Consent Withheld Sample Clauses

Consent Withheld. If the Material Project Contractor withholds its consent to a Proposed Transfer Notice, the Authority may give one or more subsequent Proposed Transfer Notices, pursuant to the provisions of Section 4.1, containing changed particulars relating to the same Proposed Substitute or particulars relating to another Proposed Substitute which the Authority reasonably believes would fulfil the requirements of Sections 4.3, provided that only one Proposed Transfer Notice may be outstanding at any one time, and provided further that:
Sample 1Sample 2Sample 3See All (14)
AutoNDA by SimpleDocs
Consent Withheld. If the Material Project Contractor withholds its consent to a Proposed Novation Notice, the Authority may give one or more subsequent Proposed Novation Notices, pursuant to the provisions of Section 4.1, containing changed particulars relating to the same Proposed Substitute or particulars relating to another Proposed Substitute which the Authority reasonably believes would fulfil the requirements of Sections 4.3, provided that only one Proposed Novation Notice may be outstanding at any one time, and provided further that:
Sample 1Sample 2Sample 3See All (4)
Consent Withheld. If the Material Contract Party withholds its consent to a Proposed Transfer Notice, BC Hydro may give one or more subsequent Proposed Transfer Notices, pursuant to the provisions of Section 4.1, containing changed particulars relating to the same Proposed Substitute or particulars relating to another Proposed Substitute which BC Hydro reasonably believes would fulfil the requirements of Sections 4.3, provided that only one Proposed Transfer Notice may be outstanding at any one time, and provided further that:
Sample 1
Consent Withheld. If the Project Contractor withholds its consent to a Proposed Transfer Notice, the City may give one or more subsequent Proposed Transfer Notices, pursuant to the provisions of Section 4.1 [Proposed Substitute], containing changed particulars relating to the same Proposed Substitute or particulars relating to another Proposed Substitute which the City reasonably believes would fulfil the requirements of Section 4.3 [Grant of Consent], provided that only one Proposed Transfer Notice may be outstanding at any one time, and provided further that:
Sample 1
Consent Withheld. If the Design-Builder withholds its consent to a Proposed Transfer Notice, the Owner may give one or more subsequent Proposed Transfer Notices, pursuant to the provisions of Section 4.1, containing changed particulars relating to the same Proposed Substitute or particulars relating to another Proposed Substitute which the Owner reasonably believes would fulfil the requirements of Sections 4.3, provided that only one Proposed Transfer Notice may be outstanding at any one time, and provided further that:
Sample 1
Consent Withheld. County will not unreasonably withhold consent to proposed Alterations; provided, however, it will be reasonable for County to withhold consent if the Alterations, in the County’s judgment:
Sample 1
Consent Withheld. If the Material Contract Party withholds its consent to a Proposed Transfer Notice, the Authority may give one or more subsequent Proposed Transfer Notices, pursuant to the provisions of Section 4.1, containing changed particulars relating to the same Proposed Substitute or particulars relating to another Proposed Substitute which the Authority reasonably believes would fulfil the requirements of Sections 4.3, provided that only one Proposed Transfer Notice may be outstanding at any one time, and provided further that:
Sample 1
AutoNDA by SimpleDocs
Consent Withheld. If the Material Contract Party withholds its consent to a Proposed Transfer Notice, the Province may give one or more subsequent Proposed Transfer Notices, pursuant to the provisions of
Sample 1

Related to Consent Withheld

  • PAYMENT WITHHELD The OWNER may withhold all or part of any payment otherwise due the Contractor if any one of the following conditions exist:

  • No Assignment without Consent This Charter shall not be assigned by either party without mutual written consent.

  • Consent Except as otherwise provided herein, when the consent of a party is required herein, such consent shall not be unreasonably withheld or delayed.

  • Consent to Assignment The Assignor hereby irrevocably assigns the Agreement in all respects to the Assignee and the Assignee accepts the assignment thereof in all respects.

  • Assignment with Prior Consent Except as provided in Section 12.2 to this Appendix 2, no Interconnection Party shall assign its rights or delegate its duties, or any part of such rights or duties, under the Interconnection Service Agreement without the written consent of the other Interconnection Parties, which consent shall not be unreasonably withheld, conditioned, or delayed. Any such assignment or delegation made without such written consent shall be null and void. An Interconnection Party may make an assignment in connection with the sale, merger, or transfer of a substantial portion or all of its properties including the Interconnection Facilities which it owns, so long as the assignee in such a sale, merger, or transfer assumes in writing all rights, duties and obligations arising under this Interconnection Service Agreement. In addition, the Interconnected Transmission Owner shall be entitled, subject to Applicable Laws and Regulations, to assign the Interconnection Service Agreement to any Affiliate or successor that owns and operates all or a substantial portion of the Interconnected Transmission Owner’s transmission facilities.

  • Withdrawing Consent If you would like to withdraw your consent, you can tell us at any time by emailing xxxx@xxxxxxxxx.xxx.. Once you do withdraw your consent, we will no longer send you paper copies of any Legal Disclosure.

  • Payments Withheld 9.6.1 The Architect may decline to certify payment and may withhold his or her Certificate in whole or in part, to the extent necessary reasonably to protect the State, if in the Architect’s opinion he or she is unable to make representations to the State as provided in Subparagraph

  • How to Withdraw Consent If you have registered for the Service and you wish to withdraw your consent to have Communications provided in electronic form, you must cancel any pending transfer requests (within the time period permitted by the Service cancellation policies) and stop using the Service. There are no fees to cancel a pending transfer request (as long as such cancellation is made within the time period permitted by the Service cancellation policies).

  • Consent to Transfer (1) If the Land sold is leasehold, this contract is subject to any necessary consent to the transfer of the lease to the Buyer being obtained by the Settlement Date.

  • Settlement without Consent if Failure to Reimburse If at any time an indemnified party shall have requested an indemnifying party to reimburse the indemnified party for fees and expenses of counsel, such indemnifying party agrees that it shall be liable for any settlement of the nature contemplated by Section 6(a)(ii) effected without its written consent if (i) such settlement is entered into more than 45 days after receipt by such indemnifying party of the aforesaid request, (ii) such indemnifying party shall have received notice of the terms of such settlement at least 30 days prior to such settlement being entered into and (iii) such indemnifying party shall not have reimbursed such indemnified party in accordance with such request prior to the date of such settlement.

Time is Money Join Law Insider Premium to draft better contracts faster.