Improvements Completion Date definition

Improvements Completion Date. The term "Improvements Completion Date" shall mean the deadline for Completion of each element of the Improvements as set forth on the Approved Construction Schedule.
Sample 1Sample 2
Improvements Completion Date has the meaning set forth in Section 6.1 hereof.
Sample 1Sample 2
Improvements Completion Date means the deadline for completion of each element of construction, development, renovation and rehabilitation of the Improvements as set forth on the Approved Construction Schedule, which shall not be later than October 1, 2004.
Sample 1

Examples of Improvements Completion Date in a sentence

  • Until the Infrastructure Improvements Completion Date, the membership interests in RCP may not be transferred to a third party other than the University of Kansas or Kansas Athletics, Inc.

  • The Parties agree that to the extent, if any, that the City does not receive the sum referred to in Section 12.02(b) above by the thirtieth (30th) day after the Infrastructure Improvements Completion Date, the Infrastructure Payment will be reduced in accordance with Section 11.01.

  • After Closing, if the Recreation Center Contractor or any of its subcontractors damage any of the Infrastructure Improvements or the work in progress related to Infrastructure Improvements of RCP or RCP’s contractor and its subcontractors and materialmen, whether on before or after the Infrastructure Improvements Completion Date, then the City and the Recreation Center Contractor are responsible for such damages.

  • The City acknowledges that except for any express warranties or representations made by RCP in this Agreement or in a document hereafter executed by RCP and delivered to the City, RCP is not now, and on the Infrastructure Improvements Completion Date will not be, making any express or implied representations as to the Infrastructure Improvements and the condition or continuing performance thereof.

  • Further, the Public Improvements Completion Date shall automatically extend for any period of time that the EIR or Project Entitlements are the subject of a legal challenge (a “ Project Entitlement Lawsuit”).

  • If the required Public Improvements are not completed by [Insert Required Public Improvements Completion Date], then all Escrow Account Funds shall be released to the City to assure the appropriate completion of the required Public Improvements.

  • Notwithstanding the foregoing, the Public Improvements Completion Date shall automatically extend to the expiration of any bonds or other security posted by Owner with the City which secures completion of the Public Improvements in accordance with Government Code Section 66499.

  • Tenant further agrees that the Tenant Construction Contract will provide that the Tenant Improvements will be completed by the Tenant Improvements Completion Date and that any and all other agreements pertaining to the construction of the Tenant Improvements will provide for a completion date consistent with such Tenant Improvements Completion Date.

  • Tenant covenants that it shall not cause Tenant Delay with respect to the Leasehold Improvements Completion Date and shall timely respond to any request for approval in accordance with Landlord’s Construction Guidelines, from time to time promulgated.

  • The time period beginning on the Improvements Completion Date and ending on the fifth (5th) anniversary of the Improvements Completion Date; provided that the Operating Period may be extended up to a maximum period of six (6) years from the Improvements Completion Date as provided in Section 2.


More Definitions of Improvements Completion Date

Improvements Completion Date means the date on which the City Engineer certifies in writing that the Authorized Improvements have been constructed in substantial compliance with the approved plans and specifications for such improvements and are ready to be accepted by the City.
Sample 1

Related to Improvements Completion Date

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Final Completion Date means the date on which Final Completion occurs.

  • Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Phase 1 means the phase of the ATP comprised of: (1) improvements to the State Street Substation; (2) construction of the Proposed Line; (3) the rebuilding of NYSEG’s existing Lines 971 and 000 xxxxx xx Xxxxxxxx Xxxx xx the NYSEG ROW to allow for construction of the Proposed Line as intended; (4) improvements to the Elbridge Substation to accept the Proposed Line; and (5) National Grid’s conveyance to NYSEG of the NYSEG Acquired ROW and such other land interests as contemplated by the Purchase and Sale Agreement.

  • Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Tenant Improvements Defined in Exhibit B, if any.

  • Construction Period means the period commencing from the Appointed Date and ending on the date of the Completion Certificate;

  • Construction Work means any work in connection with⎯

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • demolition work means a method to dismantle, wreck, break, pull down or knock down of a structure or part thereof by way of manual labour, machinery, or the use of explosives;

  • Construction Phase means that Phase of the Project which shall commence after the Authority provides the Trade Contractor with written Notice to Proceed with the Construction Phase.

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Construction project means the same as that term is defined in Section 38-1a-102.

  • Construction Plant means appliances, machinery with necessary supply to up keep and maintenance of the works or temporary works but dose not include materials or other things intended to form part of the permanent work.