Guaranteed Delivery Date definition

Guaranteed Delivery Date has the meaning set forth in Section 5.2.

Split View

AI-Powered Contracts

Draft, Review & Redline at the Speed of AI

Get StartedBook a Demo

Guaranteed Delivery Date means the dates specified in the Purchase Order in accordance with the Cell Delivery Schedule specified in Annexure B or any such other date which is mutually agreed between the Parties, by which date the agreed quantity of Cells is required to be delivered by Supplier at the Designated Delivery Point.

Guaranteed Delivery Date has the meaning set forth in Section 5.2. “Hazardous Materials” has the meaning set forth in Section 19.1. “Indemnified Party” has the meaning set forth in Section 15.1. “Indemnifying Party” has the meaning set forth in Section 15.1. “Infringement Claim Costs” means any and all judgments, damages, fines, awards, penalties, and interest associated with any of the foregoing, that, in each case, are finally awarded in a claim for which an Indemnifying Party is obligated to indemnify an Indemnified Party under Section 15.2 or 15.3, as applicable, and costs and expenses, including reasonable attorneys’ fees, court costs and other reasonable costs of suit, arbitration, dispute resolution or other similar proceedings, associated with such claim. “Integrated Solution” means an integrated, stationary, battery based energy storage solution, comprised of inverters, a control system including software, and electrical battery. Notwithstanding the foregoing, the following will not be considered Integrated Solutions:

Examples of Guaranteed Delivery Date in a sentence

• A “Change Order” is a written instrument signed by the Parties and stating their mutual agreement upon a change in the obligations of the Parties under this Agreement or any Purchase Order, including if applicable the amount of the adjustment in the purchase price and the extent of any adjustment to the Delivery schedule, including the Guaranteed Delivery Date.

• The Demonstration Period (defined herein) for the first Committed Capacity Test shall commence no earlier than six (6) months prior to the Capacity Delivery Date and testing must be completed by 11:59 p.m. on the date prior to the Guaranteed Delivery Date.

• Neither the Purchase Order nor any milestone date contained therein, including the Guaranteed Delivery Date for the Equipment, may be changed unless the same has been modified by a duly executed Change Order.

• The Demonstration Period (defined herein) for the first Committed Capacity Test shall commence no earlier than six (6) months prior to the Capacity Delivery Date and testing must be completed by 11:59 p.m. EST on the date prior to the Guaranteed Delivery Date.

• In either case, such amounts shall be calculated at the end of each week after the applicable Guaranteed Delivery Date until the date of delivery of the applicable Component, and shall be credited to Buyer in accordance with Section no later than thirty (30) days thereafter.

More Definitions of Guaranteed Delivery Date

Guaranteed Delivery Date has the meaning set forth in Section 5.2. “Hazardous Materials” has the meaning set forth in Section 19.1. “Indemnified Party” has the meaning set forth in Section 15.1. “Indemnifying Party” has the meaning set forth in Section 15.1. “Infringement Claim Costs” means any and all judgments, damages, fines, awards, penalties, and interest associated with any of the foregoing, that, in each case, are finally

Guaranteed Delivery Date means the final date of delivery of all Equipment purchased from Seller under the terms of this Agreement to the Destination, as set forth on Exhibit A hereto.

Guaranteed Delivery Date means the “Guaranteed Delivery Date” or “Agreed to Dates (by GE & Kiewit)” indicated on Exhibit A, Attachment 02-01f corresponding to each Major Component and Minor Component as provided in the Milestone Schedule (which Guaranteed Delivery Date may be adjusted in accordance with the terms and provisions of this Agreement).

Guaranteed Delivery Date has the meaning set forth in Section 3(a).

Guaranteed Delivery Date. “Incoterm”, “Invoice Schedule”, “Payment Terms”, “System Price” and “System Specifications” have the meaning given to them in the Accepted Purchase Order for the relevant System.

Guaranteed Delivery Date means those date/s for delivery confirmed in writing to Purchaser as fixed by the Company “Liquidated Damages Cap" shall mean the maximum agreed amount (if any) for payment of liquidated and ascertained damages “Normal Working Hours" shall mean 0800 to 1700 Monday to Friday

Guaranteed Delivery Date means January 15, 2010 as to Building One and February 15, 2010 as to Building Two and Building Three, subject as to each date to extension as follows: (i) on a day-for-day basis for each day that the Closing Date is delayed beyond May 26, 2008, (ii) based on Permitted Changes to the Project Schedule, or (iii) as provided in Section 4.5 in connection with Owner’s failure to fund requisitioned amounts.