TERMINATION BY LANDLORD definition

TERMINATION BY LANDLORD. LANDLORD reserves the right to terminate this agreement with a SIXTY (60) day written notice to BROKER. In the event this agreement is terminated by LANDLORD, the BROKER's rights provided for in this agreement shall survive such termination. All monies expended by BROKER shall be paid to BROKER prior to this cancellation and BROKER is authorized to withhold any sums owed to BROKER from monies held prior to the final disbursement to LANDLORD. An additional cancellation fee of $195.00 will be charged to LANDLORD should LANDLORD terminate this agreement for any reason. If BROKER has not procured a TENANT within 90 days of the property being fully available for rent, LANDLORD may terminate this Agreement with no penalty.
Sample 1

Examples of TERMINATION BY LANDLORD in a sentence

  • SCHEDULE 3Residential Tenancies Act 1995—Section 91(1) (Residential Tenancies (General) Regulations 1995—Regulation 12(2)) NOTICE OF TERMINATION BY LANDLORD FOR A PERIODIC TENANCY (GENERAL FORM) (Note: A landlord cannot use this form to terminate a fixed-term tenancy (except under section 82 of the Act)—Application must be made to the Residential Tenancies Tribunal) To: .

  • Any attempted assignment, delegation, or transfer in violation of this Section shall be void and have no force or effect whatsoever, and at LANDLORD’S sole discretion, is grounds for TERMINATION BY LANDLORD under Section 28 TERMINATION BY LANDLORD of this Agreement.

  • TERMINATION BY LANDLORD: Termination is effective when actually physically received by BROKER BY CERTIFIED MAIL.

  • Any attempted assignment, transfer of ownership interest, or delegation in violation of this Section shall be void and have no force or effect whatsoever, and at LANDLORD’s sole discretion, is grounds for Termination by LANDLORD under SECTION 35 TERMINATION BY LANDLORD of this Agreement.

  • Any attempted assignment, delegation, or transfer in violation of this Section shall be void and have no force or effect whatsoever, and at LANDLORD’S sole discretion, is grounds for TERMINATION BY LANDLORD under Section 31 TERMINATION BY LANDLORD of this Agreement.

  • Any attempted assignment, transfer of ownership interest, or delegation in violation of this Section shall be void and have no force or effect whatsoever, and at LANDLORD’s sole discretion, is grounds for Termination by LANDLORD under SECTION 36 TERMINATION BY LANDLORD of this Agreement.

  • Any attempted assignment, delegation, or transfer in violation of this Section shall be void and have no force or effect whatsoever, and at LANDLORD’S sole discretion, is grounds for TERMINATION BY LANDLORD under Section 28 of this Agreement.

  • Landlord shall be responsible for ordinary and regular maintenance.6. TERMINATION BY LANDLORD Notwithstanding anything else in this Agreement to the contrary, Landlord shall have a unilateral right to terminate this Agreement, and the Tenant’s right of occupancy thereunder, upon ninety (90) days written notice in accordance with the Notice provisions of Paragraph 33.

Related to TERMINATION BY LANDLORD

  • Termination Right have the respective meanings given in the PRA Contractual Stay Rules.

  • Landlord Delay shall occur if either: (i) Landlord fails to complete the Base Building and/or other improvements on the Project that are required by the DDA, the Parking REA and/or the CC&Rs, and as a direct result of such failure Tenant is unable to obtain a temporary or permanent certificate of occupancy for the Premises upon substantial completion of the Tenant Improvements; or (ii) substantial completion of the Warm Shell Improvements or Tenant Improvements is delayed directly and solely as a result of any of the following and such delay could not have been mitigated by Tenant using commercially reasonable measures, which delay occurs after the Delivery Date and before the Commencement Date and does not result from Tenant's interference or delay in connection with completion of the Tenant Improvements or after a Tenant Default or Work Letter Draw Event: (a) subject to Paragraph 8 above, unreasonable interference by Landlord or Landlord's Contractor with the construction of the Warm Shell Improvements or the Tenant Improvements; (b) Landlord's failure to comply with any deadlines for response to, or submissions from, Tenant as required by this Work Letter; (c) any material Discretionary Changes to Landlord's Plans or the Warm Shell Plans after their final approval by applicable governmental entities (other than Tenant Modifications) that directly affect Tenant's Plans or the Tenant Improvements; and/or (d) Landlord failure to complete portions of the Base Building and/or other improvements on the Project that are Landlord's obligation to complete hereunder, and as a direct result of such failure Tenant and Tenant's contractors do not have access to the Premises to the extent required to complete the Warm Shell Improvements and/or Tenant Improvements. Tenant shall give Landlord at least five (5) days prior notice if Tenant becomes aware that Landlord is in danger of causing a Landlord Delay, and if Landlord takes appropriate measures to prevent such delay within such five (5) day period, no adjustment to the Commencement Date shall be made on account of such Landlord; provided, however, that if such delay was not reasonably foreseeable by Tenant, the five (5) day period for prior notice and opportunity to mitigate provided above shall be changed to forty-eight (48) hours after Tenant becomes aware of such delay or potential delay.

  • Partial Termination has the meaning set forth in the Section 6.3(a).

  • Renewal Rent for the Aircraft means the rent payable therefor in respect of a Renewal Lease Term determined pursuant to Section 17.2.2 of the Lease.

  • Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.

  • this Lease means the relevant portion of Articles 1 through 29 of this Office Lease to which this Tenant Work Letter is attached as EXHIBIT B and of which this Tenant Work Letter forms a part, and all references in this Tenant Work Letter to sections of "this Tenant Work Letter" shall mean the relevant portion of Sections 1 through 7 of this Tenant Work Letter.

  • Force Majeure Delays means any actual delay in the construction of the Tenant Improvements, which is beyond the reasonable control of Landlord or Tenant, as the case may be, as described in Paragraph 33 of the Lease.

  • Termination for Convenience means the termination of the Trade Contract Agreement or the Trade Contractor Work by the Authority without cause and for the convenience of the Authority as decided in its sole discretion.

  • this Tenant Work Letter means the relevant portion of Sections 1 through 6 of this Tenant Work Letter.

  • Base Rent As defined in Section 3.1.

  • Termination With Cause and “Cause” shall have the same meaning specified in any effective severance or employment agreement existing on the date hereof or hereafter entered into between the Executive and the Bank. If the Executive is not a party to a severance or employment agreement containing a definition of termination with cause, Termination with Cause means the Bank terminates the Executive’s employment for any of the following reasons –

  • Recapture Period means the period commencing on the Effective Date and ending on the fifth anniversary of the last date that a Project owned by the Company is Placed in Service.

  • Additional Rent means any and all amounts, other than Basic Rent, required to be paid by the Tenant under this Lease, whether or not same are designated “Additional Rent” or whether or not the same are payable by Landlord;

  • Base Rental means the sum of Seven Hundred Nineteen Thousand Two Hundred Sixty-Eight and NO/100 Dollars ($719,268.00), payable by Tenant to Landlord in sixty (60) monthly installments as follows:

  • Additional Rental has the meaning set forth in Section 4.03.

  • Master Lease means that certain [Master Lease title], relating to the leasing of, inter alia, the Healthcare Facility by Borrower to Master Tenant.

  • Termination or “Terminated” means, for purposes of this Plan with respect to a Participant, that the Participant has for any reason ceased to provide services as an employee, officer, director, consultant, independent contractor or advisor to the Company or a Parent or Subsidiary of the Company. An employee will not be deemed to have ceased to provide services in the case of (i) sick leave, (ii) military leave, or (iii) any other leave of absence approved by the Committee; provided, that such leave is for a period of not more than 90 days, unless reemployment upon the expiration of such leave is guaranteed by contract or statute or unless provided otherwise pursuant to formal policy adopted from time to time by the Company and issued and promulgated to employees in writing. In the case of any employee on an approved leave of absence, the Committee may make such provisions respecting suspension of vesting of the Award while on leave from the employ of the Company or a Parent or Subsidiary of the Company as it may deem appropriate, except that in no event may an Award be exercised after the expiration of the term set forth in the applicable Award Agreement. The Committee will have sole discretion to determine whether a Participant has ceased to provide services and the effective date on which the Participant ceased to provide services (the “Termination Date”).

  • Non-Renewal shall have the meaning set forth in Paragraph 2(b) hereof.

  • Termination Option means the option of either party to terminate a transaction in the event that the other party fails to perform a Firm obligation to deliver Gas in the case of Seller or to receive Gas in the case of Buyer for a designated number of days during a period as specified on the applicable Transaction Confirmation.

  • Terminating Party As defined in Section 7.1(f).

  • Automatic Termination shall have the meaning set forth in Section 2.3.2.

  • Basic Rent means Basic Rent as defined in Paragraph 6.

  • Tenant Delay as used in the Lease or this Agreement shall mean any delay that Landlord may encounter in the performance of Landlord’s obligations under the Lease or this Agreement because of any act or omission of any nature by Tenant or its agents or contractors, including any: (1) delay attributable to changes in or additions to the Approved Plans or to the Landlord’s Work requested by Tenant; (2) delay attributable to the postponement of any Landlord’s Work at the request of Tenant; (3) delay caused by a Change Order requested by Tenant; (4) delay attributable to the failure of Tenant to pay, when due, any amounts required to be paid by Tenant pursuant to the Lease; or (5) delay attributable to a failure of Tenant to employ union labor for Tenant’s work at the Premises during the time the Landlord’s Work is being constructed. Tenant shall pay all actual costs and expenses incurred by Landlord which result from any Tenant Delay and the Commencement Date of the Lease shall be accelerated one (1) day for each day the Premises is not Ready for Occupancy as a result of a Tenant Delay. No Tenant Delay shall be deemed to have occurred unless Landlord gives Tenant prior written notice or written notice within five (5) days of the occurrence, as reasonable under the circumstances, specifying the claimed reasons for such Tenant Delay, and Tenant shall fail to promptly correct or cure such Tenant Delay. There shall be excluded from the number of days of any Tenant Delay, or any of the following events of force majeure: labor disputes, fire, unusual delay in transportation, adverse weather conditions not reasonably anticipatable, unavoidable casualties, delays in obtaining permits or governmental approvals or any other causes beyond Landlord’s or its contractor’s reasonable control (and other than for financial reasons) (collectively, “Force Majeure Delays”).

  • Rent as used in this Section 21 shall be deemed to be and to mean all sums of every nature required to be paid by Tenant pursuant to the terms of this Lease, whether to Landlord or to others. As used in Sections 21(c)(ii)(A) and (B), above, the “worth at the time of award” shall be computed by allowing interest at the Default Rate. As used in Section 21(c)(ii)(C) above, the “worth at the time of award” shall be computed by discounting such amount at the discount rate of the Federal Reserve Bank of San Francisco at the time of award plus 1%.

  • Normal Termination means termination of employment or service with the Company and Affiliates:

  • Automatic Renewal Term has the meaning set forth in Section 10(a) hereof.