Major Renovation Sample Clauses

Major Renovation. If during any consecutive 12-month period during the Term of this Lease, a Major Renovation of the Facility is undertaken, either pursuant to (i) the agreed upon Capital Budget, or (ii) as otherwise agreed to by Lessor, Lessor and Lessee shall agree on an appropriate adjustment, if any, in the Rent payable under this Lease after the completion of such Major Renovation, if it is reasonably anticipated that such Major Renovation will have a material impact on the revenues to be derived or expenses to be incurred at the Facility. In the event that Lessor and Lessee are unable to agree upon any Rent adjustment pursuant to this Section 38.2, after using good faith efforts to do so, the matter shall be submitted to arbitration under Section 40.2 hereof.
Sample 1Sample 2
AutoNDA by SimpleDocs
Major Renovation. The obligations under this Subsection are separate from and in addition to all of the preceding obligations under this subsection. Lessee understands and agrees that, in order to operate a first- class business, maintain the Improvements in a first-class condition, and to provide up-to-date facilities of first-class order, periodic major renovation and refurbishing of the Improvements is necessary. During the first year and the third year of the term of this Lease (or such other time approved in writing by the Port) Lessee shall submit to the Port for Port approval a detailed plan for Lessee’s major renovation and refurbishing of the Improvements, which provides for the commencement of work on such dates as may be authorized in writing by the Port. Within 90 days after receipt of said detailed plan of major renovation and refurbishing the Port shall approve, disapprove or request amendments to said plan, and Lessee within 30 days thereafter, as appropriate, shall submit to the Port a new or amended plan. The Port shall approve or disapprove the new or amended plan within 60 days after Lessee’s submittal. The Port’s approval shall not be unreasonably withheld or delayed. After approval of the plan and necessary building permits by the Port, Lessee shall promptly secure all necessary permits and approvals for the work and commence construction, and thereafter diligently complete the same as provided in said Port-approved plan.
Sample 1
Major Renovation. If in any Lease Year during the Term of ---------------- this Lease, a renovation of the Facility is required, either pursuant to (i) the agreed upon Capital Budget, or (ii) as otherwise agreed to by Lessor, and the total cost of such renovation (including, but not limited to, any termination fees and penalties, including liquidated damages, if such renovation is incurred in connection with a change of the existing franchise), is or will be equal to or greater than eight percent (8%) of actual or projected Gross Revenues derived or to be derived from the Leased Property for such Lease Year (a "Major Renovation"), Lessor and Lessee hereby agree that the Rent payable under Section 3.1 hereof shall be adjusted, based upon the following formula: First, an amount equal to the sum of 4% of the actual Gross Revenues derived from the Leased Property for each Lease Year of the Term for the period commencing from January, 1998 to and including the then current Lease Year, based upon 4% of the actual or projected Gross Revenues for such Lease Year in which the Major Renovation shall occur (the "Cumulative Capital Expenditure Reserve") shall be compared to the total amount of Capital Expenditures actually paid by Lessor for the Leased Property during such period (the "Cumulative Capital Expenditures"). If the Cumulative Capital Expenditure Reserve exceeds the Cumulative Capital Expenditures, the excess amount shall be subtracted from the total cost of the Major Renovation, and the Rent shall be increased by an amount equal to 7% of the difference from and after the date on which such Major Renovation has been substantially completed (the "Completion Date"). If the Cumulative Capital Expenditures exceed the Cumulative Capital Expenditure Reserve, the excess amount shall be added to the total cost of the Major Renovation, and the Rent shall be increased by an amount equal to 7% of the sum from and after the Completion Date. In the event that Lessor and Lessee are unable to agree to the Rent adjustment or the Completion Date pursuant to this Section, after using good faith efforts to do so, the matter shall be submitted to arbitration under Section 40.2 hereof.
Sample 1
Major Renovation. Notwithstanding anything contained in this Lease to the contrary, in the event the Premises, is damaged or destroyed and this Lease has not been terminated as elsewhere provided herein, and Landlord does not complete the reconstruction of the Premises and the building the Premises are located in, within two hundred seventy (270) days after such damage or destruction, Tenant, at its option, may terminate this Lease effective upon written notice thereof to Landlord given at any time prior to the substantial completion of such reconstruction.
Sample 1

Related to Major Renovation

  • Construction of the Tenant Improvements Landlord shall construct the Tenant Improvements in accordance with this exhibit and the construction contract to be executed by Landlord and its contractor(s). The construction contract for constructing the Tenant Improvements and the contractor(s) to perform the work shall be approved and/or selected, as the case may be, by Landlord at its sole and absolute discretion without the consent of Tenant.

  • Tenant Improvements Subject to the terms and conditions hereof, Landlord agrees, at its cost and expense to complete a “turnkey” interior build-out (“Tenant Improvements”) of the Leased Premises in accordance with the conditions stated in the Work Letter attached hereto as Exhibit C and incorporated hereby pursuant to the Approved Final Plans to be finalized and approved in accordance with the Work Letter and upon approval attached thereto. Any changes or modifications to the Approved Final Plans thereafter must be done in writing and signed by both Tenant and Landlord in accordance with the Work Letter. So long as in accordance with Article 19 of this Lease, Tenant agrees that Landlord shall be entitled to select, in its reasonable discretion and acting in good faith, all architects, engineers, contractors and material suppliers necessary to furnish the labor and materials for the construction of the Tenant Improvements. Landlord shall be the sole contracting party with respect to the employment of contractors which perform the work necessary to construct the Tenant Improvements. Tenant shall not be entitled to access to the Leased Premises prior to the Date of Substantial Completion and Tenant shall not interfere with or impair in any material way the construction of the Tenant Improvements, and any such interference or impairment shall be included within a Tenant Delay as defined in the Work Letter and shall entitle Landlord to all remedies provided herein for breach of this Lease. Prior to the Possession Date, Tenant shall not enter into any contract for construction of any improvements within the Leased Premises with any person other than Landlord without Landlord's prior written consent. Tenant, at Tenant's expense, shall obtain and maintain any and all necessary permits and licenses to enable Tenant to conduct Tenant’s Permitted Use, and the failure of Tenant to obtain or maintain same shall not in any manner affect the Tenant’s obligations hereunder. Landlord shall be solely responsible, at its cost and expense, for obtaining all permits and approvals related to the Tenant Improvements.

  • Cost of Tenant Improvements Unless specified otherwise herein, Landlord shall bear and pay the cost of the Tenant Improvements (which cost shall include, without limitation, the costs of construction, the cost of permits and permit expediting, and all architectural and engineering services obtained by Landlord in connection with the Tenant Improvements, the Contractor's fees, Landlord's fee for construction administration in an amount equal to the amount charged by any construction manager retained by Landlord (the "Construction Manager") up to a maximum of $6,121,750 (the "Tenant Improvement Allowance"). The Tenant Improvement Allowance shall be utilized only for building improvements to the Building (and Tenant's architect fees), and not for signage, furniture costs, any third party consulting or contracting fees, any telecom/cabling costs, or any other purpose. Tenant shall bear and pay the cost of the Tenant Improvements (including but not limited to all of the foregoing fees and costs) in excess of the Tenant Improvement Allowance, if any. The cost of the Tenant Improvements shall exclude the cost of furniture, fixtures and inventory and other items of Tenant's Work (as defined below). Notwithstanding the foregoing, the Tenant Improvement Allowance shall not be used for (and Tenant shall have no responsibility for) the following costs except to the extent any of the foregoing are caused by Tenant, are due to Tenant Delays or result from the failure of Tenant to comply with the terms of the Lease or this Work Letter: (1) Property Maintenance Costs prior to the Delivery Date; (2) charges for overtime, except to the extent approved by Tenant; (3) costs to correct construction defects; (4) costs incurred to enforce contracts or cure contractor or subcontractor defaults (including legal fees); or (5) principal or interest on construction loan obtained by Landlord for construction of the Tenant Improvements.

  • Building Renovations It is specifically understood and agreed that Landlord has made no representation or warranty to Tenant and has no obligation and has made no promises to alter, remodel, improve, renovate, repair or decorate the Premises, Building, or any part thereof and that no representations respecting the condition of the Premises or the Building have been made by Landlord to Tenant except as specifically set forth herein or in the Work Letter Agreement. However, Tenant hereby acknowledges that Landlord is currently renovating or may during the Lease Term renovate, improve, alter, or modify (collectively, the "Renovations") the Project, the Building and/or the Premises including without limitation the parking structure, common areas, systems and equipment, roof, and structural portions of the same, which Renovations may include, without limitation, (i) installing sprinklers in the Building common areas and tenant spaces, (ii) modifying the common areas and tenant spaces to comply with applicable laws and regulations, including regulations relating to the physically disabled, seismic conditions, and building safety and security, and (iii) installing new floor covering, lighting, and wall coverings in the Building common areas, and in connection with any Renovations, Landlord may, among other things, erect scaffolding or other necessary structures in the Building, limit or eliminate access to portions of the Project, including portions of the common areas, or perform work in the Building, which work may create noise, dust or leave debris in the Building. Tenant hereby agrees that such Renovations and Landlord's actions in connection with such Renovations shall in no way constitute a constructive eviction of Tenant nor entitle Tenant to any abatement of Rent. Landlord shall have no responsibility or for any reason be liable to Tenant for any direct or indirect injury to or interference with Tenant's business arising from the Renovations, nor shall Tenant be entitled to any compensation or damages from Landlord for loss of the use of the whole or any part of the Premises or of Tenant's personal property or improvements resulting from the Renovations or Landlord's actions in connection with such Renovations, or for any inconvenience or annoyance occasioned by such Renovations or Landlord's actions.

  • Construction of Tenant Improvements After the Landlord and Ground Lessor (in accordance with Paragraph 12 hereof) approve Tenant’s Plans and Tenant receives any necessary building permits, Tenant shall administer and diligently prosecute the construction of Tenant Improvements in accordance with Tenant’s Plans, in compliance with applicable Laws, and using building standard material, subject to Landlord’s right, at its election, to itself construct the Restroom Improvements. All Tenant Improvements (other than, if applicable, the Restroom Improvements) shall be constructed by Tenant’s Contractor (and/or its subcontractors), and Tenant shall be responsible for project management with respect to construction of the Tenant Improvements. During construction of the Tenant Improvements, Tenant and its contractors and subcontractors (i) shall not interfere with the access to, use of, or business conducted within any other portions of the Project by other tenants or occupants, (ii) shall use diligent efforts to coordinate the timing of work, deliveries and other construction matters with tenants or occupants of the Project that could be adversely impacted by such work, deliveries and construction matters, including, without limitation, by scheduling work CERTAIN CONFIDENTIAL PORTIONS OF THIS EXHIBIT WERE OMITTED AND REPLACED WITH “[***]”. A COMPLETE VERSION OF THIS EXHIBIT HAS BEEN FILED SEPARATELY WITH THE SECRETARY OF THE SECURITIES AND EXCHANGE COMMISSION PURSUANT TO AN APPLICATION REQUESTING CONFIDENTIAL TREATMENT UNDER RULE 406 OF THE SECURITIES ACT OF 1933. that would create noise, vibrations, dust or other similar annoyances to other tenants or occupants of the Project outside normal business hours, notwithstanding any additional cost (for overtime or otherwise) that Tenant may incur, (iii) shall clean and secure construction and staging areas daily, (iv) shall stage all construction and store all construction materials and equipment in a location designated by Landlord (in Landlord’s sole discretion) on the Project, and (v) shall otherwise abide by all rules and requirements established or imposed by Landlord relating to the performance of the Tenant Improvements, including rules relating to any required shutdown of utilities (including life-safety systems), storage of materials, and coordination of work with other tenant’s or occupant’s contractors. Tenant shall not be charged any construction management fee for Landlord’s review of Tenant’s Plans or any oversight of the construction of the Tenant Improvements.

  • Landlord Improvements Landlord will construct a laboratory build-out for the Premises ("Landlord Improvements") pursuant to plans submitted by Landlord to Tenant and reasonably approved by Tenant ("Plans"), which shall be consistent with the floor plan attached hereto as Exhibit "C." The Plans generally shall provide for the Landlord Improvements to be constructed in order to accommodate generally accepted generic biotechnical laboratory uses, except as Landlord may otherwise agree. Unless otherwise determined by Landlord, the Tenant Improvements shall include the construction of an energy efficient electronically controlled central HV/AC plant. Within five (5) days after the Effective Date, Tenant shall provide to Landlord for Landlord's review and approval the following: (i) a proposed detailed list of equipment for the Premises, with the make, model, and specifications, and (ii) a detailed chemical inventory, with all codes and classifications. Tenant shall provide to Landlord such other information as Landlord may reasonably request for construction of the Landlord Improvements within five (5) days after written request therefor. Tenant shall provide written notice of its disapproval of the Plans within five (5) days after the Plans have been submitted detailing its precise reasons for disapproval. The failure of Tenant to disapprove the Plans in writing within a five (5) day period shall be conclusively deemed Tenant's approval of the Plans. Landlord shall have its architect revise the Plans to remedy any reasonable objections of Tenant, and Tenant shall have an additional five (5) day period to review the revised Plans to reasonably determine if such objections were satisfied; provided, however, Tenant shall make no new objections to the Plans. If there are any reasonable objections not addressed by revised Plans, the review procedure shall be repeated until all Tenant's objections are reasonably satisfied. If Tenant has not fully approved the Plans within sixty (60) days after the date such plans were first submitted to Tenant hereunder, Landlord at its sole election may terminate this Lease. Tenant shall timely sign and submit to Landlord a Certificate of Approval of Tenant Improvement Plans in the form as shown in Exhibit "F" attached to this Lease and incorporated herein by this reference ("Certificate"). In the case where Tenant is deemed to have approved the Plans on account of Tenant's failure to timely respond following the delivery of the Plans, such approval shall be deemed to have been given in accordance with the terms of the Certificate. Tenant acknowledges that Landlord may reasonably change the Plans as required by Applicable Law or unforeseen circumstances.

  • Improvements; Alterations Improvements to the Premises shall be installed at Tenant’s expense only in accordance with plans and specifications which have been previously submitted to and approved in writing by Landlord, which approval shall be governed by the provisions set forth in this Section 8(a). No alterations or physical additions in or to the Premises may be made without Landlord’s prior written consent, which shall not be unreasonably withheld or delayed; however, Landlord may withhold its consent to any alteration or addition that would adversely affect (in the reasonable discretion of Landlord) the (1) Building’s Structure or the Building’s Systems (including the Building’s restrooms or mechanical rooms), (2) exterior appearance of the Building, (3) appearance of the Building’s common areas or elevator lobby areas, or (4) provision of services to other occupants of the Building. Tenant shall not paint or install lighting or decorations, signs, window or door lettering, or advertising media of any type visible from the exterior of the Premises without the prior written consent of Landlord, which consent may be withheld in Landlord’s sole and absolute discretion. All alterations, additions, and improvements shall be constructed, maintained, and used by Tenant, at its risk and expense, in accordance with all Laws; Landlord’s consent to or approval of any alterations, additions or improvements (or the plans therefor) shall not constitute a representation or warranty by Landlord, nor Landlord’s acceptance, that the same comply with sound architectural and/or engineering practices or with all applicable Laws, and Tenant shall be solely responsible for ensuring all such compliance.

  • Alterations Tenant agrees that it will not (a) demolish or undertake any structural alterations of any of the buildings or other improvements erected upon or otherwise comprising the Demised Premises, without the prior written consent of Landlord or (b) make any other alterations which would change the character of the buildings or other improvements comprising the Demised Premises or which would weaken, impair or otherwise in any way affect the structural aspects of integrity of or lessen the value of the Demised Premises and/or the buildings and other improvements comprising the Demised Premises. With respect to any alterations permitted to be made by Tenant pursuant to this Article Ten, Tenant shall (a) pay all costs, expenses and charges thereof, (b) make the same in accordance with all applicable laws and building codes in a good and workmanlike manner, (c) cause the same to be performed by qualified contractors who shall not create any labor or other disturbance at the Demised Premises while performing same, (d) fully and completely indemnify and hold harmless Landlord from and against any mechanic’s liens or other liens or claims in connection with the making thereof and (e) by reason of such alterations, not thereby and (e) by reason of such alterations, not thereby reduce the economic value of the Demised Premises. All alterations, improvements and additions to the Demised Premises permitted to be made by Tenant hereunder, shall be made in accordance with all applicable laws and plans and specifications previously submitted to Landlord for Landlord’s approval, which approval shall not be unreasonably withheld or delayed, and, except for removable trade fixtures, shall at once when made or installed be deemed to have attached to the freehold and to have become the property of Landlord and shall remain for the benefit of Landlord at the end of the term or other expiration of this Lease in as good order and condition as they were when installed, reasonable wear and tear excepted. In the event in the making of such alteration, improvements and additions as herein provided, Tenant further agrees to indemnify and hold harmless Landlord from and against all costs, expenses, liens, claims and damages arising out of, or resulting from the undertaking or making of such alterations, improvements and additions.

  • Base Building Work Landlord shall construct the Base Building Work as further set forth on Exhibit 10.03, attached.

  • Capital Improvements The Department has identified the following possible opportunities for Capital Improvements:

Time is Money Join Law Insider Premium to draft better contracts faster.