NOTICE TO BUYER OF LABOR DISPUTES Sample Clauses

NOTICE TO BUYER OF LABOR DISPUTES. Whenever Seller has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Contract, Seller shall immediately give notice thereof, including all relevant information, to Buyer.
Sample 1Sample 2Sample 3See All (146)
AutoNDA by SimpleDocs
NOTICE TO BUYER OF LABOR DISPUTES. (a) Whenever Seller has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Order, Seller shall immediately give notice thereof, including all relevant information, with respect thereto, to Buyer. (b) Xxxxxx agrees to insert the substance of this clause, including this paragraph (b), in any subcontract hereunder to which a labor dispute may delay the timely performance of this Order.
Sample 1Sample 2Sample 3See All (6)
NOTICE TO BUYER OF LABOR DISPUTES. (1) Whenever an actual or potential labor dispute is delaying or threatening to delay the performance of this Agreement, Seller shall immediately give notice thereof to Buyer. Such notice shall include all relevant information with respect to such disputes.
Sample 1Sample 2Sample 3See All (6)
NOTICE TO BUYER OF LABOR DISPUTES. Whenever Seller has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this PO, Seller shall immediately give notice thereof, including all relevant information, to Buyer.
Sample 1Sample 2Sample 3See All (5)
NOTICE TO BUYER OF LABOR DISPUTES. Whenever Seller has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this contract, Seller shall immediately give notice thereof, including all relevant information, whether Buyer has requested such status or not. When requested by Buyer, Seller will in a timely manner provide status on labour contracts and pending negotiations and prepare a contingency plan including incurred costs to address potential disruptions to the satisfaction of Buyer acting reasonably. Whenever Seller has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this contract, Seller shall immediately give notice thereof, including all relevant information, to Buyer.
Sample 1Sample 2See All (5)
NOTICE TO BUYER OF LABOR DISPUTES. Whenever Supplier knows or, in the exercise of reasonable judgment, should know, that any actual or potential labor dispute is delaying or threatens to delay Supplier’s timely performance of the Purchase Order, Supplier shall immediately provide written notice and all relevant information relating thereto to Buyer. Supplier shall insert the substance of this Paragraph 17 in any subcontract as to which a labor dispute may delay the timely performance of the Purchase Order.
Sample 1Sample 2Sample 3
NOTICE TO BUYER OF LABOR DISPUTES. Whenever Seller has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this contract, Seller shall immediately give notice thereof, including all relevant information, with respect hereto to Buyer. Seller agrees to insert the substance of this clause in any subcontract hereunder as to which a labor dispute may delay the timely performance of this contract.
Sample 1Sample 2
AutoNDA by SimpleDocs
NOTICE TO BUYER OF LABOR DISPUTES. Whenever Seller has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Contract, Seller shall immediately give notice, including all relevant information, to Buyer. GENERAL DYNAMICS LAND SYSTEMS 00-000-0000 (11/01/15)
Sample 1
NOTICE TO BUYER OF LABOR DISPUTES. Whenever Seller has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Contract, Seller shall immediately give notice thereof, including all relevant information, to Buyer PACKING AND SHIPPING Seller shall pack the materials to prevent damage and deterioration. Unless otherwise set forth in this Contract, Seller shall package the goods in accordance with the requirements of Boeing Document D37522-6 “Supplier Packaging”. Buyer may charge Seller for damage to or deterioration of any goods resulting from improper packing or packaging. If the Contract specifies FOB destination (place of delivery), then in addition to any other shipping instructions, Seller shall forward materials freight prepaid. Seller shall make the transportation arrangements, pay the shipping costs, and remain responsible for the materials until the materials are delivered and the Buyer takes possession at the destination. If the Contract specifies FOB origin (place of shipment), then in addition to any other shipping instructions, Seller shall forward goods collect. For goods shipped within the United States, Seller shall make no declaration concerning the value of the goods shipped except on goods where the tariff rating is dependent upon released or declared value. In such event, Seller shall release or declare such value at the maximum value within the lowest rating. Seller will ship the goods in accordance with the provisions set forth in the Boeing Domestic Shipment Routing Guide to be accessed through Buyer’s supplier portal at xxxxx://xxxxxx.xxxxxxx.xxx/. Sellers need a One Time Password (OTP) token to log into the Boeing Supplier Portal. Upon Xxxxx’s request, Seller will identify packaging charges showing material and labor costs for container fabrication. Seller shall provide with each container shipped under this Contract an Advanced Shipping Notice (“ASN”). For each container shipped, Seller shall provide two (2) readable copies of the ASN barcode as follows: one (1) copy is to be securely affixed to the outside of each container and one (1) copy is to be loose inside each container. Non-conforming shipments are subject to rejection and repackaging at Seller’s expense. Instructions and guidelines related to the ASN process can be found on the Boeing Supplier Portal. Seller shall access by selecting the “Enterprise ASN Instructions” hyper-link under the header “Exostar Resources”. A copy of these instructions can...
Sample 1

Related to NOTICE TO BUYER OF LABOR DISPUTES

  • Absence of Labor Dispute No labor dispute with the employees of the Company or any of its subsidiaries exists or, to the knowledge of the Company, is imminent, and the Company is not aware of any existing or imminent labor disturbance by the employees of any of its or any subsidiary’s principal suppliers, manufacturers, customers or contractors, which, in either case, would result in a Material Adverse Effect.

  • Absence of Labor Disputes No labor dispute with the employees of the Company or any of its subsidiaries exists or, to the knowledge of the Company, is imminent, which would reasonably be expected to result in a Material Adverse Effect.

  • No Labor Dispute No labor disturbance by or dispute with the employees of any of the Partnership Entities exists or, to the knowledge of the Partnership Parties, is imminent or threatened that could reasonably be expected to have a Material Adverse Effect.

  • No Labor Disputes No labor disturbance by or dispute with employees of the Company or any of its subsidiaries exists or, to the knowledge of the Company, is contemplated or threatened, and the Company is not aware of any existing or imminent labor disturbance by, or dispute with, the employees of any of its or its subsidiaries’ principal suppliers, contractors or customers, except as would not have a Material Adverse Effect.

  • Litigation, Labor Controversies, etc There is no pending or, to the knowledge of the Borrower or any of its Subsidiaries, threatened litigation, action, proceeding or labor controversy

  • Labor Disputes No labor disturbance by or dispute with employees of the Company or any of its Subsidiaries exists or, to the knowledge of the Company, is threatened which would reasonably be expected to result in a Material Adverse Effect.

  • Corrective Action Plan Within fifteen (15) Business Days following the establishment of the Joint Remediation Committee, the Purchasers, in consultation with the Sellers, shall prepare and submit to the Joint Remediation Committee an initial draft of the Corrective Action Plan. The parties shall work in good faith through the Joint Remediation Committee to finalize the Corrective Action Plan within fifteen (15) Business Days of the Purchasers’ submission of the initial draft of the Correct Action Plan. At the end of such period, if the Sellers reasonably determine that the Corrective Action Plan proposed by the Purchasers (as may be modified over the course of such period) would not reasonably be expected to satisfactorily address the Major Default, then the Sellers may escalate the issue to the Head of Commercial Capital (or equivalent leader of any successor business unit) of the Seller Group and the Chief Executive Officer of the Bank Assets Purchaser (the “Senior Executives”) and the Senior Executives shall work collaboratively (including with the Joint Remediation Committee) to develop a mutually agreeable Corrective Action Plan within fifteen (15) Business Days.

  • Labor Disputes; Compliance (a) Seller has complied in all material respects with all Legal Requirements relating to employment practices, terms and conditions of employment, equal employment opportunity, nondiscrimination, immigration, wages, hours, benefits, collective bargaining and other employment practices, the payment of social security and similar Taxes and occupational safety and health. Seller is not liable for the payment of any Taxes, fines, penalties, or other amounts, however designated, for failure to comply with any of the foregoing Legal Requirements.

  • Notice of Arbitration If a Person asserts that there exists a Dispute, then such Person (the “Disputing Person”) will give each other Person involved in such Dispute a written notice setting forth the nature of the asserted Dispute. If all such Persons do not resolve any such asserted Dispute prior to the 10th business day after such notice is given, then any of them may commence arbitration pursuant to this Paragraph 19 by giving each other Person involved in such Dispute a written notice to that effect (an “Arbitration Notice”), setting forth any matters which are required to be set forth therein in accordance with the AAA Rules.

  • Expedited Arbitration (a) The Parties may by mutual agreement refer to expedited arbitration any outstanding grievances considered suitable for this process, and shall set dates and locations for hearings of groups of grievances considered suitable for expedited arbitration.

Time is Money Join Law Insider Premium to draft better contracts faster.