Schedule Sample Clauses

Schedule. The Work shall be performed as expeditiously as possible in conformity with the schedule requirements contained herein and in the Statement of Work. The draft and final versions of all deliverables shall be submitted by the dates specified in the Exhibit A Schedule and Project Period noted in Item No. 7 of this Agreement. It is understood and agreed that the delivery of the draft and final versions of such deliverables by the Contractor shall occur in a timely manner and in accordance with the requirements of the Exhibit A Schedule.
AutoNDA by SimpleDocs
Schedule. The CONTRACTOR shall commence services on December 1, 2020 and complete all services by November 30, 2021 Reports and other items shall be delivered or completed in accordance with the detailed schedule set forth in Exhibit “A”. This contract may be renewed, for four (4) additional one (1) year periods upon mutual written agreement of the parties at the same prices, terms and conditions. Any change in price, terms or conditions shall be accomplished by written amendment to this contract. Any order issued during the effective date of this contract, but not completed within that period, shall be completed by the CONTRACTOR within the time specified in the order. The contract shall govern the CONTRACTOR and the COUNTY’S rights and obligations with respect to the extent as if the order were completed during the contract’s performance period.
Schedule. The Design Professional shall provide the services required by this Contract in conformance with the approved Preliminary Design and Construction Schedule, to be attached to each Design Order. The Design Professional agrees to complete the Construction Documents not later than 90 calendar days following execution of this Contract, unless otherwise stated in the Design Order. Individual Milestones for completion of construction documents will be mutually agreed by the Owner and Design Professional.
Schedule a. Time is and shall remain of the essence in the performance of this Contract and Seller shall strictly adhere to the schedules specified in this Contract. Failure to deliver in accordance with the Contract schedule, if unexcused, shall constitute a material breach of this Contract. In the event of any anticipated or actual delay, including but not limited to delays attributed to labor disputes, Seller shall: (i) promptly notify Buyer in writing of the reasons for the delay and the actions being taken to overcome or minimize the delay; (ii) provide Buyer with a written recovery schedule; and (iii), if requested by Buyer, ship via air or expedited routing, at no additional cost to Buyer, to avoid or minimize delay to the maximum extent possible.
Schedule. The components of the project described in the Scope of Services shall be completed according to Term, above.
Schedule. The Services will be undertaken in a manner that ensures the Project is completed timely and efficiently in accordance with the Project.
Schedule. The Review Board shall assume control of the arbitration process and shall schedule all events as expeditiously as possible. The Arbitration Hearing shall commence within ninety (90) Business Days after receipt of the Notice of Dispute by the Arbitration Administrator.
AutoNDA by SimpleDocs
Schedule. CONSULTANT shall adhere to the schedule set forth in Exhibit A; provided, that CITY shall grant reasonable extensions of time for the performance of such services occasioned by governmental reviews of CONSULTANT’s work product or other unavoidable delays; provided, further, that such unavoidable delay shall not include strikes, lockouts, work stoppages, or other labor disturbances conducted by, or on behalf of, CONSULTANT’s officers or employees. CONSULTANT acknowledges the importance to CITY of CITY’s Project schedule and agrees to put forth its best professional efforts to perform its services under this Agreement in a manner consistent with that schedule.
Schedule. The schedule for design and development of the Tenant Improvements, including the time periods for preparation and review of construction documents, approvals and performance, shall be in accordance with a schedule to be prepared by Tenant (the "Schedule"). Tenant shall prepare the Schedule so that it is a reasonable schedule for the completion of the Tenant Improvements. The Schedule shall clearly identify all activities requiring Landlord participation. As soon as the Schedule is completed, Tenant shall deliver the same to Landlord for Landlord's approval, which approval shall not be unreasonably withheld, conditioned or delayed. Such Schedule shall be approved or disapproved by Landlord within ten (10) business days after delivery to Landlord. Landlord's failure to respond within such ten (10) business day period shall be deemed approval by Landlord. If Landlord disapproves the Schedule, then Landlord shall notify Tenant in writing of its objections to such Schedule, and the parties shall confer and negotiate in good faith to reach agreement on the Schedule. The Schedule shall be subject to adjustment as mutually agreed upon in writing by the parties, or as provided in this Work Letter.
Time is Money Join Law Insider Premium to draft better contracts faster.