INSERT APPROPRIATE Sample Clauses

INSERT APPROPRIATE. EXECUTION CLAUSE FOR CONSULTANT] CONDITIONS OF SUBCONTRACT Glossary of terms, interpretation AND MISCELLANEOUS Glossary of Terms Unless the context otherwise indicates, whenever used in the Subcontract, each word or phrase in the headings in clause 1.1 has the meaning given to it under the relevant heading. Accredited Building Surveyor A person who is: a building surveyor accredited by the Australian Institute of Building Surveyors; or from time to time nominated in the MFPE as having the capacity to certify compliance with the requirements of the MFPE and the National Construction Code for Commonwealth projects similar to the MCC Works.
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
INSERT APPROPRIATE. EXECUTION CLAUSE FOR CONTRACTOR] CONDITIONS OF CONTRACT COMMENCEMENT Contractor's Obligations The Contractor must: give the Contract Administrator the prior written notice specified in the Contract Particulars of when it proposes to commence work on Site; and immediately commence to perform the Contractor's Activities and commence work on the Site by the date specified in the Contract Particulars. Principal's Obligations The Principal must: after: the Contractor provides the Contract Administrator with evidence satisfactory to the Contract Administrator that each insurance policy required under clause 4.3(a) is current; the Site Management Plan, the Work Health and Safety Plan and the Environmental Management Plan have been finalised under clause 8.7; and the Contractor has satisfied the conditions precedent to access set out in the Contract Particulars, give the Contractor sufficient access to the Site to allow it to commence work on Site provided that it will not be obliged to provide such access earlier than the date stated in the Contractor's notice under clause 1.1(a); and subject to other provisions of the Contract affecting access, continue to allow the Contractor sufficient access to the Site to enable it to perform its Contract obligations. Delayed Access Failure by the Principal to give access as required by clause 1.2(a) will not be a breach of Contract but will entitle the Contractor to: claim an extension of time to the Date for Completion under clause 9.4 if it is delayed in achieving Completion by the Date for Completion; and be paid by the Principal any extra costs incurred by it arising from the Principal's delay in giving the Contractor access to the Site. The Contractor's entitlement under paragraph (b) will be its only right to payment of money arising from the Principal's failure to give access as required by clause 1.2(a) and will be subject to the Contractor complying with clause 12.
Sample 1Sample 2See All (4)
INSERT APPROPRIATE. EXECUTION CLAUSE FOR CONTRACTOR] CONDITIONS OF CONTRACT COMMENCEMENT Contractor's Obligations The Contractor must: give the PDS Contractor the prior written notice specified in the Contract Particulars of when it proposes to commence work on Site; and immediately commence to perform the Contractor's Activities and commence work on the Site by the time specified in the Contract Particulars.
Sample 1Sample 2Sample 3
INSERT APPROPRIATE. EXECUTION CLAUSE FOR WARRANTOR] MORAL RIGHTS CONSENT Deed Poll made at [INSERT PLACE] on [INSERT DAY AND MONTH], 20[INSERT YEAR] By: [INSERT NAME OF INDIVIDUAL] of [INSERT ADDRESS], [INSERT OCCUPATION] (Author) In favour of: Commonwealth of Australia (Commonwealth)
Sample 1Sample 2
INSERT APPROPRIATE. EXECUTION CLAUSE FOR CONTRACTOR AND EXPERT] CONTRACTOR DESIGN CERTIFICATE [OPTION 1 - MONTHLY] [DATE] [NAME AND ABN OF CONTRACTOR] (Contractor) To: PDS Contractor Re: Estate Works Program Medium Works Contract for [INSERT BRIEF PROJECT DETAILS] dated [INSERT DATE OF CONTRACT] [INSERT RELEVANT SECTION, IF APPLICABLE] CERTIFICATION OF DESIGN FOR [MONTH] The Contractor certifies that: the design of the part of the Works which the Design Documents expressly or impliedly requires it to design complies with: subject to clause 7.3(a) of the Contract, all Statutory Requirements (including the WHS Legislation); and the requirements of the Contract; and the Works comply or the Section specified above complies (as the case may be) with the design which has been the subject of the PDS Contractor's permission under clause 5.2 of the Contract, as at the date of this certificate, except to the extent set out below: [INSERT DETAILS, IF ANY]. Terms defined in the Contract have the same meaning in this certificate. Yours faithfully, [CONTRACTOR'S REPRESENTATIVE] [OPTION 2 - CONDITION PRECEDENT TO COMPLETION OF THE WORKS OR A SECTION] [DATE] [NAME AND ABN OF CONTRACTOR] (Contractor) To: PDS Contractor Re: Estate Works Program Medium Works Contract for [INSERT BRIEF PROJECT DETAILS] dated [INSERT DATE OF CONTRACT] [INSERT RELEVANT SECTION, IF APPLICABLE] The Contract requires the Contractor to provide this certificate as a condition precedent to Completion of the Works or the Section specified above (if any).
Sample 1

Related to INSERT APPROPRIATE

  • Appropriate Use It will use its Project property for appropriate purposes (including joint development purposes as well as uses that provide program income to support public transportation) for the duration of the useful life of its Project property, which may extend beyond the duration of the Award, and consistent with other requirements FTA may impose.

  • Court Approval This Agreement is subject to approval of the courts with respect to participating carriers in the hands of receivers or trustees.

  • Appropriate Technical and Organizational Measures SAP has implemented and will apply the technical and organizational measures set forth in Appendix 2. Customer has reviewed such measures and agrees that as to the Cloud Service selected by Customer in the Order Form the measures are appropriate taking into account the state of the art, the costs of implementation, nature, scope, context and purposes of the processing of Personal Data.

  • Court Appearances If an employee is subpoenaed to appear as a witness in a job-related court case, not during the employee’s regularly assigned shift, the employee shall be credited for actual time worked, or a minimum of two and one-half hours, whichever is greater.

  • MUTUAL AGREEMENT PROCEDURES 1. Where difficulties or doubts arise between the Parties regarding the implementation or interpretation of this Agreement, the respective competent authorities shall use their best efforts to resolve the matter by mutual agreement.

  • Court Appearance (a) In the event an Employee is required to appear before a court of law as a member of a jury, as a witness in a criminal matter or as a witness in any matter arising out of the Employee’s employment with the Employer, the Employee shall:

  • CFR PART 200 AND FEDERAL CONTRACT PROVISIONS EXPLANATION TIPS and TIPS Members will sometimes seek to make purchases with federal funds. In accordance with 2 C.F.R. Part 200 of the Uniform Administrative Requirements, Cost Principles, and Audit Requirements for Federal Awards (sometimes referred to as “XXXXX”),Vendor's response to the following questions labeled "2 CFR Part 200 or Federal Provision" will indicate Vendor's willingness and ability to comply with certain requirements which may be applicable to TIPS purchases paid for with federal funds, if accepted by Vendor. Your responses to the following questions labeled "2 CFR Part 200 or Federal Provision" will dictate whether TIPS can list this awarded contract as viable to be considered for a federal fund purchase. Failure to certify all requirements labeled "2 CFR Part 200 or Federal Provision" will mean that your contract is listed as not viable for the receipt of federal funds. However, it will not prevent award. If you do enter into a TIPS Sale when you are accepting federal funds, the contract between you and the TIPS Member will likely require these same certifications.

  • PLEASE READ CAREFULLY I, as applicant or duly authorized representative of the applicant, hereby affirm that the submitted information is true and correct to the best of my knowledge. As such, I have been authorized by the applicant to apply for this permit and have read, understand and agree to comply with all rules concerning the use of the Noblesville Parks and Recreation Auditorium at the Ivy Tech Community College Xxxxxxxx County Campus. The applicant agrees that while renting the park or park premise, the applicant will not exclude anyone from participation in, deny anyone benefits of, or otherwise subject anyone to discrimination because of that person’s race, color, sex, religion, creed, national origin or ancestry, age or handicap. Under this Auditorium Rental Agreement, the applicant assumes all responsibility for proper conduct in the park, including consumption of alcoholic beverages. I , on behalf of the permit applicant, shall agree to release, hold harmless, and forever indemnify the City of Noblesville and Ivy Tech Community College, its employees, officers, and agents from any and all claims or causes of action that may arise from the activities described herein. This includes claims for personal injury, property damage, and/or any other types of claim which may arise from these activities, whether such claims may be brought by the permit applicant or any of its agents, or by any third party. I have read this release and understand all of its terms. I agree with its terms and sign it voluntarily. Signature Date City of Noblesville Parks and Recreation Department 000 Xxxxxx Xxxx Noblesville, Indiana 46060 000-000-0000 000 Xxxxxx Xxxx Xxxxxxxxxxx, XX 00000 OFFICIAL EVENT PERMIT APPLICATION FOR AUDITORIUM City of Noblesville Parks and Recreation Department (NPRD) (Please Print or Type) - Auditorium operating hours are 8:00 a.m. - 10:00 p.m. - Permit applications must be submitted to the Department at least six weeks prior to event. - An application for Special Use shall not become a permit until it has been approved and signed by the Department. Application approval will not be finalized without submittal of an application, certificate of insurance and payment of all fees/charges/deposits. Type of Organization: (check all that apply) □City of Noblesville □Department-Affiliated □Private – City Resident □Xxxxxxxx County □Non-Profit □Private – Non-Resident □Other Tax ID# □Profit Making Please complete entire application: Non-Profit Fundraising Event □Other Tax ID# Date of Application: Date of Proposed Event: Contact Information:

  • Appropriate Safeguards BA shall implement appropriate safeguards to prevent the use or disclosure of Protected Information other than as permitted by the Contract or Addendum, including, but not limited to, administrative, physical and technical safeguards in accordance with the Security Rule, including, but not limited to, 45 C.F.R. Sections 164.308, 164.310, and 164.312. [45 C.F.R. Section 164.504(e)(2)(ii)(B); 45 C.F.R. Section 164.308(b)]. BA shall comply with the policies and procedures and documentation requirements of the Security rule, including, but not limited to, 45 C.F.R. Section 164.316 [42 U.S.C. Section 17931].

  • Disclosure Statement for Xxxx IRAs 1. Am I Eligible to Contribute to a Xxxx XXX? Anyone with compensation income whose Modified Adjusted Gross Income (AGI) does not exceed the limits described below is eligible to contribute to a Xxxx XXX. (For convenience, all future references to compensation are deemed to mean “earned income” in the case of a self- employed individual.) Employers may also contribute to Xxxx IRAs established for the benefit of their employees. You may also establish a Xxxx XXX to receive rollover contributions or transfers from another Xxxx XXX or, in some cases, from a Traditional IRA. A Qualified Rollover Contribution can be made to a Xxxx XXX and is a distribution from an IRA that meets the requirements of section 408(d)(3), a rollover from a designated Xxxx account described in section 402A, or a rollover from an eligible retirement plan as described in section 402(c)(8)(B).

Time is Money Join Law Insider Premium to draft better contracts faster.