Safety and Security Contractor is responsible for maintaining safety in the performance of this Contract. Contractor shall be responsible for complying with the District’s rules and regulations pertaining to safety, security, and driving on school grounds, particularly when children are present.
Health, Safety and Security 22.2.1 The University and the Association agree to promote safe, secure and healthy working conditions and procedures, and to encourage Members to adopt and follow sound health, safety and security procedures in the performance of their work.
Safety and Security Procedures Contractor shall maintain and enforce, at the Contractor Work Locations, industry-standard safety and physical security policies and procedures. While at each Court Work Location, Contractor shall comply with the safety and security policies and procedures in effect at such Court Work Location.
DATA HANDLING AND SECURITY It will always be the responsibility of the selected Contractor to manage data transfer and to secure all data appropriately during the project to prevent unauthorized access to all data, products, and deliverables.
Data Protection and Security A. In this Agreement the following terms shall have the meanings respectively ascribed to them:
Privacy and Security (a) The Service Provider shall not transmit or store any AHS data outside the borders of Canada, nor transmit any AHS data in Canada to any party not specifically contemplated in this Agreement, without AHS’s prior written consent to each such data transmittal, which consent may be arbitrarily and unreasonably withheld.
Data and Security If Contractor is granted access to Court Data, Confidential Information or Court Work Locations in the performance of the Work;
ENVIRONMENT, SAFETY AND HEALTH PROTECTION (a) Seller shall perform this Agreement in a manner that ensures adequate protection for workers, the public, and the environment, and shall be accountable for actions of itself and its lower-tier subcontractors, agents and employees. Seller shall exercise a degree of care commensurate with the work and the associated hazards. Seller shall ensure that management of environment, safety and health (ES&H) functions and activities is an integral and visible part of Seller’s work planning and execution process. In the event that Xxxxxx fails to comply with this Agreement, Company may, without prejudice to any other legal or contractual rights, issue an order stopping all or any part of the work; thereafter a start order for resumption of work may be issued at Company’s discretion. Seller shall make no claim for an extension of time or for compensation or damages by reason of or in connection with such work stoppage. In addition, Company may require, in writing, that Seller remove from the work any employee the Company deems unsafe, incompetent, careless, or otherwise objectionable.
Pupil Safety and Fingerprinting CONTRACTOR shall comply with all provisions of the Education Code which protect the safety of any pupil that may come in contact with employees of the CONTRACTOR. Pursuant to Education Code section 45125.1, CONTRACTOR shall conduct criminal background checks of ALL employees of CONTRACTOR assigned to the PROJECT site, and shall certify that no employees who have been convicted of serious or violent felonies, as specified in Education Code Section 45125.1, will have contact with pupils, by utilizing the General Certification Regarding Background Checks Form. As part of such certification, CONTRACTOR must provide the District with a list of all employees providing services pursuant to this Agreement, and designate which sites such employees will be assigned. In performing the services set forth in this Agreement, CONTRACTOR shall not utilize any employees who are not included on the above-referenced list. At District’s sole discretion, District may make a finding, as authorized under Education Code section 45125.1, that CONTRACTOR’s employees will have only “limited contact” with pupils. In accordance with Education Code Section 45125.2, a CONTRACTOR performing construction, reconstruction, rehabilitation or repair services to a school facility shall not be required to perform Section 45125.1 background checks of all employees assigned to the PROJECT site if such CONTRACTOR installs a physical barrier at the worksite to limit employee contact with pupils and/or provides continual supervision and monitoring of all employees of the CONTRACTOR by an employee of the CONTRACTOR whom the Department of Justice has ascertained has not been convicted of a violent or serious felony. Such CONTRACTOR shall certify to the District its compliance with one of the aforementioned alternatives under Education Code Section 45125.2 pertaining to pupil safety with the form entitled CONSTRUCTION CONTRACTOR CERTIFICATION REGARDING BACKGROUND CHECKS which is on file at the Administrative Office of the DISTRICT. Contractor’s failure to comply with the law or Article VI, Paragraph 4 of this Agreement shall be considered a material breach of this Agreement upon where this Agreement may be terminated, at District’s sole discretion, without any further compensation to Contractor.
SAFETY AND HEALTH 20.1 The Employer, employee and Union have a significant responsibility for workplace safety and health.
