Latent Conditions. 62.17 If, during the execution of the work under the Contract, the Contractor encounters on the site or its surroundings, physical conditions (other than climatic conditions or conditions arising there from) including artificial obstructions, which he considers:
Latent Conditions. If TasNetworks accepts that a latent condition exists under clause 5.3(c) it must give a notice to the Customer as soon as possible that specifies at a minimum:
Latent Conditions. 35.1 If the Service Provider becomes aware of a Latent Condition, it must give AMSA written notice within 24 hours after becoming aware of the latent condition, including any evidence to identify the Latent Condition.
Latent Conditions. A.19.1 If, during the execution of the Works, the Contractor becomes aware of a Latent Condition, the Contractor must, within 3 Business Days of becoming aware of the Latent Condition, and before the Latent Condition is disturbed, give a written Notice to the Principal specifying:
Latent Conditions. (a) If, during the performance of the Works, the Contractor becomes aware of any physical condition of the Site which may be a Latent Condition, the Contractor must, before disturbing the physical Site condition, give written notice to Tetra Tech’s Representative of the existence of the physical Site Condition.
Latent Conditions. Where remodeling, alteration or rehabilitation work occurs, the Association understands and acknowledges that certain design and technical decisions are made on assumptions based on readily available documents and visual observations of existing conditions and because some of these assumptions may not be verifiable without expending additional sums of money or destroying otherwise adequate or serviceable portions of the community, Association and Consultant agree that the discovery of unanticipated latent conditions may require a renegotiation of the scope of services or a termination of services. Association shall rely on Consultant’s judgment as to the continued adequacy of this Agreement in light of discoveries that were not anticipated or known. If Consultant determines that renegotiation is necessary, Consultant and Association shall in good faith enter into renegotiation of this Agreement to permit Consultant to continue to meet Association’s needs. If renegotiated terms cannot be agreed to, Association agrees that Consultant has the right to terminate this Agreement. If the Agreement is terminated, Association shall pay Consultant for all services conducted and expenses incurred up to and including the date of termination.
Latent Conditions. We shall be entitled to an extension of time and our reasonable delay costs, if any, and reimbursed all costs arising out of any latent conditions.
Latent Conditions. (a) If during the installation of the EPC Solutions, the Contractor becomes aware of a latent condition that will affect the completion of the installation, the Contractor must (as a condition precedent to any entitlement to additional time or money) forthwith and where possible before the latent condition is disturbed, (and in any event within five business days) give written notice thereof to the Customer and obtain the Customer’s written consent to undertake any action which may cause Contractor any additional cost which the Customer may be liable to pay.
Latent Conditions. On becoming aware of any Latent Condition, the Contractor must give the Owner written notice of the Latent Condition in a QBCC Form 4 - Variation Document.
Latent Conditions. This Clause has been amended to make all weather conditions excluded and not just weather conditions at the site. It was arguable that because the words at the site were included in the 1986 edition, that weather conditions which occurred off site and which caused a latent condition on site, e.g. seepage, could be a latent condition. The deletion of the words at the site clarifies that all latent conditions due to weather are exempt from the definition. This approach— • increases clarity of the provision; and therefore • should minimize disputes in this area.
