Site Engineers definition

Site Engineers means the Assistant Engineer & Jr. Engineer (Civil / Electrical) appointed by Institute works department.
Sample 1Sample 2Sample 3
Site Engineers means the AEE (Civil)/ Junior Engineer (Civil)/Junior
Sample 1Sample 2Sample 3
Site Engineers means the AEE (Civil)/ Junior Engineer (Civil)/Junior Engineer (Electrical) appointed by Works & Estate department.
Sample 1Sample 2Sample 3

Examples of Site Engineers in a sentence

  • Site Engineers shall mean the Assistant Engineer & Jr. Engineer (Electrical) for Electrical & Air-conditioning works, appointed by the Institute Works Department.2. Duties & Powers : i) Site Engineers :The duties of the Site Engineer(s) are to watch and supervise the works and the workmanship employed in connection with the works, and to test and examine any materials to be used.

  • The Engineer-in-charge, from time to time in writing, delegates to the Site Engineer(s) any of the powers and authorities vested in them.

  • Duties & Powers : i) Site Engineers : The duties of the Site Engineer(s) are to watch and supervise the works and the workmanship employed in connection with the works, and to test and examine any materials to be used.

  • The duties of the Site Engineer(s) are to watch and supervise the works and the workmanship employed in connection with the works, and to test and examine any materials to be used.

  • He shall have no authority to relieve the contractor of any of his duties or obligations under the contract, except as expressly provided here under, nor to order any work involving delay or any extra payment by the Institute and to make any variation in the works.The Engineer-in-charge, from time to time in writing, delegates to the Site Engineer(s) any of the powers and authorities vested in them.

  • Failure of the Site Engineer(s) to disapprove any work or materials shall not prejudice the power of the Engineer In-charge to subsequently disapprove such work or materials and to order the pulling down, removal or breaking up thereof.

  • One Site Engineers with 3 years of experience having Civil Engineering.

  • If the contractor is dissatisfied by reason of any decision of the Site Engineer(s), he shall be entitled to refer the matter to the Engineer- in-charge, who shall thereupon confirm reverse or vary such decision.

  • Preparing for the use of the Bank, the contactors, PMC/ and the Site Engineers (if any) appointed by the Bank, six copies of the contract documents of various trades including all drawings, specifications and other particular such further details and drawings as are necessary for the proper execution of the said works.

  • BHEL shall mean Bharat Heavy Electricals Limited (of PE&SD, Hyderabad), a company registered under Indian Companies Act 1956, with its Registered Office at BHEL HOUSE, SIRI FORT, NEW DELHI – 110 049, or its Power Sector Regional Offices/PESD HQ or its Authorised Officers or its Site Engineers or other employees authorised to deal with any matters with which these persons are concerned on its behalf.


More Definitions of Site Engineers

Site Engineers means the Assistant Engineer & Jr. Engineer (Civil / Electrical) appointed by Institute works department. 2. DUTIES &POWERS: 2.1 Site Engineers:The duties of the Site Engineer(s) are to watch and supervise the works and the workmanship in connection with the works, and to test and examine any materials to be used. He shall have no authority to relieve the contractor of any of his duties or obligations under the contract, except as expressly provided here under, nor to order any work involving delay or any extra payment by the Institute and to make any variation in the works.The Engineer-in-charge, from time to time in writing, delegates to the Site Engineer(s) any of the powers and authorities vested in them. Any written instruction or written approval given by the Site Engineer (s) to the contractor within the terms of such delegation (but not otherwise) shall bind the contractor and the Institute as though it had been given by the Engineer-in-charge provided always as follows:
Sample 1
Site Engineers means the AEE /Assistant Engineer (Electrical)/ Engineer appointed by the Works & Estate department.
Sample 1Sample 2
Site Engineers means the appointed by Institute works department.
Sample 1
Site Engineers means the Assistant Executive Engineer, Assistant Engineer & Jr. Engineer (Civil / Electrical)/ Project Site Engineer (Civil/Electrical) appointed by Institute works department.
Sample 1
Site Engineers means the Assistant Engineer & Jr. Engineer (Civil / Electrical) appointed by the Institute.
Sample 1
Site Engineers means the Assistant Engineer & Jr. Engineer (Civil / Electrical) appointed by Institute works department. 2. DUTIES & POWERS : 2.1 Site Engineers : The duties of the Site Engineer(s) are to watch and supervise the works and the workmanship in connection with the works, and to test and examine any materials to be used. He shall have no authority to relieve the contractor of any of his duties or obligations under the contract, except as expressly provided here under, nor to order any work involving delay or any extra payment by the Institute and to make any variation in the works.The Engineer-in-charge, from time to time in writing, delegates to the Site Engineer(s) any of the powers and authorities vested in them. Any written instruction or written approval given by the Site Engineer (s) to the contractor within the terms of such delegation (but not otherwise) shall bind the contractor and the Institute as though it had been given by the Engineer-in-charge provided always as follows : Failure of the Site Engineer (s) to disapprove any work or materials shall not prejudice the power of the Engineer in-charge to subsequently disapprove such work or materials and to order the pulling down, removal or breaking up thereof. If the contractor is dissatisfied by reason of any decision of the Site Engineer (s), he shall be entitled to refer the matter to the Engineer-in-charge, who shall thereupon confirm reverse or vary such decision. 3. ASSIGNMENT & SUBLETTING: 3.1 The contractor shall not assign the contract or any part thereof or any benefit or interest therein or there under without the written consent of the Engineer in-charge. The whole of the works included in the contract shall be executed by the contractor except where otherwise provided in the contract. The contractor shall not sublet any part of the works without the written consent of the Engineer in-charge and such consent, if given, shall not relieve the contractor from any liability or obligation under the contract, and he shall be responsible for the acts, defaults and neglects of sub-contractor, his agents, servants or workmen, as if they were the acts, defaults or neglects of the contractor provided always that the provision of labour contracts on a piece work basis shall not be deemed to be a subletting under this clause. 4. SCOPE OF CONTRACT:The contract comprises the construction, completion and maintenance of the works for twelve (12) months after the completion, and the provision of all labou...
Sample 1

Related to Site Engineers

  • Site Engineer means an Engineer appointed by the SBIIMS at site as their representative for day-to-day supervision of work and to give instructions to the contractors.

  • Geotechnical engineer means a professional engineer registered with the Association of Professional Engineers, Geologists, and Geophysicists of the Northwest Territories and whose principal field of specialization is the design and construction of earthworks in a permafrost environment;

  • Architect/Engineer or “A/E” means the Person identified in the Agreement responsible for providing professional design services and construction contract administration for the Project. The A/E shall be (1) a registered architect holding a license and certificate of authorization issued by the Ohio Architects Board pursuant to ORC Chapter 4703, (2) a landscape architect holding a license and certificate of authorization issued by the Ohio Landscape Architects Board pursuant to ORC Chapter 4703, or (3) a professional engineer or professional surveyor holding a license and certificate of authorization issued by the Ohio Engineers and Surveyors Board pursuant to ORC Chapter 4733. As used in the Agreement, the term A/E may include a criteria architect or engineer for a Design-Build project.

  • Engineers Certificate" shall mean a certificate of the Consulting Engineers or of such other engineer or firm of engineers having a favorable repute for skill and experience in the engineering matters with respect to which such certification is required by this Master Indenture.

  • SBI Engineer means The Civil/Electrical Engineer in-charge of the Project, as nominated by the AGM (P&E), SBI, RAJKOT

  • Project Architect means the architect retained by Lessee to design and supervise construction of the Improvements.

  • Banks Engineer means any Engineer who is employed by SBI or any other Engineer appointed from time to time by the Employer, and certified in writing to the Architect and the contractor, to act as Engineer for the purpose of the Contract in place of the said engineer.

  • Architect means the person or other entity engaged by the PHA to perform architectural, engineering, design, and other services related to the work as provided for in the contract. When a PHA uses an engineer to act in this capacity, the terms “architect” and “engineer” shall be synonymous. The Architect shall serve as a technical representative of the Contracting Officer. The Architect’s authority is as set forth elsewhere in this contract.

  • Value Engineering means the detailed analysis of systems, equipment, materials, services, facilities, and supplies required by the Contract Documents for the purpose of achieving the desired and essential functions of the Owner’s program at the lowest cost consistent with required and necessary performance, longevity, reliability, quality and safety.

  • Project Engineer means the surveyor or engineer employed by or private

  • Professional Engineer means a person entitled to practise as a Professional Engineer in the Province of Ontario under a licence issued under the Professional Engineers Act;

  • Design engineer means a person professionally qualified and duly licensed in New Jersey to perform engineering services that may include, but not necessarily be limited to, development of project requirements, creation and development of project design and preparation of drawings and specifications.

  • Architects means any Architect whom the Vendors and the Builder have appointed as the Architects for the Project / Buildings time to time.

  • COMPANY ENGINEER means the following:

  • Independent Engineer means XxXxxxxx and XxxXxxxxxxx or any other third party engineering firm acceptable to the Administrative Agent in its sole discretion.

  • City Engineer means the person appointed to the office of City Engineer, by Council, acting, either directly or through authorized staff acting severally within the scope of the particular duties entrusted to them.

  • Engineer means the representative of the Architect/consultant.