Scheduled Project Completion Date definition

Scheduled Project Completion Date shall have the meaning specified in Section 6.3 (c);

Scheduled Project Completion Date. Means the last day of 60 (Sixty) months starting from the Agreement Date.

Scheduled Project Completion Date. Means the last day of 24 (Twenty Four) months starting from the Agreement Date or the date on which encumbrance free land was actually handed over to the Lessee, whichever is later.

Examples of Scheduled Project Completion Date in a sentence

• Provided no such Change of Scope shall be made in the Construction Phase if it is in the reasonable judgment of the parties hereto likely to delay the completion of the Project such that the Project cannot be completed on the Scheduled Project Completion Date.

• Developer shall apply its best effort to sell the entire Residential Units within the Scheduled Project Completion Date or within any extended period allowed.

• The Concessioning Authority shall not operationalise any additional facility within Port Limits for handling (specify cargo)_either on its own or through any other Person until the earlier of (i) 5 (five) years from the Scheduled Project Completion Date; or (ii) the average annual volume of cargo handled at the Project Facilities and Services reaches a level of 75% (seventy five percent) of Project Capacity for 2 (two) consecutive years (“Exclusivity Period”).

• Subject to the provisions of 11.4, if COD does not occur prior to the 30th (thirtieth) day after the Scheduled Project Completion Date, unless the delay is on account of reasons attributable to the Authority or due to Force Majeure, the Concessionaire shall pay Damages to the Authority at the rate of 0.05% (zero point zero five per cent) of the amount of Construction Performance Security for delay of each day until COD is achieved.

• Provided no such Change of Scope shall be made in the Expansion Phase if it is in the reasonable judgment of the parties hereto likely to delay the Scheduled Project Completion Date.

More Definitions of Scheduled Project Completion Date

Scheduled Project Completion Date means [●]9.

Scheduled Project Completion Date. Means the last day of 108 (One Hundred and Eight) months starting from the Agreement Date or the date on which NRDA Assets, free from encumbrances are actually handed over to the Developer, whichever is later.

Scheduled Project Completion Date or “Scheduled Completion Date” shall have the meaning as set forth Clause 16.6;

Scheduled Project Completion Date shall have the meaning set forth in Article 9.2(b).

Scheduled Project Completion Date. Means the last day of 5.0 (Five) years starting from the Date of Issue of Notice of Allotment (NoA).

Scheduled Project Completion Date means the day following completion of 18 calendar months after Date of Award of Concession.

Scheduled Project Completion Date means the date specified in the Project Timetable set out in Item 5 of Schedule A;