Project Deadline definition

Project Deadline means the long stop date by which the Recipient must complete the Project, as stated in the Front Sheet (or such other date as the parties may agree in writing);
Sample 1Sample 2
Project Deadline means February 28, 2023, or such other date as may be agreed to by the parties, mutually, in writing.
Sample 1Sample 2
Project Deadline is defined in Section 1.2.
Sample 1

Examples of Project Deadline in a sentence

  • Work will be performed under the scope of work, schedule for work, and cost based upon rates in agreement.2.0 Project Deadline and Liquidated Damages‌The completion date for this project shall be set forth in the bid the time by which Bidder shall achieve substantial completion, subject to the restrictions established in these instructions.

  • The City shall have a right to terminate this Agreement in the event the Company fails to meet the Project Deadline.

  • Thus, DISTRICT shall be damaged in the event ARCHITECT does not provide the services necessary to meet the DOD Deadlines and specifically the Project Deadline.

  • PROJECT FORMS AND INSTRUCTIONS Savio Senior Project Deadline Worksheet Use this worksheet to keep track of your action items throughout the Senior Project.

  • It being impracticable and infeasible to determine the amount of actual damage, it is agreed that the ARCHITECT will pay the DISTRICT the sum of Five Hundred Dollars ($500) per calendar day for each and every day of delay beyond the Project Deadline as liquidated damages and not as a penalty or forfeiture.

  • Project Description: Project Deadline: Specific Deliverables:1.2.3.

  • Project Deadline The project completion date is June 30, 2016 and will be reviewed by the West Virginia State Historic Preservation Office.

  • If the Completion Conditions are not satisfied by March 1, 2015 (other than due to the City’s delay in completing the Dirt Work), the parties agree to extend the Project Deadline, day for day, until the Completion Conditions are satisfied, except for the Dirt Project which deadline for completion shall remain August 15, 2014.

  • Supplemental documentation should be attached to this form to illustrate the necessity of an extension and to provide support to the written and signed justification provided on the Project Deadline Extension Form.

  • If the Parties are unable to establish new Project Deadlines after the original Project Deadline expires, the Sellers may elect to repurchase the Property pursuant to Section 5.2.2(ii) below.


More Definitions of Project Deadline

Project Deadline shall have the meaning given to such term in Section 4.5(a) of this Agreement. “Receipt Point” shall mean, a point where the custody and control of Shipper Crude Oil transfers from Shipper to Gatherer located at the inlet flange of Gatherer’s LACT through which such Shipper Crude Oil flows into the Gathering System. “Services” shall mean receipt, gathering and transportation on the Gathering System of Crude Oil for Shipper’s account from the Receipt Point(s) and delivery to the Delivery Point(s) specified in Shipper’s Nomination, together with all other services to be provided by Gatherer as contemplated in this Agreement. “Shipper” shall have the meaning given to such term in the preamble of this Agreement. “Shipper Crude Oil” shall have the meaning given to such term in Section 3.1 of this Agreement. “Shipper Default” shall have the meaning given to such term in Section 19.1 of this Agreement. “Shipper Default Notice” shall have the meaning given to such term in Section 19.2 of this Agreement. “Shipper Indemnified Party” means Shipper and its Affiliates, and all of its and their respective equityholders, partners, members, directors, officers, managers, employees, agents and representatives. “Shipper’s Maximum Daily Quantity” or “MDQ” shall mean, with respect to any Contract Year, the volume of Crude Oil (expressed in BPD) set forth for such Contract Year in the table captioned “MDQ” in Exhibit B attached hereto, for which Shipper shall receive Priority Service as set forth in Section 6.2 hereof. With respect to any Contract Year beginning on or after the fourth (4th) anniversary of the Commencement Date, Gatherer shall have the option, by delivering written notice to Shipper on or before the date that is thirty (30) Days prior to the start of any such Contract Year, to reduce Shipper’s Maximum Daily Quantity for such Contract Year to an amount equal to the lesser of (x) the MDQ that was in effect at the end of the immediately preceding Contract Year or (y) 110% of the ADV of Shipper Crude Oil delivered or available for delivery hereunder by Shipper to Gatherer during the immediately preceding twelve (12)
Sample 1

Related to Project Deadline

  • Opt-Out Deadline means the deadline set by the Court for the timely submission of requests by Settlement Class Members to be excluded from the Settlement Class.

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Response Deadline means 60 days after the Administrator mails Notice to Class Members and Aggrieved Employees, and shall be the last date on which Class Members may: (a) fax, email, or mail Requests for Exclusion from the Settlement, or (b) fax, email, or mail his or her Objection to the Settlement. Class Members to whom Notice Packets are resent after having been returned undeliverable to the Administrator shall have an additional 14 calendar days beyond the Response Deadline has expired.

  • Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Xxxxxx Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.