Time for Performance definition

Time for Performance means the time for completing the Works or a Section (as the case may be) under Clause 9 (with any extension under Clause 13, calculated from the Commencement Date.
Sample 1
Time for Performance means, in relation to a contract of any description mentioned in subsection (1) above, the time for performance by the air travel organiser of any of his obligations under the contract with respect to the provision of any services, accommodation or facilities; and
Sample 1
Time for Performance means the completion schedule defined in Section 5. “Unavoidable Delays” means any delay in the Project caused by: (a) economic, industry-wide strikes, (b) fire, (c) unusual delays in transportation, (d) acts of God, (e) acts of the public enemy, (f) floods, (g) rebellions, riots, insurrections or sabotage, (h) unusually adverse weather conditions, (i) arbitrary suspension, stoppage, or interruption of the Project by Owner, or (j) approved Change Orders.
Sample 1

Examples of Time for Performance in a sentence

  • Subparagraphs (d) to (f) apply only if services are performed under this contract.(2) Adjustments of Price or Time for Performance.

  • Adjustments of Price or Time for Performance: If any such change increases or decreases the Contractor's cost of, or the time required for, performance of any part of the work under this contract, whether or not changed by the order, an adjustment shall be made in the contract price, the delivery schedule, or both, and the contract modified in writing accordingly.

  • Time for Performance Consultant shall perform the Work as expeditiously as is consistent with professional skill and the orderly progress of the Work, and in accordance with any schedule set forth in the attached Scope of Work.

  • An extension of the Time for Performance in an amount equal to the time loss due to such delay(s) will be the Contractor's sole and exclusive remedy for such delay(s).

  • Time for Performance of the relative obligation suspended by the event of force majeure shall stand extended by the period for which such clause lasts.

  • Time for Performance The Contractor agrees to perform the Work diligently at all times and within any timelines or schedule specified in Schedule A – Scope of Work.

  • If any materials or equipment are damaged by the negligence or willful misconduct of an employee, agent or invitee of Customer, Customer shall repair or replace said item within a reasonable period of time, or, adjust the Contract Price to pay for repair or replacement or adjust Time for Performance and Final Completion, or both.

  • Subparagraphs(d) to (f) apply only if services are performed under this contract.(2) Adjustments of Price or Time for Performance.

  • Except as specifically provided herein, nothing in this Order shall impact or alter the Court’s Corrected Order Granting in Part Debtors’ Emergency Motion for Entry of Order Extending Time for Performance of Obligations Arising Under Unexpired Real Property Leases and Establishing Temporary Procedures (ECF No. 157).

  • If the Customer concurs with the need, cost estimate, and time delay, Customer and ESCO shall make an equitable adjustment in the Contract Price or Time for Performance and Final Completion, or both.

Related to Time for Performance

  • human performance means human capabilities and limitations which have an impact on the safety and efficiency of aeronautical operations;

  • Index Performance means, in relation to an Index and an Auto-Call Valuation Date or the Valuation Date, as the case may be, a percentage calculated by the Calculation Agent in respect of such date in accordance with the following formula: Index Performance =Final Index Level × 100% Initial Index Level

  • Control Performance Standard or “CPS” shall mean the reliability standard that sets the limits of a Balancing Authority’s Area Control Error over a specified time period.

  • Underlying Performance means in relation to the Valuation Date a decimal number calculated by applying the following formula: UP =Underlying FINAL Underlying INITIAL where: UP = Underlying Performance with respect to the Valuation Date UnderlyingFINAL UnderlyingINITIAL= Reference Price of the Underlying with respect to the Valuation Date = Initial Price of the Underlying

  • Total Performance means that the entire Work, except those items arising from the provisions of any warranty, have been performed in accordance with the Contract;

  • Extreme performance coating means coatings designed for harsh exposure or extreme environmental conditions.

  • Substantial Performance means the stage of completion when:(a) all Work, as certified by the Contract Administrator, is capable of completion or correction at a cost of not more than:

  • Basket Performance means a decimal number calculated by applying the following formula: BP = ∑ W ×iX ⎛⎜⎜i=1 ⎝ Underlyingi,FINAL ⎞⎟⎠Underlyingi,INITIAL ⎟ where: BP = Basket Performance X = 8 Wi = Weighting of the relevant Underlying Underlying i,FINAL Underlying i,INITIAL= Arithmetic mean of the Reference Prices of the relevant Underlying with respect to all Averaging Dates = Initial Price of the relevant Underlying

  • Annual performance report means a written appraisal of the teaching staff member's performance prepared by the teaching staff member’s designated supervisor based on the evaluation rubric for his or her position.

  • Sexually explicit performance means a live or public act or show intended to arouse or satisfy the sexual desires or appeal to the prurient interest of patrons.

  • Performance Standards or “PS” shall mean the cleanup levels and other measures of achievement of the remedial action objectives, as set forth in the ROD.

  • Energy Performance Score means the numeric rating generated by Portfolio Manager that compares the Energy usage of the building to that of similar buildings.

  • Performance Standard means the acceptable range of performance for a Performance Indicator or a Service Volume that results when a Performance Corridor is applied to a Performance Target.

  • Key Performance Indicators or “KPIs” means the performance measurements and targets set out in Part 3 of Schedule 1 (Services) of this Framework Agreement;

  • energy performance contracting means a contractual arrangement between the beneficiary and the provider of an energy efficiency improvement measure, verified and monitored during the whole term of the contract, where investments (work, supply or service) in that measure are paid for in relation to a contractually agreed level of energy efficiency improvement or other agreed energy performance criterion, such as financial savings;

  • Key Performance Indicator means a measure that captures the performance of a critical variable to expand and improve community-based corrections programs to promote offender success, ensure accountability, enhance public safety, and reduce recidivism.

  • Financial Performance Covenants means the covenants of the Borrower set forth in Sections 6.10 and 6.11.

  • Performance Level means a reference to one of Performance Level I, Performance Level II, Performance Level III, Performance Level IV or Performance Level V.

  • Publicly Perform means to perform public recitations of the Work and to communicate to the public those public recitations, by any means or process, including by wire or wireless means or public digital performances; to make available to the public Works in such a way that members of the public may access these Works from a place and at a place individually chosen by them; to perform the Work to the public by any means or process and the communication to the public of the performances of the Work, including by public digital performance; to broadcast and rebroadcast the Work by any means including signs, sounds or images.

  • Financial Performance Covenant means the covenant set forth in Section 6.10.

  • Additional Performance Security means the Bank Guarantee to be submitted by Successful Bidder in accordance with Clause 8.7 of this RFP Document

  • Capacity Performance Resource means a Capacity Resource as described in Tariff, Attachment DD, section 5.5A(a).

  • Time of Performance means the specific time or times indicated in the Contract at which or within which delivery or other performance is to be completed.

  • Performance evaluation means evaluation of work and program participation as well as other areas of behavior.

  • Qualifying Performance Criteria means any one or more of the following performance criteria, either individually, alternatively or in any combination, applied to either the Company as a whole or to a business unit, Parent, Subsidiary or business segment, either individually, alternatively or in any combination, and measured either annually or cumulatively over a period of years, on an absolute basis or relative to a pre-established target, to previous years’ results or to a designated comparison group, and on a pre-tax or after-tax basis, in each case as specified by the Committee in the Award: (i) cash flow (including operating cash flow or free cash flow); (ii) earnings (including gross margin, earnings before interest and taxes, earnings before taxes, and net earnings); (iii) earnings per share; (iv) growth in earnings or earnings per share; (v) stock price; (vi) return on equity or average stockholders’ equity; (vii) total stockholder return; (viii) return on capital; (ix) return on assets or net assets; (x) return on investment; (xi) revenue; (xii) income or net income; (xiii) operating income or net operating income; (xiv) operating profit or net operating profit; (xv) operating margin; (xvi) return on operating revenue; (xvii) market share; (xviii) contract awards or backlog; (xix) overhead or other expense reduction; (xx) growth in stockholder value relative to the moving average of the S&P 500 Index or a peer group index; (xxi) credit rating; (xxii) strategic plan development and implementation (including individual performance objectives that relate to achievement of the Company’s or any business unit’s strategic plan); (xxiii) improvement in workforce diversity; (xxiv) expenses; (xxv) economic value added; (xxvi) product quality; (xxvii) number of customers; (xxviii) objective customer indicators; (xxix) customer satisfaction; (xxx) new product invention or innovation; (xxxi) profit after taxes; (xxxii) pre-tax profit; (xxxiii) working capital; (xxxiv) sales; (xxxv) advancement of the Company’s product pipeline; (xxxvi) consummation of strategic transactions; (xxxvii) reduction in cash utilization; and (xxxviii) addition of technologies and products. The Committee may appropriately adjust any evaluation of performance under a Qualifying Performance Criteria to exclude any of the following events that occurs during a performance period: (A) asset write-downs; (B) litigation or claim judgments or settlements; (C) the effect of changes in tax law, accounting principles or other such laws or provisions affecting reported results; (D) accruals for reorganization and restructuring programs; and (E) any gains or losses classified as extraordinary or as discontinued operations in the Company’s financial statements.

  • Performance Review means a summative evaluation of a teacher other than a beginning teacher and used to determine whether the teacher’s practice meets school district expectations and the Iowa teaching standards, and to determine whether the teacher’s practice meets school district expectations for career advancement in accordance with Iowa Code section 284.7.