SUSPENSION OF THE WORK. 1. The State, at any time, may suspend all or any part of the services of the Engineer. In such event, the Engineer shall be given notice of such suspension in writing by registered or certified mail to the Engineer's address as furnished to the State for purposes of receiving notices under this contract, by email to the Engineer’s email address as furnished to the State for the purpose of notices, by facsimile transmission telecopy (fax) to the Engineer’s fax number as furnished to the State for the purpose of notices, or by hand delivery.
SUSPENSION OF THE WORK. A. The State, at any time, may suspend all or any part of the services of the Construction Administrator. In such event, the Construction Administrator shall be given notice of such suspension in writing by registered or certified mail to the Construction Administrator's address as furnished to the State for purposes of receiving notices under this contract, by email to the Construction Administrator’s email address as furnished to the State for the purpose of notices, by facsimile transmission telecopy (fax) to the Construction Administrator’s fax number as furnished to the State for the purpose of notices, or by hand delivery.
SUSPENSION OF THE WORK. 1. The State, at any time, may suspend all or any part of the services of the Architect. In such event, the Architect shall be given notice of such suspension in writing by registered or certified mail to the Architect's address as furnished to the State for purposes of receiving notices under this contract, by email to the Architect’s email address as furnished to the State for the purpose of notices, by facsimile transmission telecopy (fax) to the Architect’s fax number as furnished to the State for the purpose of notices, or by hand delivery.
SUSPENSION OF THE WORK. 1. The State, at any time, may suspend all or any part of the services of the Consultant. In such event, the Consultant shall be given notice of such suspension in writing by registered or certified mail to the Consultant 's address as furnished to the State for purposes of receiving notices under this contract, by email to the Consultant’s email address as furnished to the State for the purpose of notices, by facsimile transmission telecopy (fax) to the Consultant’s fax number as furnished to the State for the purpose of notices, or by hand delivery.
SUSPENSION OF THE WORK. (a) The Department will have the right and authority, without liability to the Concessionaire, to suspend any affected portion of the Work by written order to the Concessionaire to comply with any court order or judgment, to protect against a risk to the public health, safety or welfare (as more particularly set forth in Section 24.04(b)) including to workers, other personnel or the general public from unsafe or dangerous conditions, or upon the occurrence of any of the following by the Concessionaire:
SUSPENSION OF THE WORK. (a) Buyer may at any time, by written notice, order a suspension of the work in whole or in part for a period of up to ninety (90) days. Seller shall immediately comply with any such order and shall promptly take all steps necessary to put any such order into full force and effect in a manner that minimizes the cost to do so. During any period of suspension, Seller shall not remove any part of the work from any premises without prior written consent of Buyer. Within the said period of suspension, Buyer shall either i. rescind the order suspending the work,
SUSPENSION OF THE WORK. In written from the Employer, the Supplier must suspend the Work either in full or in part, for whatever period and in whatever way the Employer considers to be reasonably necessary. The Supplier must, in such circumstances, protect and safeguard the Work to the extent that this is considered to be necessary by the Employer. In cases where the suspension lasts for more than six months, the Supplier and the Employer engage themselves to renegotiate the Agreement for the Work on the basis of the new circumstances. The Supplier and/or the Employer are free to request for settlement of disputes in accordance with Clause 33 of this Agreement.
SUSPENSION OF THE WORK. If Owner exercises its suspension rights under Article 22, Owner shall grant to Contractor an extension of the Contract Time for the relevant part of the Work equal to the length of the actual delay to the Critical Path necessarily caused by such suspension, but there shall be no adjustment of the Contract Amount in connection with such suspension except as explicitly provided in this Article. In the event that the Work is suspended by Owner pursuant to this Article for more than thirty days, the Contract Amount for such part of the Work may be adjusted for any increase in the cost of performance of the Work (excluding profit) necessarily caused by such suspension. However, no adjustment of the Contract Time or Contract Amount shall be made for any suspension: (a) to the extent that performance would have been suspended, delayed or interrupted by any other cause, including the fault or negligence of Contractor or (b) for which equitable adjustment is provided for or excluded under any other provision of the Contract.
SUSPENSION OF THE WORK. Performance of the Work under this Agreement may be suspended by AURA in the event of a total or partial government shut down or if funding for the Work or this Project is delayed or suspended. Such suspension shall be considered temporary and in no way shall be deemed to be a breach or termination of this Agreement.
SUSPENSION OF THE WORK. A. The State, at any time, may suspend all or any part of the services of the Claims Analyst. In such event, the Claims Analyst shall be given notice of such suspension in writing by registered or certified mail to the Claims Analyst's address as furnished to the State for purposes of receiving notices under this contract, by email to the Claims Analyst’s email address as furnished to the State for the purpose of notices, by facsimile transmission telecopy (fax) to the Claims Analyst’s fax number as furnished to the State for the purpose of notices, or by hand delivery.
