Warranty Period /„Maintenance Period‟ shall mean the period during which the Contractor shall remain liable for repair or replacement of any defective part of the Works performed under the Contract.
Customer Premises Equipment or "CPE" means equipment employed on the premises of a Person other than a Carrier to originate, route or terminate Telecommunications (e.g., a telephone, PBX, modem pool, etc.).
Software Update means a package used to upgrade software to a new version including a change of the configuration parameters.
Product Warranty has the meaning set forth in Section 9.3.
Software Updates means the Software releases, service packs, build updates or emergency fixes released from time to time in accordance with the Vocera’s update policy for such Software.
Original component manufacturer means an organization that designs and/or engineers a part and is entitled to any intellectual property rights to that part.
Supplier Software means software which is proprietary to the Supplier and software which is or will be used by the Supplier for the purposes of providing the Services;
Application Software means Software formulated to perform specific business or technical functions and interface with the business or technical users of the System and is identified as such in Appendix4 of the Contract Agreement and such other Software as the parties may agree in writing to be Application Software.
Software Upgrade means a release of Software, in object code form, or firmware, which adds new functionality and feature enhancements to the Software or Equipment.
Manufacturer’s Warranty means the warranty supplied from time to time by the manufacturer of the Goods as at the date of the acceptance of the Statement of Work; “PPSA” means the Personal Property Securities Xxx 0000; “Price” means the amount specified within each Statement of Work (subject to any Variation) or as otherwise specified from the Company to the Customer representing the cost for the Works; “Related Work” means any additional building, carpentry, painting, plastering, plumbing or other work or other trades that the Customer requires, which are not to be carried out by the Company; “Services” means the services provided by the Company to the Customer as part of the Works, which may include without limitation the installation of Goods; “Services Delay Charge” means the services delay charge (if any) set out in the Statement of Work; “Services Interruption Event” means any interruption to a Works caused by; a Force Majeure Event, the Customer’s failure to carry out or perform any obligation required of it under this agreement which in the sole opinion of the Company does or may cause a delay in the Works and any other matter which in the reasonable opinion of the Company will cause an interruption or delay in the performance of the Works; “Statement of Work” means the details outlining the provision of the Works, which statement can be delivered verbally or in writing (including email) and may include (where applicable) an estimate or quotation (as specifically expressed as the case) of costs; “Variation” means a change in the Statement of Work including the specifications, scope, time of supply, price or scale of the Works and such variation shall form part of this agreement; “Workmanship” means a good and high quality and standard of delivery in connection with the Services performed; “Works” means the supply of Goods and the provision of Services to the Customer as per each Statement of Work;
Engine Manufacturer means CFM International, Inc.
Extended Warranty means an agreement for a specified duration to
Non-Conforming Product means a Product that does not conform to the Supplier’s Warranties.
Original equipment manufacturer means a company that manufactures products that it has designed from purchased components and sells those products under the company's brand name.
Product Schedule means PTC’s standard order form entitled “PTC Product Schedule” (including all schedules, attachments and other document(s) specifically referenced therein) or such alternative order form as may be submitted by Customer and accepted by PTC, in each case that specifies (i) the Licensed Products and/or Services ordered; and (ii) for Licensed Products, the installation address (including the Designated Country) and the Licence Term.
Excluded Downtime has the meaning set forth in Section 2 below.
Satellite Manufacturer means, with respect to any Satellite, the prime contractor and manufacturer of such Satellite.
Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.
Original manufacturer means the original component manufacturer, the original equipment manufacturer, or the contract manufacturer.
Excusable Delays means delays due to acts of terrorism, acts of war or civil insurrection, strikes, riots, floods, earthquakes, fires, tornadoes, casualties, acts of God, labor disputes, governmental restrictions or priorities, embargoes, national or regional material shortages, failure to obtain regulatory approval from any Federal or State regulatory body, unforeseen site conditions, material litigation by parties other than the Parties not caused by the Parties’ failure to perform, or any other condition or circumstances beyond the reasonable or foreseeable control of the applicable party using reasonable diligence to overcome which prevents such party from performing its specific duties or obligation hereunder in a timely manner.
Supplier System means the information and communications technology system used by the Supplier in performing the Services including the Software, the Equipment and related cabling (but excluding the Customer System);
Supply Period means for a Supply Point, the period beginning on the Start Date and ending on the Termination Date;