Commencement Date Delay definition

Commencement Date Delay means only a “force Majeure Delay” or a “Landlord Caused Delay,” as those terms are defined below in this Section 5.1 of this Tenant Work Letter. As used herein, the term “Force Majeure Delay” shall mean only an actual delay resulting from strikes, fire, wind, damage or destruction to the Building, explosion, casualty, flood, hurricane, tornado, the elements, acts of God or the public enemy, terrorist acts, sabotage, war, invasion, insurrection, rebellion, civil unrest, riots, earthquakes or slow-downs or shut downs to the permitting office. As used in this Tenant Work Letter, “Landlord Caused Delay” shall mean actual delays to the extent resulting from the acts or omissions of Landlord including, but not limited to (i) failure of Landlord to timely approve or disapprove any Construction Drawings; (ii) material and unreasonable interference by Landlord, its agents or Landlord Parties (except as otherwise allowed under this Tenant Work Letter) with the Substantial Completion of the Tenant Improvements and which objectively preclude or delay the construction of tenant improvements in the Building or move into the Premises by any person, which interference relates to access by Tenant, or Tenant’s Agents to the Building or any Building facilities (including loading docks and freight elevators) or service (including temporary power and parking areas as provided herein) during normal construction hours, or the use thereof during normal construction hours; (iii) delays due to the acts or failures to act of Landlord or Landlord Parties with respect to payment of the Tenant Improvement Allowance (except as otherwise allowed under this Tenant Work Letter) and/or cessation of work as a result thereof; or (iv) failure to deliver to Tenant sole and exclusive possession of the Premises in the Delivery Condition required by the Lease by September 1, 2015.
Sample 1Sample 2
Commencement Date Delay means only a “Force Majeure Delay” or a “Landlord Delay,” as those terms are defined below in this
Sample 1Sample 2
Commencement Date Delay means only a “Force Majeure Delay” or a “Landlord Caused Delay,” as those terms are defined below in this Section 4.4.1. As used herein, the term “Force Majeure Delay” shall mean only an actual delay resulting from fire, earthquake, strikes, explosion, flood, hurricane, the elements, acts of God or the public enemy, war, invasion, insurrection, rebellion, or riots. As used herein, the term “Landlord Caused Delay” shall mean actual delays to the extent resulting from the acts or omissions of Landlord including, but not limited to (i) failure of Landlord to approve or disapprove any Construction Drawings in the times provided herein; (ii) material interference by Landlord, its agents, employees or contractors (except as otherwise allowed under this Work Letter) with the Substantial Completion of the Improvements in the Premises, and which objectively precludes or delays the construction of tenant improvements in the Building by any person, which interference relates to access by Tenant, or Tenant’s Agents to the Building or any Building facilities (including loading docks and freight elevators) or service (including temporary power and parking areas as provided herein) during normal construction hours, or the use thereof during normal construction hours; and (iii) delays due to the acts or failures to act of Landlord or its agents, employees or contractors with respect to payment of the Improvement Allowance (except as otherwise allowed under this Work Letter).
Sample 1Sample 2

Examples of Commencement Date Delay in a sentence

  • If Tenant contends that a Commencement Date Delay has occurred, Tenant shall notify Landlord in writing of the event which constitutes such Commencement Date Delay, within ten (10) business days after the occurrence of the relevant Commencement Date Delay.

  • The New Term Rent Commencement Date set forth in Section 3 of the Second Amendment shall be extended by the number of days of delay of the “Substantial Completion of the Improvements” (as defined in Section 4.4.3 below) in the Premises to the extent caused by a “Commencement Date Delay” (as defined below), but only to the extent such Commencement Date Delay causes the Substantial Completion of the Improvements in the Premises to occur after the New Term Rent Commencement Date.

  • If such action, inaction or circumstance described in such notice (the “Delay Notice”) is not cured by Landlord within two (2) business days of Landlord’s receipt of the Delay Notice and if such action, inaction or circumstance otherwise qualifies as a Commencement Date Delay, then a Commencement Date Delay shall be deemed to have occurred commencing as of the date of Landlord’s receipt of the Delay Notice and ending as of the date such delay ends.


More Definitions of Commencement Date Delay

Commencement Date Delay means only a “Force Majeure Delay” or a “Landlord Caused Delay,” as those terms are defined below in this Section 5.1. As used herein, the term “Force Majeure Delay” shall mean only an actual delay resulting from fire, earthquake, explosion, flood, hurricane, the elements, acts of God or the public enemy, war, invasion, insurrection, rebellion, riots, industry-wide labor strikes or lockouts (which objectively preclude Tenant from obtaining from any reasonable source of union labor or substitute materials at a reasonable cost necessary for completing the Tenant Improvements), or governmental acts (which do not specifically relate to the construction of the Tenant Improvements and which objectively preclude construction of tenant improvements in the Building by any person). Notwithstanding anything to the contrary contained herein, a Force Majeure Delay shall not include any of the foregoing delays to the extent caused by the negligence or willful misconduct of Tenant, its contractors or agents. As used in this Tenant Work Letter, a “Landlord Caused Delay” shall mean only an actual delay resulting from the failure of Landlord to timely approve or disapprove the Construction Drawings, the Final Space Plan and/or the Approved Working Drawing, and such failure results in an actual delay of the completion of the Tenant Improvements.
Sample 1Sample 2
Commencement Date Delay means only a "Force Majeure Delay" or a "Landlord Caused Delay," as those terms are EXHIBIT D -13-
Sample 1
Commencement Date Delay means only a “Force Majeure Delay” or a “Landlord Caused Delay,” as those terms are defined below in this Section 5.5.1 of this Tenant Work Letter. As used herein, the term “Force Majeure Delay” shall mean only an actual delay resulting from an event of Force Majeure, as that term is defined in Section 29.15 of the Lease. As used in this Tenant Work Letter, “Landlord Caused Delay” shall mean actual delays to the extent resulting from (i) the failure of Landlord to timely approve or disapprove any Construction Drawings; (ii) delays due to the acts or failures to act of Landlord or Landlord Parties with respect to payment of the Tenant Improvement Allowance (except as otherwise allowed under this Tenant Work Letter); (iii) any other act or omission of Landlord or any Landlord Party in violation of the Lease or this Tenant Work Letter which actually delays construction of the Tenant Improvements; or (iv) delays in construction of the Tenant Improvements due to failure of the Base Building to be constructed in accordance with applicable Laws.
Sample 1
Commencement Date Delay shall have the meaning set forth in Exhibit H.
Sample 1

Related to Commencement Date Delay

  • Rent Commencement Date means [Insert date or description] or any later date calculated in accordance with paragraph 3.3 of Part 5 of the Schedule;

  • Commencement Date means the date of this Agreement.

  • Commencement Date of the Contract means the date of signing of the Contract between the Purchaser and the Contractor.

  • Loan Commencement Date means, with respect to each Loan, the first Business Day of the calendar month following the Funding Date of such Loan.

  • Commencement Date or Handover Date means the date on which the Licensed Space of first lot of stations as per Annexure 1 is handed over by DMRC to the Selected Bidder, in accordance with the terms of this agreement.

  • Project Commencement Date means the commencement date notified to the Minister pursuant to clause 4(1);

  • Lease Commencement Date has the meaning specified in Section 3.2 of the Master Lease.

  • Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.

  • Term Commencement Date shall be the later of (i) November 1, 2006 or (ii) the date on which Landlord’s Work is Substantially Complete (or the date on which Landlord’s Work would have been Substantially Complete absent Tenant Delay or Force Majeure (as defined below)); provided, however, that if the Term Commencement Date is not the first day of a calendar month, then the first lease year shall be extended through the last day of the calendar month in which the first 12-month period expires, and Rent for the additional period at the end of the first lease year shall be payable at the rate for the 12th month of the Term. “Force Majeure” means accident; breakage; repair; governmental regulation, moratorium or other governmental action. The “Term Expiration Date” shall be the day immediately preceding the seventh (7th) anniversary of the Term Commencement Date, provided that if such preceding day is not the last day of a calendar month, then the Term Expiration Date shall be the last date of the calendar month in which such preceding day occurs. Landlord and Tenant shall each execute and deliver to the other written acknowledgment of the actual Term Commencement Date and the Term Expiration Date when such are established, and shall attach it to this Lease as Exhibit B. Failure to execute and deliver such acknowledgment, however, shall not affect the Term Commencement Date or Landlord’s or Tenant’s liability hereunder. Failure by Tenant to obtain validation by any medical review board or other similar governmental licensing of the Premises required for the Permitted Use by Tenant shall not serve to extend the Term Commencement Date.

  • Billing Commencement Date means the earlier of:

  • Payment Commencement Date means the date payments of amounts deferred begin pursuant to Article III, Section 6.

  • the commencement date means the date on which the Contract shall take effect, as notified by the Authority to the Contractor in a letter awarding the Contract.

  • Amortization Commencement Date means the date on which an Amortization Event is deemed to occur pursuant to Section 20 hereof.

  • Recommencement Date As defined in Section 6(d) hereof.

  • commencement day means the day on which the State Administrative Tribunal (Conferral of Jurisdiction) Amendment and Repeal Act 2004 Part 2 Division 29 comes into operation;

  • Final Completion Date means the date on which Final Completion occurs.

  • Term Start Date has the meaning set forth in Section 1.01.

  • Interest Commencement Date means the Issue Date of the Notes or such other date as may be specified as the Interest Commencement Date in the relevant Final Terms;

  • Framework Commencement Date means [insert date dd/mm/yyyy];

  • Quarterly Commencement Date means the 1st day of each of April, July, October and January in each year.

  • Scheduled Completion Date shall be the date set forth in Clause 10.3;

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Accumulation Commencement Date means January 1, 2021, or such later date as the Calculation Agent on behalf of the Issuer determines in accordance with Section 2.11 hereof.

  • Pay Out Commencement Date means the date on which a Trust Pay Out Event is deemed to occur pursuant to Section 9.01 of the Agreement or a Series 2001-D Pay Out Event is deemed to occur pursuant to Section 7 hereof.

  • Construction Period means the period commencing from the Appointed Date and ending on the date of the Completion Certificate;

  • Start Date for Term Calculation Purposes Only: Regardless of actual award/effective date of Contract, for Agreement “term” calculation purposes only, the Agreement “start date” is the last day of the month that Award Notifications are anticipated as published in the Solicitation. Example: If the anticipated award date published in the Solicitation is August 27, 2020 but extended negotiations delay award until September 24, 2020 the end date of the resulting initial “two-year” term Agreement, (which is subject to an extension(s)) will still be August 31, 2022 in this example