Installation Works definition

Installation Works means, as the context so requires,

Installation Works means, as the context so requires: collectively, all works which the Contractor is to carry out at the beginning of the Contract Period to install the Goods in accordance with the Specification and the Tender; or where there are a series of works to be carried out during the Contract Period to install the Goods in accordance with the Specification and the Tender, each set of installation works.

Installation Works means, as the context so requires:

Examples of Installation Works in a sentence

• Save to the extent that the Installation Contractor has caused or contributed directly or indirectly to any delay and subject to Clause 13.4, the Installation Contractor shall be entitled to an appropriate and reasonable extension of the Scheduled COD for delays to the Installation Works on the critical path as a result of any Relevant Event.

• No later than fifteen (15) Business Days after the Commencement Date and before undertaking any Installation Works at the Site, the Installation Contractor shall prepare its own safety management systems and site rules to be agreed by the Project Company taking into account the documents and applicable Laws referred under Clause 9.1 (HSE), perceived hazards and any other relevant information provided by the Project Company ("Site Safety Plan").

• If the Project Company subsequently remedies such failure prior to the Installation Contractor issuing a notice of Termination to the Project Company under Clause 25.1(b) (Project Company Termination Events), the Installation Contractor shall promptly resume performance of the Installation Works.

• Following the expiry of the Defects Warranty Period and the Installation Contractor having completed all outstanding Installation Works, assigned any manufacturer's warranties and guarantees to the Project Company (or such other person as directed by the Project Company) in accordance with Clause 19.2 (Manufacturer’s Warranties and Guarantees) and paid any Delay Liquidated Damages due, the Project Company shall issue the final acceptance certificate (the "Final Acceptance Certificate").

• The Installation Works may include the Interconnection Facilities.

More Definitions of Installation Works

Installation Works means, as the context so requires:collectively, all works which the Contractor is to carry out at the beginning of the Contract Period to install the Goods in accordance with the Specification and the Tender; orwhere there are a series of works to be carried out during the Contract Period to install the Goods in accordance with the Specification and the Tender, each set of installation works.

Installation Works means all works which the Supplier is to carry out at the beginning of the Call Off Contract Period to install the Goods in accordance with the Call Off Order Form;

Installation Works means all works which the Supplier is to carry out pursuant to the Call Off Agreement;

Installation Works means all works which the Supplier is to carry out at the beginning of the Contract Period to install the Goods in accordance with paragraph 2.4 of the Order Form;

Installation Works means, as the context so requires: ‫ ‫collectively, all works which the Contractor is to carry out at the beginning of the Contract Period to install the Goods in accordance with the Specification and the Tender; or where there are a series of works to be carried out during the Contract Period to install the Goods in accordance with the Specification and the Tender, each set of installation works. The Specification The Contractor shall supply and, where relevant, install the Goods in accordance with the Specification and the Tender and with all applicable provisions of the Contract. The Goods If requested by the Authority, the Contractor shall either provide the Authority with samples of Goods or performance demonstrations of Goods for evaluation and approval at the Contractor’s cost and expense. The Contractor shall ensure that the Goods are fully compatible with any equipment, to the extent specified in the Specification. The Contractor acknowledges that the Authority relies on the skill and judgment of the Contractor in the supply of the Goods and the performance of its obligations under the Contract.

Installation Works means all works which the Supplier is to carry out at the beginning of the Call Off Contract Period to install the Goods in accordance with the Order Form;

Installation Works all works which the Supplier is to carry out at the beginning of the Call-Off Contract Period to install the Goods in accordance with the Call-Off Contract;