Improvement Allowances Sample Clauses

Improvement Allowances. To help pay for those costs which are incurred by Tenant in designing and constructing those improvements which Tenant desires to make to the Fourth Amendment Expansion Spaces (the “Fourth Amendment Improvements”), Landlord shall make each Fourth Amendment Applicable Improvement Allowance available to Tenant. Landlord shall disburse each Fourth Amendment Applicable Improvement Allowance on a monthly basis in accordance with customary construction disbursement procedures and upon receipt of a sworn construction statement and draw requests, with supporting invoices for actual costs incurred and lien waivers from all material contractors and subcontractors delivered one month in arrears; it being agreed, however, that Landlord shall not be required to disburse any portion of a Fourth Amendment Applicable Improvement Allowance if Tenant is then in default of its obligations under the Lease. If the actual cost of the Fourth Amendment Improvements for any Fourth Amendment Expansion Space exceeds the amount of the Fourth Amendment Applicable Improvement Allowance for such Fourth Amendment Expansion Space, Tenant shall pay the excess costs without reimbursement from Landlord as and when such excess costs become due and payable. If Tenant has not submitted requisitions covering all of the Fourth Amendment Applicable Improvement Allowance for any Fourth Amendment Expansion Space on or before the Fourth Amendment Applicable Improvement Allowance Expiration Date for such Fourth Amendment Expansion Space, then up to, but not more than, $5.00 per square foot of any unused portion of the Fourth Amendment Applicable Improvement Allowance may be applied as a credit against the next installments of Rent due under this Lease. Notwithstanding anything to the contrary in the foregoing, Tenant may pool the Fourth Amendment Applicable Improvement Allowances for use in paying the costs of designing and constructing improvements to any one or more of the Fourth Amendment Expansion Spaces, but Tenant shall not be entitled to draw upon a Fourth Amendment Applicable Improvement Allowance prior to the Fourth Amendment Expansion Space Delivery Date for such Fourth Amendment Expansion Space, or after the Fourth Amendment Applicable Improvement Allowance Expiration Date. Landlord shall be permitted to offset against any Fourth Amendment Applicable Improvement Allowance any amounts past due to Landlord by Tenant under this Lease. Each Fourth Amendment Applicable Improvement Allowance shal...
Sample 1Sample 2See All (4)
AutoNDA by SimpleDocs
Improvement Allowances. (a) Tenant acknowledges that it has made a complete examination and inspection of the Premises and accepts the same in its current condition, "AS IS, WHERE IS", without recourse to Landlord, and Landlord shall have no obligation to complete any improvements to the Premises. ADDITIONALLY, LANDLORD MAKES NO WARRANTIES, EXPRESS OR IMPLIED, WITH RESPECT TO THE LEASEHOLD IMPROVEMENTS IN THE PREMISES. ALL IMPLIED WARRANTIES WITH RESPECT THERETO, INCLUDING BUT NOT LIMITED TO THOSE OF MERCHANTABILITY, HABITABILITY AND FITNESS FOR A PARTICULAR PURPOSE, ARE EXPRESSLY DISCLAIMED, NEGATED AND WAIVED. This Paragraph 5(a), however, is subject to the lease amendments set out in Paragraph 12 below.
Sample 1Sample 2
Improvement Allowances. In addition to performing the Work, as defined below in Subclause B, Lessor hereby agrees to provide County with an allowance of twenty dollars ($20.00) per RSF (totalling $147,080.00) to be used towards FF&E, cabling, and any other move-in related expenses (“FF&E Allowance”). Any unused FF&E Allowance may, at County’s sole discretion, be used to offset Rent and/or converted to cash upon thirty
Sample 1
Improvement Allowances. Tenant shall receive a “Base Improvement Allowance” of Two Hundred Forty-four Thousand Five Hundred Dollar ($244,500.00) allowance for construction of building improvements and for related architectural and engineering services. Tenant shall receive an “Additional Tenant Improvement Allowance” of up to Two Hundred Thousand Dollars ($200,000.00) at its option. The Base Improvement Allowance and the Additional Tenant Improvement Allowance, if elected, shall be used for Tenant directed building improvements, architectural and engineering services only. Attached hereto as Exhibit I is Tenant’s itemized list of all anticipated improvements, which list may not be changed without Landlord’s consent (which consent shall not be unreasonably withheld). Provided that the improvements specified in Exhibit I have been completed in compliance with Paragraph 12 and this paragraph, Landlord shall promptly reimburse Tenant for said improvements after presentation to Landlord of the invoices for the actual construction costs as billed. The parties understand and agree that the Improvement Allowances are made for Tenant’s benefit and to further induce Tenant to enter into the Lease. Accordingly, in the event of Tenant’s default, the unamortized amount of the Improvement Allowances shall be an element of Landlord’s damages for breach of the Lease.
Sample 1
Improvement Allowances. In consideration for Tenant funding all Tenant Improvement Work, Landlord shall provide abatement of Base Rent in accordance with the schedule in Article III Section 3.2 of this Lease "Tenant Improvement Allowance". Tenant agrees that the dollar value of such Tenant Improvement Allowance shall be used to pay the cost of: (i) the preparation of the Plans, (ii)obtaining the building permit and Certificate of Occupancy (or functional equivalent) from the City of Coral Gables, (iii) required demolition; (iv) the Tenant Improvement Work, and (v) buildout costs including, without limitation, government impact fees, refurbishing of existing improvements, decorations, signage and relocations and installation of HVAC system. The above shall include, without limitation, the purchase and installation of drywall partitions, ceiling, carpeting, wallcovering, window treatments and energy efficient and lighting fixtures. The Tenant shall have the right to use any existing Improvements in the Premises without additional costs and without deduction from the Improvement Allowance. Any requests by Tenant to modify the Plan or have any work ("Extra Work") not constituting a part of the Tenant Improvement Work to be installed in the Premises, shall require Landlord's prior written approval and any delays occasioned thereby (including, without limitation, a reasonable time for Landlord to review and approve revised Plans) shall be "Tenant Delays".
Sample 1
Improvement Allowances. (a) Sublessee shall cause the tenant fit-up and finish work in the Sublease Premises to be completed in accordance with plans and specifications to be agreed upon by Sublessor and Sublessee, in their respective reasonable judgment. Sublessor shall provide an allowance for the tenant fit-up and finish work in the Sublease Premises of $12.00 per rentable square foot for the 4th floor and $6.00 per rentable square foot for the 5th floor within the Sublease Premises (the "Allowance"). To the extent the costs to complete the tenant fit-up and finish work in the Sublease Premises are less than the Allowance, then the difference shall be retained by Sublessor. To the extent the costs to complete the tenant fit-up and finish work in the Sublease Premises are greater than the Allowance, then the amount of such excess shall be paid by Sublessee.
Sample 1
Improvement Allowances. Landlord has no obligation to improve or remodel the Premises and Tenant accepts the Premises in their “as is” condition on June 1, 2005 for the Extended Term. Notwithstanding the foregoing, Landlord agrees to make the following payments to Tenant: (i) within 30 days following the delivery of this Addendum, mutually executed, Landlord will pay Tenant [ * ] as a reimbursement to Tenant for existing improvements in the Premises (the “First Allowance”); and (ii) promptly after June 1, 2010, Landlord will pay Tenant [ * ] (the “Second Allowance”) as a reimbursement to Tenant for existing improvements in the Premises; provided that, if Tenant exercises its option under Section 10.C(2) below to maintain the Expiration Date as March 31, 2008, the Second Allowance will no longer be applicable. If there is an uncured event of default by Tenant at the time Landlord is obligated to pay the respective allowance, Landlord shall have the right to withhold payment of the respective allowance until such event of default is cured. Any amounts expended by Tenant in excess of the allowances shall be at Tenant’s sole cost and expense. Any alterations and improvements to the Premises by Tenant are subject to the terms of the Lease, including obtaining Landlord’s prior consent if required by the terms of the Lease.
Sample 1
AutoNDA by SimpleDocs
Improvement Allowances. (a) Tenant acknowledges that it has made a complete examination and inspection of the Added Premises and accepts the same in its current condition, “AS IS, WHERE IS”, without recourse to Landlord, and Landlord shall have no obligation to complete any improvements to the Premises. ADDITIONALLY, LANDLORD MAKES NO WARRANTIES, EXPRESS OR IMPLIED, WITH RESPECT TO THE LEASEHOLD IMPROVEMENTS IN THE PREMISES. ALL IMPLIED WARRANTIES WITH RESPECT THERETO, INCLUDING BUT NOT LIMITED TO THOSE OF MERCHANTABILITY, HABITABILITY AND FITNESS FOR A PARTICULAR PURPOSE, ARE EXPRESSLY DISCLAIMED, NEGATED AND WAIVED. This Paragraph 4(a), however, is subject to the lease amendments set out in Paragraph 12 below. Ninth Amendment to Office Lease May 8, 2007
Sample 1
Improvement Allowances 
Sample 1Sample 2Sample 3See All (5)

Related to Improvement Allowances

  • Improvement Allowance Landlord shall provide Tenant with an allowance for the costs (the “Allowance Costs”) of preparing the Premises for Tenant's initial occupancy (including the costs of Landlord’s Initial Construction) in an amount not to exceed the “Improvement Allowance,” as such term is defined in Section 1.1 of this Lease. Allowance Costs may include (i) up to $513,250 for architectural, engineering and other so-called “soft costs” and (ii) not to exceed $150,000 for the costs to cause the demolition of the Premises prior to the performance of Landlord’s Initial Construction. If requested by Tenant for any particular item(s) of Landlord’s Initial Construction in excess of $100,000, Landlord shall solicit bids from its general contractor who will solicit at least three (3) bids for each such item and shall promptly supply Tenant with such detailed information about bid requests and negotiations with contractors as Tenant may reasonably request, provided that any delays resulting from Tenant’s failure to act within two (2) business days upon the information supplied to it by Landlord shall constitute a Tenant Delay. In the case of each bid request, Landlord will accept the lowest responsible bid, unless Landlord and Tenant reasonably determine otherwise. Any HVAC control work shall be performed by AHA Consulting Engineers. Landlord shall notify Tenant of the total fixed-price construction cost of Landlord’s Initial Construction shown on such Construction Documents (the “Base Price”), including xxxx-ups as determined hereunder. The Base Price shall hereafter be subject to adjustment for Change Orders (if any). Costs of Building services or facilities (such as electricity, HVAC, and cleaning) actually required to implement Landlord’s Initial EAST\66392481.7 B-7 Construction and other variable costs to the extent required to be paid by Tenant under the Lease (such as for review, inspection, and testing) shall thereafter be added to the Base Price (as adjusted for Change Orders). A pro-rata share of the cost of the multi-tenant corridor, if applicable, which shall be constructed by Landlord, shall be added to the Base Price. All costs referred to in this paragraph shall be subject to reimbursement from the Improvement Allowance. In the event that the total fixed price of Landlord’s Initial Construction (as determined hereunder), together with any related costs reasonably estimated by Landlord, exceeds the Improvement Allowance, Landlord may from time to time require Tenant to pay such excess to Landlord before performing Landlord’s Initial Construction. Tenant shall be permitted to increase the Improvement Allowance (such increase being a “TI Allowance Increase”) to pay amounts otherwise due to Landlord under Section 7 below, subject to each of the following conditions:

  • Tenant Improvement Allowance Subject to the terms of this Section 38 set forth below, there shall be paid by the Landlord as the Landlord’s contribution toward Tenant’s Initial Alterations, the sum (“Allowance”) of $7,191,555.84, based upon a contribution of $68.04 per rentable square foot for 105,696 rentable square feet in the Initial Premises. Tenant shall submit to Landlord Tenant’s good faith estimate (“Qualified Cost Estimate”) of the Qualified Costs (hereinafter defined) to be incurred by Tenant in connection with its move to and the construction of Initial Alterations in the Premises. Installments of the Allowance shall be payable in accordance with the procedures set forth below. Installments of the Allowance, which shall in no event exceed in the aggregate the amount of the Allowance, shall be paid to Tenant (or, at Landlord’s option if Landlord reasonably determines that Tenant is not paying its contractors and such failure to pay may give rise to a lien against the Building, to the order of the contractor that performed the work set forth in the respective invoices) or, at Tenant’s option to Tenant’s contractors, with respect to Qualified Costs theretofore incurred by Tenant (and not theretofore paid to Tenant or which were Tenant’s responsibility as set forth in this Article 38) for which Tenant has submitted a requisition consisting of, (i) in the case of other than costs incurred under architectural and engineering contracts (collectively “Professional Services Contracts”) or under construction contracts, such as furniture or moving or professional fees that are contracted for by Tenant separate from construction and Professional Services Contracts, paid invoices, (ii) in the case of Professional Services Contracts, invoices, and (iii) in the case of construction costs (a) an application for payment and sworn statement of a contractor performing general contracting work in the Premises substantially in the form of AIA Document G-702 covering all work for which disbursement is to be made to a date specified therein which is part of the construction contract; (b) a certification from an AIA architect substantially in the form of the Architect’s Certificate for Payment which is located on AIA Document G702, Application and Certificate of Payment; (c) contractor’s, project managers and subcontractor’s waivers of liens which shall cover all applicable items of Qualified Costs under such construction contracts for which disbursement is being requested and any other statements and forms required for compliance with the mechanics’ lien laws of the Commonwealth of Massachusetts, together with invoices with respect to such Qualified Costs and such other supporting data as Landlord or Landlord’s Mortgagee may reasonably require; (iv) a cost breakdown for each trade or subcontractor performing the work included in Qualified Costs for which a request for disbursement under such construction contracts is being made; (v) copies of all construction contracts for the such Alterations, together with copies of all change orders, if any; and (iii) a request to disburse from Tenant containing an acknowledgement by Tenant of the work done and a good faith estimate of the cost to complete the Initial Alterations to the Premises. Upon completion of the Initial Alterations, and as part of the requisition for final disbursement of the Allowance for hard construction costs, Tenant shall furnish Landlord with: (1) general contractor and architect’s completion affidavits, (2) full and final waivers of lien, (3) receipted bills covering all labor and materials expended and used, (4) as-built plans of the Alterations, and (5) the certification of Tenant’s architect to the Landlord that, based on on-site observation and the data comprising the application for disbursement, to the best of the architect’s knowledge, information and belief, the Alterations have progressed as indicated in the application, the quality of the Alterations is in accordance with the construction contract documents and the contractor is entitled to; payment of the amount certified in the application. Notwithstanding the foregoing, if the Qualified Cost Estimate exceeds the Allowance, Tenant shall be entitled to payments with respect to any requisition in accordance with the terms hereof except that each individual disbursement of the Allowance by Landlord shall be in the same ratio to the amount properly requisitioned as the Allowance bears to the Adjusted Qualified Cost Estimate (hereinafter defined). “Adjusted

  • Tenant Improvement Allowance Items Except as otherwise set forth in this Tenant Work Letter, the Tenant Improvement Allowance shall be disbursed by Landlord only for the following items and costs (collectively the “Tenant Improvement Allowance Items”):

  • Disbursement of Tenant Improvement Allowance During the construction of the Tenant Improvements, Landlord shall make monthly disbursements of the Tenant Improvement Allowance for Tenant Improvement Allowance Items for the benefit of Tenant and shall authorize the release of monies for the benefit of Tenant as follows.

  • Tenant Allowance Landlord shall provide Tenant an allowance for each Building in an amount not to exceed the sum set forth in the Basic Lease Information for the Tenant Allowance for the applicable Building (collectively, the “Tenant Allowance”), to be applied toward the cost of the following items in respect of the Tenant Improvements in the applicable Building: Architectural and engineering fees, space planning, building permits or other governmental fees, and the cost of labor, materials, contractors fees and overhead, and other charges included in the construction contract for construction of Tenant Improvements, including the contractor’s fee, overhead and general conditions, sales and use taxes, the cost of the builder’s risk insurance during construction and all testing and inspection costs. If Landlord elects to itself construct the Restroom Improvements, Landlord shall make payments to its contractor for the Restroom Improvements as and when such costs are incurred and deduct the amount of such payments from the Tenant Allowance for Building 2 up to the maximum amount stated in Paragraph I of this Work Letter. Landlord shall not be obligated to disburse any remaining portion of the Tenant Allowance attributable to a Building until such time as (i) the Commencement Date for the applicable Building has occurred and Tenant has accepted delivery of the Building and made the initial prepayment of Rent with respect to the applicable portion of the Premises; and (ii) Tenant has delivered to Landlord and Landlord has approved, in Landlord’s reasonable discretion, all of the following: (A) invoices, paid receipts and/or related evidence reasonably acceptable to Landlord establishing that Tenant has paid an amount equal to that portion of the Tenant Allowance requested by Tenant to third parties in connection with the Tenant Improvements in the applicable Building; (B) executed unconditional final mechanics’ lien releases, in statutory form, from Tenant’s contractor and all subcontractors, laborers, materialmen and suppliers used by Tenant with respect to all work in and to the Premises located in the applicable Building; (C) a certificate from Tenant’s architect or space planner, in a form reasonably acceptable to Landlord, certifying that the construction of the Tenant Improvements in the applicable Building has been substantially completed and meets all applicable building codes; (D) a copy of the certificate of occupancy (or similar governmental authorization) for the applicable Building; (E) “as-built” drawings for the Tenant Improvements in the applicable Building, signed by either Tenant’s architect, space planner or contractor, and electronic CAD files from Tenant’s Contractor and all subcontractors; and (F) a final punch list signed off by both Tenant and Landlord and/or their architects. Thereafter, Landlord shall deliver, within fifteen (15) days following Tenant’s delivery of the materials and information required for disbursement thereof in the preceding sentence, a check payable to Tenant in the amount of that portion of the Tenant Allowance requested by Tenant and paid to third parties in connection with the Tenant Improvements for the applicable Building (which amount shall not exceed the portion of the Tenant Allowance provided for such Building as specified in the Basic Lease Information). Landlord’s payment of any portion of the Tenant Allowance shall not be deemed Landlord’s approval any of the Tenant Improvements absent Landlord’s prior approval pursuant to this Work Letter. Landlord’s obligation to disburse the Tenant Allowance for each Building under this Paragraph 9(b) shall expire six (6) months after the Delivery Date for the applicable Building, subject to extension due to Force Majeure, such that Landlord shall not be obligated to provide to Tenant any undisbursed portion of the Tenant Allowance for a Building unless Tenant has delivered to Landlord all documents required above within nine (9) months after the Delivery Date of such Building.

  • TI Allowance Landlord shall provide to Tenant a tenant improvement allowance (collectively, the “TI Allowance”) as follows:

  • Disbursement of the Tenant Improvement Allowance Except as otherwise set forth in this Tenant Work Letter, the Tenant Improvement Allowance shall be disbursed by Landlord (each of which disbursement shall be made pursuant to Landlord’s standard disbursement process), only for the following items and costs (collectively, the “Tenant Improvement Allowance Items”):

  • Construction Allowance (a) Landlord shall provide to Tenant a construction allowance not to exceed $135.00 per rentable square foot in the Relocation Premises (the “Construction Allowance”) to be applied toward the Total Construction Costs, as adjusted for any changes to the Tenant Work. If the Total Construction Costs are estimated to exceed the Construction Allowance by more than $5.00 per rentable square foot of the Relocation Premises, then no advance of the Construction Allowance shall be made by Landlord until Tenant has first paid to the contractor from its own funds (and provided reasonable evidence thereof to Landlord) the anticipated amount by which the projected Total Construction Costs exceed the amount of the Construction Allowance. Thereafter, Landlord shall pay to Tenant (or at Tenant’s request directly to Tenant’s general contractor) the Construction Allowance in multiple disbursements (but not more than once in any calendar month) following the receipt by Landlord of the following items: (i) a request for payment and sworn statements of Tenant and contractor, (ii) final or partial lien waivers, as the case may be, from all persons performing work or supplying or fabricating materials for the Tenant Work, fully executed, acknowledged and in recordable form, which waivers may be conditioned upon receipt of payment, (iii) the Architect’s certification that the Tenant Work for which reimbursement has been requested has been finally completed, including (with respect to the last application for payment only) any punch-list items, on the appropriate AIA form or another form approved by Landlord, and, (iv) with respect to the disbursement of the last 10% of the Construction Allowance, (1) the permanent certificate of occupancy issued for the Relocation Premises, if required by applicable law, (2) the record drawing in CAD format, PDF format and hard copy required by Section 5 above, and (3) an estoppel certificate confirming such factual matters as Landlord or Landlord’s Mortgagee may reasonably request (collectively, a “Completed Application for Payment”). Landlord shall pay the amount requested in the applicable Completed Application for Payment to Tenant within 30 days following Tenant’s submission of the Completed Application for Payment. If, however, the Completed Application for Payment is incomplete or incorrect, Landlord shall promptly notify Tenant of the same and Landlord’s payment of such request shall be deferred until 30 days following Landlord’s receipt of the corrected Completed Application for Payment. Notwithstanding anything to the contrary contained in this Exhibit, Landlord shall not be obligated to make any disbursement of the Construction Allowance during the pendency of any of the following: (1) Landlord has received written notice of any unpaid claims relating to any portion of the Tenant Work or materials in connection therewith covered by previously funded applications for payment, (2) there is an unbonded lien outstanding against the Building or the Relocation Premises or Tenant’s interest therein by reason of work done, or claimed to have been done, or materials supplied or specifically fabricated, claimed to have been supplied or specifically fabricated, to or for Tenant or the Relocation Premises, (3) the conditions to the advance of the Construction Allowance are not satisfied, or (4) Tenant is in Default under the Lease.

  • Tenant Improvement Costs The Tenant Improvements’ cost (the “Tenant Improvement Costs”) shall mean and include any and all costs and expenses of the Work, including, without limitation, all of the following:

  • Tenant Improvements Subject to the terms and conditions hereof, Landlord agrees, at its cost and expense to complete a “turnkey” interior build-out (“Tenant Improvements”) of the Leased Premises in accordance with the conditions stated in the Work Letter attached hereto as Exhibit C and incorporated hereby pursuant to the Approved Final Plans to be finalized and approved in accordance with the Work Letter and upon approval attached thereto. Any changes or modifications to the Approved Final Plans thereafter must be done in writing and signed by both Tenant and Landlord in accordance with the Work Letter. So long as in accordance with Article 19 of this Lease, Tenant agrees that Landlord shall be entitled to select, in its reasonable discretion and acting in good faith, all architects, engineers, contractors and material suppliers necessary to furnish the labor and materials for the construction of the Tenant Improvements. Landlord shall be the sole contracting party with respect to the employment of contractors which perform the work necessary to construct the Tenant Improvements. Tenant shall not be entitled to access to the Leased Premises prior to the Date of Substantial Completion and Tenant shall not interfere with or impair in any material way the construction of the Tenant Improvements, and any such interference or impairment shall be included within a Tenant Delay as defined in the Work Letter and shall entitle Landlord to all remedies provided herein for breach of this Lease. Prior to the Possession Date, Tenant shall not enter into any contract for construction of any improvements within the Leased Premises with any person other than Landlord without Landlord's prior written consent. Tenant, at Tenant's expense, shall obtain and maintain any and all necessary permits and licenses to enable Tenant to conduct Tenant’s Permitted Use, and the failure of Tenant to obtain or maintain same shall not in any manner affect the Tenant’s obligations hereunder. Landlord shall be solely responsible, at its cost and expense, for obtaining all permits and approvals related to the Tenant Improvements.

Time is Money Join Law Insider Premium to draft better contracts faster.