there is a long lead time in obtaining the materials therefore or which are specially or specifically manufactured, produced or milled for the Work in or to the Premises and require additional time for receipt or installation.

Long Lead Items or “LLI” shall mean the items to be procured in advance for the manufacture of Phase 3 Spacecraft as set forth in Article 26.

Long Lead Items shall be defined as any items of work for which, in Landlord’s reasonable judgment, there is a long lead time in obtaining the materials therefor or which are specially or specifically manufactured, produced or milled for the work in or to the Premises and require additional time for receipt or installation. In connection with its review and approval of the Plans, Landlord shall give written notice (“Long Lead Notice”) identifying and notifying Tenant of any items contained in the Plans which Landlord then reasonably believes to be a Long Lead Item as soon as Landlord is advised by the Contractor that an item is a Long Lead Item, but, in any event, on or before the date twenty (20) business days after Landlord receives the Final Plans. Landlord will give to Tenant Landlord’s best, good faith estimate of the period(s) of any delay which would be caused by a long-lead item. On or before the Long Lead Item Release Date, Tenant shall have the right to either (a) revise the Plans to eliminate any such long-lead item or (b) give Landlord written authorization to proceed to purchase and/or contract for Long Lead Items. Landlord shall advise Tenant, in its Long Lead Notice of any Long Lead Items which, in Landlord’s judgment, may still delay completion of the Landlord’s Work and thus result in a Tenant Delay even if Tenant authorizes their purchase or before the Long Lead Item Release Date. Tenant acknowledges that any such Long Lead Items so identified by Landlord may delay completion of Landlord’s Work and thus result in a Tenant Delay. No item shall be deemed to be a Long Lead Item unless Landlord identifies such item as a Long Lead Item in a Long Lead Notice in accordance with this Section III.A(5).