Premises Notice definition

Premises Notice means the notice described in subsection 2.3.1.
Sample 1Sample 2Sample 3
Premises Notice means the notice described in Section 3.1.1 and attached as Exhibits C, D, E, F and I.
Sample 1
Premises Notice means the notice described in Section 4.02.A and attached as‌ Exhibit G.
Sample 1

Examples of Premises Notice in a sentence

  • The Port grants to Airline the exclusive right to use the Exclusive Premises, including Shared Exclusive Premises, identified in the Premises Notice.

  • The Port grants to Airline, subject to Articles 4 and 5 of this Agreement, the right to use, on a preferential use basis, the Preferential Use Premises identified in the Premises Notice.

  • The Port grants to Airline, subject to Articles 4 and 5 of this Agreement, the right to use, on a common use basis, the Common Use Premises identified in the Premises Notice, subject at all times to the exclusive control and management by the Port.

  • Subject to the provisions of Articles 4 and 5 of this Agreement, the Port reserves the right to revise Airline’s right to use such Common Use Premises by sending to Airline a revised Premises Notice.

  • Exhibit B: Airport Legal Description and Drawing Exhibit C: Premises Notice Exhibit D: Gate Use, Assignment and Scheduling Procedures.

  • There is an element θ(X ) ∈ H2(F, C) attached to X such that X has an object over a scheme X if and only if θ(X ) is trivial over X.

  • When a Councilor anticipates being absent or late for a Council meeting, the Councilor is expected to notify (e.g. telephone, e-mail) the GNSO Secretariat as soon as practicable before the meeting begins.

  • The Port and Lessee agree that the Premises are, and shall be deemed for all purposes to be, the size set forth in the Premises Notice.

  • The Chronic Nuisance Premises Notice (“CNP Notice”) shall be deemed delivered if sent either by first class mail to the Premises owner's last known address or delivered in person to the Premises owner and the courtesy copy to the Alder at the Common Council office or by electronic mail.

  • Other names for a notice to vacate letter include: Letter to Vacate Premises Notice of Intent to Vacate Move-Out Notice Reasons to Send a Notice to Vacate If you need to break your lease early, you can use a notice to vacate letter to inform your landlord, but be advised that additional fees may apply, or you may not get your security deposit back (check your state’s rental laws).

Related to Premises Notice

  • Expansion Space means any space in the Building which, at any time during the Lease Term, is occupied by a Person other than Landlord under a written lease with Landlord, and the term “Tenant’s Expansion Space” means Expansion Space which Tenant has elected to lease as provided in this paragraph. Landlord agrees to notify Tenant promptly after Landlord learns that any Expansion Space is or will become available. Subject to the prior rights of other tenants to whom Landlord has granted substantially similar rights, Tenant has the option to lease any Expansion Space which Landlord notifies Tenant is or will become available. If Tenant gives Landlord notice of its exercise of this option within thirty (30) days after notification from Landlord of the availability of the Expansion Space and if no Event of Default exists when Tenant’s notice is given, this Lease will be deemed to be amended to include Tenant’s Expansion Space as part of the Premises for the remainder of the Lease Term upon all of the same terms contained in this Lease except that (i) the Rentable Area of the Premises will be amended to include Tenant’s Expansion Space; (ii) Tenant’s Share will be increased to include the rentable area of Tenant’s Expansion Space; (iii) the Term Commencement Date with respect to Tenant’s Expansion Space will be the earlier of sixty (60) days after the date on which Tenant’s Expansion Space becomes vacant and ready for occupancy (provided that date is at least sixty (60) days after Tenant exercises its option to lease the Expansion Space), or the date on which the Expansion Space is first occupied by Tenant; (iv) if Tenant’s Expansion Space contains a rentable area of 10,000 square feet or more, and if there are less than three (3) Lease Years remaining in the Lease Term, the Lease Term will be extended to include three (3) full years from the Term Commencement Date with respect to Tenant’s Expansion Space; and (v) subject to adjustment during each Fixed Rental Period as provided in Exhibit E, Basic Rent for each year of the remaining Lease Term (as it may be extended) will be the greater of (a) the Basic Rent last paid by the Person most recently occupying Tenant’s Expansion Space or (b) Market Rent determined as provided in the Rent Rider attached as Exhibit E. If Tenant exercises this option, Tenant’s Expansion Space will be leased to Tenant in its “as is” condition and Tenant will, at its expense and in compliance with the provisions of Section 7.06, design and construct all Improvements desired by Tenant for its use and occupancy. Landlord and Tenant agree to execute such amendments to this Lease and other instruments as either of them considers necessary or desirable to reflect Tenant’s exercise of this option.

  • Property Notice means any order, notice, proposal, demand or other requirement issued by any competent authority (including the Landlord) which materially affects the Academy Trust’s ability to use the Land for the purposes of the Academy. Restrictions on Land transfer

  • Commencement Notice means a written notice, given by any Secured Party to the other Secured Parties in accordance with the notice provisions set forth in the Securities Purchase Agreement, pursuant to which such Secured Party notifies the other Secured Parties of the existence of one or more Events of Default and of such Secured Party’s intent to commence the exercise of one or more of the remedies provided for under this Agreement with respect to all or any portion of the Collateral as a consequence thereof, which notice shall incorporate a reasonably detailed description of each Event of Default then existing and of the remedial action proposed to be taken.

  • improvement notice means the notice issued by the Authority to the Supplier pursuant to Clause 32.1.3 (Authority Remedies) which will detail how the Supplier shall improve the provision of the Goods and/or Services;

  • Storage Space means a space where goods of non-hazardous nature are stored and includes cold storage and banking safe vaults;

  • Available Space means the balance of the rentable square footage in the Building not already included as part of the Premises, which is not occupied by a tenant or which is occupied by an existing tenant whose lease is expiring within 6 months or less and such tenant does not wish to renew (whether or not such tenant has a right to renew) its occupancy of such space. If there is any Available Space in the Building, Landlord shall, at such time as Landlord shall elect so long as Tenant’s rights hereunder are preserved, deliver to Tenant written notice (the “Expansion Notice”) of such Available Space, together with the terms and conditions on which Landlord is prepared to lease Tenant such Available Space; provided that Base Rent shall be at the Market Rate (as defined in Section 40(a) below) for such Available Space. Tenant shall be entitled to exercise its right under this Section 39(a) only with respect to the entire Available Space described in such Expansion Notice (“Identified Available Space”). Tenant shall have 5 business days following delivery of the Expansion Notice to deliver to Landlord written notification of Tenant’s exercise of the Expansion Right with respect to the Identified Available Space (“Exercise Notice”). Tenant shall be entitled to lease such Identified Available Space upon the terms and conditions set forth in the Expansion Notice. If Landlord and Tenant are unable to agree on the Market Rate for the Available Space after negotiating in good faith within 5 days after Tenant’s delivery of an Exercise Notice, the applicable Market Rate will be determined through arbitration in accordance with Section 40(b). Tenant acknowledges and agrees that, if Tenant has delivered an Exercise Notice pursuant to this Section 39(a), Tenant shall have no right thereafter to rescind or elect not to lease the Available Space. Tenant acknowledges that the Term of the Lease with respect to the Identified Available Space may not be co-terminous with the Term of the Lease with respect to the original Premises. Notwithstanding anything to the contrary contained herein, Tenant shall have no right to exercise the Expansion Right and the provisions of this Section 39(a) shall no longer apply after the date that is 9 months prior to the expiration of the Base Term if Tenant has not exercised its Extension Right pursuant to Section 40. If Tenant fails to deliver an Exercise Notice to Landlord for the Identified Available Space within the required 5 business day period, Tenant shall be deemed to have forever waived its rights under this Section 39(a) to lease the Identified Available Space, and Landlord shall have the right to lease the Identified Available Space to any third party on any terms and conditions acceptable to Landlord.

  • Rectification Notice means a notice in writing that identifies a defect in a work and requires rectification of the defect within a specified period of time.

  • Exhibition Space means any space in the Exhibition Centre licensed to the Exhibitor by the Organisers for the purpose of the Exhibition under these Terms and Conditions and shall include shell (ready stand) spaces and nonshell (raw) spaces.

  • residential premises means a house, building, structure, shelter, or mobile home, or portion thereof, used as a dwelling, home, residence, or living place by 1 or more human beings. “Residential premises” includes an apartment unit, a boardinghouse, a rooming house, a mobile home, a mobile home space, and a single or multiple family dwelling, but does not include a hotel, a motel, motor home, or other tourist accommodation, when used as a temporary accommodation for guests or tourists, or premises used as the principal place of residence of the owner and rented occasionally during temporary absences including vacation or sabbatical leave.

  • Subleased Premises means such portions of the Leased Premises being particularly identified on Schedule B, which the parties agree, for the purposes of this Sublease and any square footage calculations pursuant hereto, is approximately 42,244 square feet of office (21,068 square feet on the third floor and 21,176 square feet on the seventh floor) and approximately 9.4312% of common space (building rentable area is 447,917 square feet).

  • Collocation Space means an area of space located in a Building to be used by CLEC to house telecommunications equipment. Additionally, roof or wall space used for wireless interconnection shall be included in the definition where applicable.

  • Off-premises sign means a sign directing attention to a use, product, commodity or service not related to the premises upon which the sign is located.

  • Rentable Area of the Premises The amount of square footage set forth in Section 1.01(10).

  • Escalation Notice has the meaning set forth in Section 8.02.

  • Completion Notice means a notice issued by the Developer in accordance with clause 6.1.

  • this Tenant Work Letter means the relevant portion of Sections 1 through 6 of this Tenant Work Letter.

  • Usable space means all the space on a pole, except the portion below ground level, the 20 feet of safety clearance space above ground level, and the safety clearance space between communications and power circuits. There is a rebuttable presumption that six feet of a pole are buried below ground level.

  • Premises Total Destruction means damage or destruction to the Premises, other than Lessee Owned Alterations and Utility Installations and Trade Fixtures, which cannot reasonably be repaired in six (6) months or less from the date of the damage or destruction. Lessor shall notify Lessee in writing within thirty (30) days from the date of the damage or destruction as to whether or not the damage is Partial or Total.

  • Work space means that portion of the court’s facilities dedicated to each court reporter, including but not limited to actual space in the courtroom and any designated office space.

  • New Building ’ means a new construction to house a complete motor vehicle as- sembly process, where that construction includes the pouring or construction of a new foundation and floor, the erection of a new frame and roof, and the instal- lation of new plumbing and electrical and other utilities;

  • Commercial Premises Means a place of trade or premises operated for financial gain, including but not limited to, a retirement village or a block of flats that has a common facility; a place of trade where the manufacture and production of products or produce takes place; a site where renovation, restoration and refurbishment work as described in Appendix B takes place.

  • industrial premises means any place or premises (not being a private dwelling house), including the precincts thereof, in which or in any part of which any industry, trade, business, occupation or manufacturing is being ordinarily carried on with or without the aid of power and includes a godown attached thereto;

  • Leased space means individual storage space at a self-service storage facility which is rented to an occupant pursuant to a rental agreement.

  • Landlord Delay shall occur if either: (i) Landlord fails to complete the Base Building and/or other improvements on the Project that are required by the DDA, the Parking REA and/or the CC&Rs, and as a direct result of such failure Tenant is unable to obtain a temporary or permanent certificate of occupancy for the Premises upon substantial completion of the Tenant Improvements; or (ii) substantial completion of the Warm Shell Improvements or Tenant Improvements is delayed directly and solely as a result of any of the following and such delay could not have been mitigated by Tenant using commercially reasonable measures, which delay occurs after the Delivery Date and before the Commencement Date and does not result from Tenant's interference or delay in connection with completion of the Tenant Improvements or after a Tenant Default or Work Letter Draw Event: (a) subject to Paragraph 8 above, unreasonable interference by Landlord or Landlord's Contractor with the construction of the Warm Shell Improvements or the Tenant Improvements; (b) Landlord's failure to comply with any deadlines for response to, or submissions from, Tenant as required by this Work Letter; (c) any material Discretionary Changes to Landlord's Plans or the Warm Shell Plans after their final approval by applicable governmental entities (other than Tenant Modifications) that directly affect Tenant's Plans or the Tenant Improvements; and/or (d) Landlord failure to complete portions of the Base Building and/or other improvements on the Project that are Landlord's obligation to complete hereunder, and as a direct result of such failure Tenant and Tenant's contractors do not have access to the Premises to the extent required to complete the Warm Shell Improvements and/or Tenant Improvements. Tenant shall give Landlord at least five (5) days prior notice if Tenant becomes aware that Landlord is in danger of causing a Landlord Delay, and if Landlord takes appropriate measures to prevent such delay within such five (5) day period, no adjustment to the Commencement Date shall be made on account of such Landlord; provided, however, that if such delay was not reasonably foreseeable by Tenant, the five (5) day period for prior notice and opportunity to mitigate provided above shall be changed to forty-eight (48) hours after Tenant becomes aware of such delay or potential delay.

  • Addition Notice With respect to the transfer of Subsequent Mortgage Loans to the Trust Fund pursuant to Section 2.08, a notice of the Depositor's designation of the Subsequent Mortgage Loans to be sold to the Trust Fund and the aggregate principal balance of such Subsequent Mortgage Loans as of the Subsequent Cut-off Date. The Addition Notice shall be given not later than three Business Days prior to the related Subsequent Transfer Date and shall be substantially in the form attached hereto as Exhibit P.