Examples of Separate Contractor in a sentence
Contractor shall not cut or otherwise alter the work of MSG or any Separate Contractor except with the written consent of MSG and of such Separate Contractor.
Contractor shall not unreasonably withhold from MSG or any Separate Contractor consent to cutting or otherwise altering the Work.
If any Separate Contractor causes damage to the Work, and Construction Manager is required to remedy such damage, Owner will issue a Change Order for the cost thereof, and will further grant a Time Extension or, alternatively, Owner may direct and compensate Construction Manager for Acceleration, if the delayed activity is on the Critical Path of the Project Schedule.
Accordingly, Construction Manager agrees that, upon request by Owner, Construction Manager shall temporarily suspend any affected Work activity during the period which, in Owner’s reasonable judgment, Construction Manager’s Work would unreasonably interfere with the Work of a Separate Contractor.
Contractor shall not be entitled to an adjustment of the GMAX, damages or other compensation, however characterized, arising out of or related to delays or hindrances caused solely by the Owner or a Separate Contractor unless Contractor submits a claim for such in accordance with Article 15 of these General Conditions, and any such amounts shall be limited as follows.