Peaceful Resolution of All Disputes Sample Clauses

Peaceful Resolution of All Disputes. In recognition of the special needs of the Project and to maintain a spirit of harmony, labor-management peace and stability during the term of this Community Workforce Agreement, the parties agree to establish effective and binding methods for the settlement of all misunderstandings, disputes and grievances; and in recognition of such methods and procedures, the unions agree not to engage in any strike, slowdowns or interruptions or disruption of Project Work, and the contractors agree not to engage in any lockout, or any other action impairing or impeding the Project Work.
Sample 1Sample 2Sample 3See All (14)
AutoNDA by SimpleDocs
Peaceful Resolution of All Disputes. In recognition of the special needs of the Project Work and to maintain a spirit of harmony, labor-management peace and stability during the term of the PLA, the parties agree to establish effective and binding methods for the settlement of all misunderstandings, disputes and grievances; and in recognition of such methods and procedures, the Unions agree not to engage in any strike, slowdowns, or interruption or disruption of Project Work, and the Contractors agree not to engage in any lockout.
Sample 1Sample 2See All (4)
Peaceful Resolution of All Disputes. In recognition of the special needs of the Project and to maintain a spirit of harmony, labor-management, peace and stability during the term of this CSWPA, the Parties agree to establish effective and binding methods for the settlement of all misunderstandings, disputes and grievances; and in recognition of such methods and procedures, the Unions agree not to engage in any strike, slowdowns or interruptions, pickets, or disruption of Project Work, and the Contractors agree not to engage in any lockout.
Sample 1Sample 2
Peaceful Resolution of All Disputes. In recognition of the special needs of the Project and to maintain a spirit of harmony, labor-management peace and stability during the term of the Agreement, the parties agree to establish effective and binding methods for the settlement of all misunderstandings, disputes and grievances; and in recognition of such methods and procedures, the Unions agree not to engage in any strike, slowdowns, or interruption or disruption of Project Work, and the Contractors agree not to engage in any lockout. The parties understand that the Agreement and such dispute resolution procedures must include all Building Trade Unions with traditional jurisdiction over the Project Work.
Sample 1

Related to Peaceful Resolution of All Disputes

  • Resolution of disputes and grievances (a) For the purpose of this clause 14, a dispute includes a grievance.

  • Legal Disputes 3.1 Pursuant to New York City Health and Hospitals Corporation Act, Chapter 1016-69, Section 20, all actions against NYC Health + Hospitals shall be brought in the City , in the county in which the cause of action arose, or if it arose outside of the City , in the City , County of New York. The Parties consent to the dismissal or transfer to any claims asserted inconsistent with this section. If Vendor initiates any action in breach of this section, Vendor shall promptly reimburse NYC Health + Hospitals for any attorneys’ fees incurred to remove the action to the contractually agreed upon venue.

  • Resolution of Grievances In the event of a grievance related to a matter of discipline or any dispute as to the interpretation, application or observance of the provisions of this Agreement other than discipline, it shall be handled in the following manner:

  • Informal Resolution of Disputes 10.5.1 Upon receipt by one Party of notice of a dispute by the other Party pursuant to Section 10.3 or Section 10.4.5, each Party will appoint a knowledgeable, responsible representative to meet and negotiate in good faith to resolve any dispute arising under this Agreement. The location, form, frequency, duration, and conclusion of these discussions will be left to the discretion of the representatives. Upon agreement, the representatives may utilize other alternative Dispute Resolution procedures such as mediation to assist in the negotiations. Discussions and the correspondence among the representatives for purposes of settlement are exempt from discovery and production and will not be admissible in the arbitration described below or in any lawsuit without the concurrence of both Parties. Documents identified in or provided with such communications that were not prepared for purposes of the negotiations are not so exempted, and, if otherwise admissible, may be admitted in evidence in the arbitration or lawsuit.

  • Disputes Resolution 10:01 Jurisdictional disputes involving workers employed under this Collective Agreement shall henceforth be resolved under the provisions of the Canadian Jurisdictional Disputes Plan in accordance with its rules and regulations and without work stoppage, slow down or other lack of production, and it is further agreed that a jurisdictional dispute shall in no way interfere with the progress or prosecution of work.

  • Resolution of Disputes Any dispute or disagreement which may arise under, or as a result of, or in any way related to, the interpretation, construction or application of this Agreement shall be determined by the Committee. Any determination made hereunder shall be final, binding and conclusive on the Grantee and the Company for all purposes.

  • Agreement Made in California; Venue The formation, interpretation and performance of this Agreement shall be governed by the laws of the State of California. Venue for all litigation relative to the formation, interpretation and performance of this Agreement shall be in San Francisco.

  • Contract Disputes The Parties shall deal in good faith and attempt to resolve potential disputes informally. If the dispute concerning a question of fact arising under the terms of this Contract is not disposed of in a reasonable period of time by the Contractor’s Supervisor and the County‘s project manager as specified in Article 25. Notices by way of the following process, such matter shall be brought to the attention of the County DPA by way of the following process:

  • Governing Law; Disputes This Agreement shall in accordance with Section 5-1401 of the General Obligations Law of New York in all respects be construed, governed, applied and enforced under the internal laws of the State of New York without giving effect to the principles of conflicts of laws and be deemed to be an agreement entered into in the State of New York and made pursuant to the laws of the State of New York. Except as otherwise set forth in Article “19” of this Agreement, the parties agree that they shall be deemed to have agreed to binding arbitration with respect to the entire subject matter of any and all disputes relating to or arising under this Agreement including, but not limited to, the specific matters or disputes as to which arbitration has been expressly provided for by other provisions of this Agreement and that any such arbitration shall be commenced exclusively in New York, New York. Any such arbitration shall be by a panel of three arbitrators and pursuant to the commercial rules then existing of the American Arbitration Association in the State of New York, County of New York. In all arbitrations, judgment upon the arbitration award may be entered in any court having jurisdiction. The parties specifically designate the courts in the City of New York, State of New York as properly having jurisdiction for any proceeding to confirm and enter judgment upon any such arbitration award. The parties hereby consent to and submit to the exclusive jurisdiction of the courts of the State of New York in any action or proceeding and submit to personal jurisdiction over each of them by such courts. The parties hereby waive personal service of any and all process and specifically consent that in any such action or proceeding brought in the courts of the State of New York, any service of process may be effectuated upon any of them by certified mail, return receipt requested, in accordance with Paragraph “C” of this Article “21” of this Agreement. Nothing contained herein shall be deemed to limit in any way any right to serve process in any manner permitted by law. The parties agree, further, that the prevailing party in any such arbitration as determined by the arbitrators shall be entitled to such costs and attorney's fees, if any, in connection with such arbitration as may be awarded by the arbitrators. In connection with the arbitrators’ determination for the purpose of which party, if any, is the prevailing party, they shall take into account all of the factors and circumstances including, without limitation, the relief sought, and by whom, and the relief, if any, awarded, and to whom. In addition, and notwithstanding the foregoing sentence, a party shall not be deemed to be the prevailing party in a claim seeking monetary damages, unless the amount of the arbitration award exceeds the amount offered in a legally binding writing by the other party by fifteen (15%) percent or more. For example, if the party initiating arbitration (“A”) seeks an award of one hundred thousand ($100,000) dollars plus costs and expenses, the other party (“B”) has offered A fifty thousand ($50,000) dollars in a legally binding written offer prior to the commencement of the arbitration proceeding, and the arbitration panel awards any amount less than fifty-seven thousand five hundred ($57,500) dollars to A, the panel should determine that B has “prevailed”. The arbitration panel shall have no power to award non-monetary or equitable relief of any sort. It shall also have no power to award (i) damages inconsistent with any applicable agreement between the parties or (ii) punitive damages or any other damages not measured by the prevailing party’s actual damages; and the parties expressly waive their right to obtain such damages in arbitration or in any other forum. In no event, even if any other portion of these provisions is held invalid or unenforceable, shall the arbitration panel have power to make an award or impose a remedy which could not be made or imposed by a court deciding the matter in the same jurisdiction. Discovery shall be permitted in connection with the arbitration only to the extent, if any, expressly authorized by the arbitration panel upon a showing of substantial need by the party seeking discovery. All aspects of the arbitration shall be treated as confidential. The parties and the arbitration panel may disclose the existence, content or results of the arbitration only as provided in the rules of the American Arbitration Association in New York, New York. Before making any such disclosure, a party shall give written notice to all other parties and shall afford such parties a reasonable opportunity to protect their interest.

  • LAW APPLICABLE AND COMPETENT COURT 6.1 The Agreement is governed by [insert the national law of the NA].

Time is Money Join Law Insider Premium to draft better contracts faster.