Landlord Remedies definition

Landlord Remedies. If tenant violates any part of this lease agreement including non- payment of rent, the tenant is in default of this lease agreement. In the event of a default, the landlord may initiate legal proceedings in accordance with local and state regulations to evict or have tenant removed from the lease premise as well as seek judgment against tenant for monies owed to landlord as a result of tenant’s default. Should it be necessary for landlord to employ an attorney to enforce any of the conditions or covenants hereof, including the collection of rentals or gaining possession of the premise, tenant agrees to pay all expenses so incurred, including a reasonable attorney’s fee.  The tenant agrees that any expenses and/or damages incurred as a result of a breach of lease agreement including attorney’s fees and cost will be paid to the landlord  The tenant agrees that any court costs and/or fee incurred as a result of breach of lease agreement will be paid to the landlord  All rent for the balance of the term of this lease agreement is immediately due to the landlord and the landlord may xxx for the entire balance as well as any damages, expenses, legal fees and costs. Returned Checks: Tenant agrees to pay $30.00 processing fee for each check submitted by tenant that is returned by the financial institution for any reason, including insufficient funds and closed account. This fee shall be due without demand and must be tendered by certified check or cash, together with the rent and any late fees due. If a check submitted by tenant is returned, lessor reserves the right to require that all future payments by tenant be tendered by certified check, money order or cash.
Sample 1

Examples of Landlord Remedies in a sentence

  • In Section 12 (Landlord Remedies), the tenant agrees that the landlord can give the tenant 10 days notice to leave the property for reasons not related to payment of rent.

  • Council Journal of Proceedings, September 8, 1986, page 33771) S-12-130 Landlord Remedies.

  • Landlord Remedies The bill amends the landlord’s available remedies in s.

  • As a result, the TSOs have recommended conditions with respect to TOR1 and TOR2 dispatch below.These can be split in two: frequency conditions and other system conditions.

  • Backer, Pennsylvania Landlord Remedies: Collection of Rent and Recovery of Possession, 89 DICK.

  • When there should be no confusion, we will usully drop and write simply µ for µ.If A and B are two Boolean algebras, then H(A, B) denotes the family of all homo- morphisms from A to B.

  • Chapters 17 and 18Condominiums and Cooperatives; Bylaws, Time-shares 1.0Leases, Residential and Commercial; Terms, Gross vs NetLease, Landlord Remedies, Tenant Remedies, Sublets 2.0SC Landlord Tenant Act Final Examination (Chapters 7, 10 -13) 2.5 hours ********* The instructor reserves the right to make any changes in the above referenced course outline and such changes will be announced in class.

  • Hans Schulte-Nölke: “The way forward in European consumer contract law: optional instrument instead of further deconstruction of national private laws”, p.

  • NYC Landlords Who Improved the Highest Percentage of Their ...Landlord Remedies for Tenant Rent Defaults: This is currently being addressed by the Provinceof Ontario in Bill 229 which has not yet passed, but when it does then, based on the current wording of Bill 229, it will extend the temporary protections afforded to commercial tenants by limiting rights of re-entry and distress afforded to landlords ...

  • This Article focuses instead on the significant changes in Articles 3 and 4 (Landlord Duties and Tenant Remedies), Articles 5 and 6 (Tenant Duties and Landlord Remedies), Article 7 (Access to Dwelling Unit), Article 8 (Periodic and Holdover Tenancy; Death of Tenant), Article 9 (Retaliation), Article 10 (Disposition of Tenant Personal Property), Article 11 (Effect of Domestic Violence, Dating Violence, Stalking, or Sexual Assault), and Article 12 (Security Deposits, Fees, and Unearned Rent).

Related to Landlord Remedies

  • Landlord Default shall have the meaning given such term in Article 14.

  • Landlord Delay shall occur if either: (i) Landlord fails to complete the Base Building and/or other improvements on the Project that are required by the DDA, the Parking REA and/or the CC&Rs, and as a direct result of such failure Tenant is unable to obtain a temporary or permanent certificate of occupancy for the Premises upon substantial completion of the Tenant Improvements; or (ii) substantial completion of the Warm Shell Improvements or Tenant Improvements is delayed directly and solely as a result of any of the following and such delay could not have been mitigated by Tenant using commercially reasonable measures, which delay occurs after the Delivery Date and before the Commencement Date and does not result from Tenant's interference or delay in connection with completion of the Tenant Improvements or after a Tenant Default or Work Letter Draw Event: (a) subject to Paragraph 8 above, unreasonable interference by Landlord or Landlord's Contractor with the construction of the Warm Shell Improvements or the Tenant Improvements; (b) Landlord's failure to comply with any deadlines for response to, or submissions from, Tenant as required by this Work Letter; (c) any material Discretionary Changes to Landlord's Plans or the Warm Shell Plans after their final approval by applicable governmental entities (other than Tenant Modifications) that directly affect Tenant's Plans or the Tenant Improvements; and/or (d) Landlord failure to complete portions of the Base Building and/or other improvements on the Project that are Landlord's obligation to complete hereunder, and as a direct result of such failure Tenant and Tenant's contractors do not have access to the Premises to the extent required to complete the Warm Shell Improvements and/or Tenant Improvements. Tenant shall give Landlord at least five (5) days prior notice if Tenant becomes aware that Landlord is in danger of causing a Landlord Delay, and if Landlord takes appropriate measures to prevent such delay within such five (5) day period, no adjustment to the Commencement Date shall be made on account of such Landlord; provided, however, that if such delay was not reasonably foreseeable by Tenant, the five (5) day period for prior notice and opportunity to mitigate provided above shall be changed to forty-eight (48) hours after Tenant becomes aware of such delay or potential delay.

  • Landlord Waiver means a letter in form and substance reasonably acceptable to the Administrative Agent and executed by a landlord in respect of Inventory of a Loan Party located at any leased premises of a Loan Party pursuant to which such landlord, among other things, waives or subordinates on terms and conditions reasonably acceptable to the Administrative Agent any Lien such landlord may have in respect of such Inventory.

  • Landlord Personal Property Collateral Access Agreement means a Landlord Waiver and Consent Agreement substantially in the form of Exhibit K with such amendments or modifications as may be approved by the Collateral Agent.

  • Landlord Parties means Landlord and Property Manager and their respective officers, directors, partners, shareholders, members and employees.

  • Major Damage means damage that in the estimation of the surveyor exceeds USD

  • Landlord Party or “Landlord Parties” shall mean Landlord, any affiliate of Landlord, Landlord’s managing agents for the Building, each mortgagee (if any), each ground lessor (if any), and each of their respective direct or indirect partners, officers, shareholders, directors, members, trustees, beneficiaries, servants, employees, principals, contractors, licensees, agents or representatives. For the purposes of this Lease, the term “Tenant Party” or “Tenant Parties” shall mean Tenant, any affiliate of Tenant, any permitted subtenant or any other permitted occupant of the Premises, and each of their respective direct or indirect partners, officers, shareholders, directors, members, trustees, beneficiaries, servants, employees, principals, contractors, licensees, agents, invitees or representatives.

  • Landlord Liens means liens on or against the Leased Property or any payment of Rent (a) which result from any act of, or any claim against, Landlord or any owner (other than Tenant) of a direct or indirect interest in the Leased Property, or which result from any violation by Landlord of any terms of this Agreement or the Purchase Agreement, or (b) which result from liens in favor of any taxing authority by reason of any tax owed by Landlord or any fee owner of a direct or indirect interest in the Leased Property; provided, however, that "Landlord Lien" shall not include any lien resulting from any tax for which Tenant is obligated to pay or indemnify Landlord against until such time as Tenant shall have already paid to or on behalf of Landlord the tax or the required indemnity with respect to the same.

  • Major Tenants has the meaning ascribed to such term in Section 7.2.

  • Premises Building Partial Damage shall herein mean damage or destruction to the building of which the Premises are a part to the extent that the cost of repair is less than 50% of the then replacement cost of such building as a whole.

  • Landlord Work means the work, if any, that Landlord is obligated to perform in the Premises pursuant to a separate agreement (the “Work Letter”), if any, attached to this Lease as Exhibit C.

  • Master Lease means that certain [Master Lease title], relating to the leasing of, inter alia, the Healthcare Facility by Borrower to Master Tenant.

  • Landlord shall have the meaning given such term in the preambles to this Agreement and shall also include their respective permitted successors and assigns.

  • Landlord Reserve means, as to each location at which a Borrower has Inventory or books and records located and as to which a Collateral Access Agreement has not been received by Agent, a reserve in an amount equal to the greater of (a) the number of months' rent for which the landlord will have, under applicable law, a Lien in the Inventory of such Borrower to secure the payment of rent or other amounts under the lease relative to such location, or (b) 3 months' rent under the lease relative to such location.

  • Premises Partial Damage means damage or destruction to the improvements on the Premises, other than Lessee Owned Alterations and Utility Installations, the repair cost of which damage or destruction is less than 50% of the then Replacement Cost of the Premises immediately prior to such damage or destruction, excluding from such calculation the value of the land and Lessee Owned Alterations and Utility Installations.

  • Leasehold Mortgagee means the holder of a Leasehold Mortgage.

  • Tenant Delay as used in the Lease or this Agreement shall mean any delay that Landlord may encounter in the performance of Landlord’s obligations under the Lease or this Agreement because of any act or omission of any nature by Tenant or its agents or contractors, including any: (1) delay attributable to changes in or additions to the Approved Plans or to the Landlord’s Work requested by Tenant; (2) delay attributable to the postponement of any Landlord’s Work at the request of Tenant; (3) delay caused by a Change Order requested by Tenant; (4) delay attributable to the failure of Tenant to pay, when due, any amounts required to be paid by Tenant pursuant to the Lease; or (5) delay attributable to a failure of Tenant to employ union labor for Tenant’s work at the Premises during the time the Landlord’s Work is being constructed. Tenant shall pay all actual costs and expenses incurred by Landlord which result from any Tenant Delay and the Commencement Date of the Lease shall be accelerated one (1) day for each day the Premises is not Ready for Occupancy as a result of a Tenant Delay. No Tenant Delay shall be deemed to have occurred unless Landlord gives Tenant prior written notice or written notice within five (5) days of the occurrence, as reasonable under the circumstances, specifying the claimed reasons for such Tenant Delay, and Tenant shall fail to promptly correct or cure such Tenant Delay. There shall be excluded from the number of days of any Tenant Delay, or any of the following events of force majeure: labor disputes, fire, unusual delay in transportation, adverse weather conditions not reasonably anticipatable, unavoidable casualties, delays in obtaining permits or governmental approvals or any other causes beyond Landlord’s or its contractor’s reasonable control (and other than for financial reasons) (collectively, “Force Majeure Delays”).

  • Structural damage means a covered building, regardless of the date of its construction, has experienced the following.

  • Landlord Agreement means an agreement substantially in the form provided by Lender to Borrower or such other form as Lender may agree to accept.

  • Parking space leasing data means the following government data on an application for, or lease of, a parking space: residence address, home telephone number, beginning and ending work hours, place of employment, location of parking space, and work telephone number.

  • Tenant’s Property means Removable Installations and, other than Installations, any personal property or equipment of Tenant that may be removed without material damage to the Premises, and (z) “Installations” means all property of any kind paid for by Landlord, all Alterations, all fixtures, and all partitions, hardware, built-in machinery, built-in casework and cabinets and other similar additions, equipment, property and improvements built into the Premises so as to become an integral part of the Premises, including, without limitation, fume hoods which penetrate the roof or plenum area, built-in cold rooms, built-in warm rooms, walk-in cold rooms, walk-in warm rooms, deionized water systems, glass washing equipment, autoclaves, chillers, built-in plumbing, electrical and mechanical equipment and systems, and any power generator and transfer switch.

  • Tenant means a person entitled under a rental agreement to occupy a dwelling unit to the exclusion of others.

  • this Tenant Work Letter means the relevant portion of Sections 1 through 6 of this Tenant Work Letter.

  • Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.

  • Major Tenant means a tenant of a Loan Party under a lease of Property which entitles it to occupy 15,000 square feet or more of the net rentable area of such Property.

  • Tenant Delays means delays caused by: (i) requirements of the Plans and Specifications requested by Tenant that do not conform to Landlord’s building standards for office and lab build-out, or which contain long lead-time or non-standard items requested by Tenant; provided that Landlord has notified Tenant of such deviations upon execution of this Lease (ii) any material change in the Plans and Specifications requested by Tenant and agreed to by Landlord; (iii) any request by Tenant for a delay in the commencement or completion of the Initial Tenant Improvements for any reason; (iv) Tenant delay in finalizing and approving the design of the vivarium and value engineering of same or (v) any other act or omission of Tenant or its employees, agents or contractors which reasonably inhibits the Landlord from timely completing the Initial Tenant Improvements including, without limitation any delays caused by Tenant’s presence in the Premises prior to the Term Commencement Date. The Premises shall not be deemed to be incomplete if only minor or insubstantial details of construction, decoration or mechanical adjustments remain to be done which do not unreasonably interfere with Tenant’s occupancy of the Premises. If as a result of Tenant Delays the Premises are deemed ready for Tenant’s occupancy, pursuant to the foregoing (and the term shall have commenced by reason thereof), but the Premises are not in fact actually ready for Tenant’s occupancy, Tenant shall not (except with Landlord’s consent not to be unreasonably withheld, conditioned or delayed) be entitled to take possession of the Premises for the permitted use until the Premises are in fact actually ready for such occupancy.