Stipulated Period of Completion definition

Stipulated Period of Completion means the time period for completion of Contract as specified in the Work Order. This period shall start from the Commencement Date and shall end at the Stipulated Date of Completion.
Sample 1Sample 2Sample 3
Stipulated Period of Completion means the period in which the Contractor is required to complete the work. The stipulated period is specified in the Contract Data.
Sample 1Sample 2Sample 3
Stipulated Period of Completion means the period in which the contractor is required to complete the work. The stipulated period is specified in the contract data.
Sample 1

Examples of Stipulated Period of Completion in a sentence

  • Description Prime contractor or Sub- contractor Stipulated period of completion Actual date of completion* of work- Value of Project Name of Diameter & Contract No. contract Name Employer Length of DI & Date (Rs. Lakhs) Pipes * Enclose a certificate from the Engineer concerned for completion.

  • Description Prime contractor or Sub- contractor Project Name Name of Employer of work- Diameter & Length of DI Pipes Contract No. & Date Value of contract (Rs. Lakhs) Stipulated period of completion Actual date of completion* * Enclose a certificate from the Engineer concerned for completion.

  • Description Prime contractor or Sub‐ contractor Stipulated period of completion Actual date of completion* of work‐ Value of Project Name of Diameter & Contract No. contract Name Employer Length of DI & Date (Rs. Lakhs) Pipes * Enclose a certificate from the Engineer concerned for completion.

  • Xxxxx) Date of issue of work order Stipulated period of completion Actual date of completion Remarks explaining reasons for delay, if any and work completed • Enclose certificate(s) from Engineer(s)- in- charge.

Related to Stipulated Period of Completion

  • Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Final Completion Date means the date on which Final Completion occurs.

  • Successful Completion means that in the reasonable opinion of the Customer, Deliverables completed by the Supplier are fit for purpose, completed on time and otherwise meet all the criteria defined under this Contract;

  • Time of Completion means the time for completing the execution of and passing the Tests on Completion of the Works of any section or part thereof as stated in the Contract (or as extended under Clause...) calculated from the Commencement Date

  • Date of Completion with respect to a Project shall mean: (i) the date upon which such Project and all components thereof have been acquired or constructed and are capable of performing the functions for which they were intended, as evidenced by an Engineers’ Certificate filed with the Trustee and the Issuer; or (ii) the date on which the Issuer determines, upon the recommendation of or in consultation with the Consulting Engineer, that it cannot complete such Project in a sound and economical manner within a reasonable period of time as evidenced by an Engineers’ Certificate filed with the Trustee and the Issuer; provided that in each case such certificate of the Consulting Engineer shall set forth the amount of all Costs of such Project which have theretofore been incurred, but which on the Date of Completion is or will be unpaid or unreimbursed.

  • Tests after Completion means the tests (if any) which are specified in the Contract and which are carried out in accordance with the Specification after the Works or a Section (as the case may be) are taken over by the Procuring Entity.

  • Scheduled Completion Date shall be the date set forth in Clause 10.3;

  • Initial compliance period means the first full three-year compliance period which begins at least 18 months after promulgation, except for the following contaminants: Dichloromethane; 1,2,4-Trichlorobenzene; 1,1,2- Trichloroethane; Benzo[a]pyrene; Dalapon; Di(2-ethylhexyl adipate; Di(2-ethylhexyl) phthalate; Dinoseb; Diquat; Endothall; Endrin; Glyphosate; Hexachlorobenzene; Hexachlorocyclopentadiene; Oxamyl (Vydate); Picloram; Simazine; 2,3,7,8-TCDD (Dioxin); Antimony; Beryllium; Cyanide; Nickel; and Thallium, initial compliance period means the first full three-year compliance period after promulgation for systems with 150 or more service connections (January 1993 -December 1995) and first full three-year compliance period after the effective date of regulation (January 1996 - December 1998) for systems having fewer than 150 service connections.

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Construction Period means the period commencing from the Appointed Date and ending on the date of the Completion Certificate;

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.

  • Study Completion means the database for the Study has been locked and all Essential Documents have been provided to the Sponsor, including a copy of the letter from the Reviewing HREC acknowledging receipt of the final report and/or closure letter from the Principal Investigator.

  • Virtual Completion means the premise is in the opinion of the Employer fit for occupation.

  • Notice of Completion means a document issued by the Department or Delegated Agency at the end of project construction when all items and conditions of the approved Sediment and Stormwater Management Plan have been satisfied, post construction verification documents demonstrate that the stormwater management systems have been constructed in accordance with the approved Sediment and Stormwater Management Plan, and final stabilization of disturbed areas on the site has been achieved.

  • Rectification Period means the period of time set out in Section 4.3 of this RFP during which a Proponent will be permitted to rectify its Proposal to satisfy the mandatory submission requirements of this RFP.

  • Program Period means the period of time which the department intends to support the program without requiring the recompetition for funds. The program period is specified within the grant application.

  • Evaluation Period bears the meaning ascribed thereto in Section 7.4(d)(i);

  • Outside Completion Date shall have the meaning assigned to such term in Section 6.3(d).

  • Commissioning Period means, with respect to each Subproject, the period commencing upon the first delivery of Feed Gas to the Subproject in accordance with Sections 4.8 and 11.1 of the Agreement continuing through achievement of RFSU, commissioning, Start Up, Performance Testing and achievement of Substantial Completion for such Subproject.