Performance of the Work. The Contractor shall perform all of the Work required for the complete and prompt execution of everything described or shown in, or reasonably implied from the Contract Documents for the above referenced Project.
Performance of the Work. The Contractor shall carefully study the approved Construction Documents and shall plan its schedule of operations well ahead of time. If at any time it is discovered that work is being done which is not in accordance with the approved Construction Documents, the Contractor shall correct the Work immediately.
Performance of the Work a. Grantee shall complete the Project [make sure defined] and provide the deliverables (the “Deliverables”) described in the Scope of Work set forth in Attachment 1 (the “Scope of Work”).
Performance of the Work. In addition to those matters elsewhere expressly made the responsibility of the CONTRACTOR, the CONTRACTOR shall have the full and direct responsibility for the performance and completion of the Work under this Contract and for any act or neglect of the CONTRACTOR, his agents, employees or subcontractors. He shall bear all losses, if any, resulting on account of the amount and character of the Work, or because the conditions under which the work must be done are different from what were estimated or anticipated by him, or because of weather, floods, elements or other causes.
Performance of the Work. With the exclusion of all Enabling Work which is performed pursuant to the Enabling Work Agreement, StadCo shall not do or permit others to do any Project Improvements Work unless and until (i) StadCo shall have first procured and paid for applicable permits, licenses, and approvals then required under Applicable Law to commence the specific work being performed and (ii) StadCo has complied with the Insurance Covenants. All such Project Improvements Work shall be (i) prosecuted with reasonable diligence and completed with all reasonable dispatch, subject to Force Majeure; (ii) constructed and performed in a good and workmanlike manner in accordance with standard construction practices for construction, repair, renewal, renovation, demolition, rebuilding, addition or alteration, as the case may be, of improvements similar to the Project Improvements; (iii) constructed and performed using qualified workers and subcontractors; (iv) constructed and performed in accordance with Applicable Laws and the terms of this Agreement; and (v) subject to Section 7.14 below, free of any Liens other than any Leasehold Mortgage permitted pursuant to the terms of the Stadium Lease. StadCo shall take all reasonably necessary measures and precautions to minimize damage, disruption or inconvenience caused by such work and make adequate provisions for the safety and convenience of all Persons affected thereby, in each case in the manner as a Reasonable and Prudent Developer would undertake in light of the particular circumstances. Except as expressly provided in this Agreement, StadCo shall be responsible for all costs incurred in connection with the Project Improvements Work, including any costs, charges, and fees in connection with supplying the Project Improvements with all necessary utilities, all costs, charges, and fees payable to any Governmental Authority in connection with the Project Improvements Work (including all building permits, platting, and zoning fees and street closure fees or any other license, permit or approval under Applicable Laws), title insurance costs associated with leasehold and mortgagee title insurance obtained by StadCo and all other site preparation costs, fees or expenses incurred in connection with the Land or the design, development, construction, furnishing, and opening of the Project Improvements. Dust, noise, traffic, hazards, and other effects of such work shall be controlled in such manner as a Reasonable and Prudent Developer would under...
Performance of the Work. As a primary inducement for us to enter into this Agreement, you agree to perform the work listed on Attachment C (the "Work") in strict accordance with our specifications.
Performance of the Work. Design-Builder represents that the Work shall be planned, organized and executed in accordance with the Project Schedule to achieve the Guaranteed Completion Date(s). Should Owner have a reasonable belief that the Project Schedule or Guaranteed Completion Date(s) will not be met for causes that do not constitute an Excusable Delay, Owner has the right, but not the obligation, to so notify Design-Builder, and Design- Builder shall then work additional overtime, engage additional personnel and take such other measures as necessary to complete the Work within the Project Schedule and by the Guaranteed Completion Date(s). Design-Builder shall bear all costs related to such overtime, additional personnel, and other measures.
Performance of the Work. (a) Contractor agrees to use, and agrees that it shall require each of its Subcontractors to use, only personnel who are qualified and properly trained and who possess every license, permit, registration, certificate or other approval required by Applicable Law or any Governmental Authority to enable such Persons to perform their Work involving any part of Contractor’s obligations under this Agreement.
Performance of the Work. Contractor shall, at its sole cost and expense, provide, perform, and complete all of the following, all of which is herein referred to as the “Work”:
Performance of the Work. Except as provided in subparagraphs 7(A) and 7(D), NAI must, using its best skill and judgment and in an expeditious and economical manner not inconsistent with the interests of BNPPLC, perform or cause to be performed all work required, and must provide or cause to be provided all supplies and materials required, to design and complete construction of the Construction Project (collectively, the “Work”) no later than the Target Completion Date. The Work will include obtaining all necessary building permits and other governmental approvals required in connection with the design and construction of the Construction Project, or required in connection with the use and occupancy thereof (e.g., certificates of occupancy). The Work will also include any repairs or restoration required because of damage to Improvements by fire or other casualty prior to the Completion Date (a “Pre-lease Casualty”); provided, however, the cost of any such repairs or restoration will be subject to reimbursement not only through Construction Advances made to NAI on and subject to the terms and conditions of this Agreement, but also through the application of Escrowed Proceeds as provided in Paragraph 5; and, provided further, like other Work, any such repairs and restoration to be provided by NAI will be subject to subparagraphs 7(A) and 7(B), which establish certain rights of NAI to suspend or discontinue any Work. NAI will carefully schedule and supervise all Work, will check all materials and services used in connection with all Work and will keep full and detailed accounts as may be necessary to document expenditures made or expenses incurred for the Work.
