Hold Points definition

Hold Points means the hold points described in clauses 2.3(a)(i) to (iii) of this schedule.
Sample 1Sample 2Sample 3
Hold Points has the meaning given in Schedule 11 – Integrated Management System Requirements.
Sample 1
Hold Points. 5: Refer to schedule of hold points in Annexure 1. GENERAL QUALITY CONTROL The latest revision of specification PROCESS FOR THE CHECKING OF DISTRIBUTION SUBSTATION CONSTRUCTION, before handing over for Commercial Operation’ shall be applicable to this project and must be completed in full by the Clerk of Works and returned to the Project Engineer with all the “as - built” documentation. Reference must also be made to Annexure 1 of this document, for a schedule of all the applicable hold points that have been identified as critical to the quality control process involved in the construction of this project, which are to be observed by the contractor(s) involved and enforced accordingly. Furthermore, contractor “check lists” have been established for all the main activities involved in the construction of this project, to assist all affected parties in achieving a final quality product on completion of the project. Refer Part 4 ‘Project Management’, item 4.5, of the overall Project Package. The Contractor is further referred to SANS 1921: 2004: Construction and Management Requirements for Works Contracts, Part 1: General Engineering and Construction Works. These specifications shall be applicable to the contract under consideration and the Contractor shall comply with all requirements relevant to the project. Certain aspects however require further attention as described hereafter. QUALITY ASSURANCE (QA) (Read with SANS 1921 – 1: 2004 clause 4.4) The Contractor will be solely responsible for the production of work that complies with the Specifications to the satisfaction of the Engineer. To this end it will be the full responsibility of the Contractor to institute an appropriate Quality Assurance (QA) system on site. The Engineer will audit the Contractor's quality assurance (QA) system on a regular basis to verify that adequate independent checks and tests are being carried out and to ensure that the Contractor's own control is sufficient to identify any possible quality problems which could cause a delay or failure. Upon completion and submission of each portion of the Works to the Engineer for examination, the Contractor shall furnish the Engineer with the results of relevant tests, measurements and levels, thereby indicating compliance with the Specifications. “Hold Point No. 6” – Furthermore, the contractor shall implement his own quality check system throughout the duration of this project. The contractor shall provide regular feedback on all aspects o...
Sample 1

Examples of Hold Points in a sentence

  • Nothing in this Section 3.4 shall be deemed to limit the Design-Builder’s obligations to provide the Commission access to all Work as provided in other Sections of this Agreement, nor shall the Commission’s observation of the Work at Construction Hold Points be construed to relieve the Design-Builder of its obligation to correct defective Work if defects are discovered after an observation.

  • Quality assurance and quality control activities at Major Subcontractors shall be limited to participation in scheduled audits and execution of Witness Points identified as the Witness Points and Hold Points in the manufacturing and fabrication plans for the Equipment, such as in-process testing and final product review for acceptance.

  • Contractor shall provide Owner access to or copies of these manufacturing and fabrication schedules for Equipment identified in Exhibit Q and the regular updates to these schedules, such that Owner has advance notice of approaching scheduled Witness Points and Hold Points.

  • In cases where Contractor incurs additional cost or delay in the Project Schedule from its Major Subcontractors due to Owner's request to add additional Witness Points and/or Hold Points beyond those identified by Contractor, Contractor shall be entitled to a Change Order pursuant to Article 9.

  • After review, Owner may identify additional Witness Points and Hold Points and Owner shall notify Contractor of any Owner-designated Witness Points or Hold Points that they shall attend.

  • In addition, Work associated with concrete work on ADA compliant items (sidewalks, ramps, landings, floors, platforms, etc.) shall be considered Hold Points.

  • Amtrak, its representatives and agents, intend to perform quality-control activities required to verify that the Work complies with Amtrak’s and other legal requirements, whether specified or not, at Hold Points, and intend to conduct a final inspection prior to payment.

  • The City shall indicate all Hold Points on a baseline schedule, with a three week look ahead, such schedule to be shared with Amtrak and updated weekly.

  • Owner shall acknowledge the notification of Owner-designated Hold Points within five (5) Business Days and indicate whether or not it intends to attend the activity that is the subject of the Hold Point.

  • Hold Points shall be deemed to occur, at a minimum, prior to any concrete pour when forms and rebar are in place, after any concrete pour when the concrete has cured, before any walls are closed.


More Definitions of Hold Points

Hold Points means a critical step in a manufacturing, construction or testing process beyond which Contractor or a Subcontractor cannot proceed except pursuant to the provisions in Section 18.05(b).
Sample 1
Hold Points means a specified event in the Contract Documents whereby NMAAI shall seek approval of the event prior to proceeding to the next event. Hold Points shall be specified in the CPM Schedule by NMAAI as outlined in Section 9 of the Performance Standards, titled “Acceptance Testing.” Indemnified Parties means the City, its elected officials, legally designated officials, appointee, Agents, and employees.
Sample 1
Hold Points means those points beyond which the Work shall not proceed without review and release by LGL. The Contractor shall agree the “Hold Points” with LGL prior to the work commencing and in accordance with the Manufacturer’s recommendations and procedures. The “Hold Points” shall form part of the Contractor’s schedule. Unless otherwise directed by LGL, the Contractor shall give at least two (2) working days prior notice of each Hold Point and shall ensure that all relevant test and verification results are available for inspection by LGL at the time of the Hold Point. The Contractor shall allow for one (1) working day at the Hold Point for LGL to attend the Site and inspect the work and documentation.
Sample 1
Hold Points means the points described in clause 46 together with:
Sample 1

Related to Hold Points

  • MSCF means one thousand standard cubic feet.

  • Threshold Percentage means 15%.

  • Threshold Period shall have the meaning set forth in Section 6(d).

  • Threshold Price is the lowest price (except to the extent otherwise provided in Section 2.6) at which the Company may sell Shares during the applicable Pricing Period as set forth in a Fixed Request Notice (not taking into account the applicable percentage discount during such Pricing Period determined in accordance with Section 2.2); provided, however, that at no time shall the Threshold Price be lower than $3.00 per share unless the Company and the Investor mutually shall agree.

  • Pricing Period means the five (5) consecutive Trading Days after the Advance Notice Date.

  • Receipt Point(s means the receipt points set forth in Section 6 of this Toll Schedule.

  • H-point means the pivot centre of the torso and thigh of the H-point machine when installed in a vehicle seat in accordance with Annex 12. Once determined in accordance with the procedure described in Annex 12, the "H" point is considered fixed in relation to the seat-cushion structure and is considered to move with it when the seat is adjusted.

  • Measurement Point means the emission source for which continuous emission measurement systems (CEMS) are used for emission measurement, or the cross-section of a pipeline system for which the CO2 flow is determined using continuous measurement systems;

  • Meet Point A point, designated by the Parties, at which one Party’s responsibility for service begins and the other Party’s responsibility ends.

  • GPM means gallons per minute.

  • Concentration Reserve Percentage means, at any time of determination, the largest of: (a) the sum of the five (5) largest Obligor Percentages of the Group D Obligors, (b) the sum of the three (3) largest Obligor Percentages of the Group C Obligors, (c) the sum of the two (2) largest Obligor Percentages of the Group B Obligors and (d) the largest Obligor Percentage of the Group A Obligors.

  • Crude Petroleum means the direct product of oil wells or a mixture of the indirect products transportable like the direct products and containing not more than two percent (2%) of sediment, water, and other impurities.

  • Cubic foot of gas means the amount of gas required to fill a cubic foot of space when the gas is at an absolute pressure of fourteen and seventy-three hundredths (14.73) pounds per square inch at a temperature of sixty (60) degrees Fahrenheit.

  • Meet-Point Billing (MPB means the billing associated with interconnection of facilities between two (2) or more LECs for the routing of traffic to and from an IXC with which one of the LECs does not have a direct connection. In a multi-bill environment, each Party bills the appropriate tariffed rate for its portion of a jointly provided Switched Exchange Access Service.

  • SOFR Reserve Percentage means, for any day, the maximum effective percentage in effect on such day, if any, as prescribed by the Board of Governors of the Federal Reserve System (or any successor) for determining the reserve requirements (including, without limitation, supplemental, marginal and emergency reserve requirements) with respect to SOFR funding.

  • Net metering period means the 12-month period following the date of final interconnection of the

  • Signaling Transfer Point (“STP”) means a signaling point that performs message routing functions and provides information for the routing of messages between signaling points within or between CCIS networks. An STP transmits, receives and processes CCIS messages.

  • Net meter means an appropriate energy meter capable of recording both import & export of electricity or a pair of meters one each for recording the import and export of electricity as the case may be;

  • Pricing Service means J.J. Kenny or any pricing service designated by the Board of Directors of the Corporation provided the Corporation obtains written assurance from S&P and Moody's that such designation will not impair the rating then assigned by S&P and Moody's to the AMPS.

  • Minimum Dilution Reserve Percentage means, at any time of determination, the product (expressed as a percentage and rounded to the nearest 1/100th of 1%, with 5/1000th of 1% rounded upward) of (a) the average of the Dilution Ratios for the twelve (12) most recent Fiscal Months, multiplied by (b) the Dilution Horizon Ratio.

  • Euro-Dollar Reserve Percentage has the meaning set forth in Section 2.06(c).

  • Throughput means the measure of production, or factor related to production, used to determine the relationship between the amount of energy used by the target unit and the levels of activity of the target unit, as set out in Schedule 6 to an underlying agreement; “the Tribunal” means the First-tier Tribunal established under the Xxxxxxxx Xxxxxx xxx Xxxxxxxxxxx Xxx 00000;

  • Original Applicable Credit Support Percentage With respect to each of the following Classes of Subordinated Certificates, the corresponding percentage described below, as of the Closing Date: Class B-1 % Class B-2 % Class B-3 % Class B-4 % Class B-5 % Class B-6 %

  • Capacity Market Seller means a Member that owns, or has the contractual authority to control the output or load reduction capability of, a Capacity Resource, that has not transferred such authority to another entity, and that offers such resource in the Base Residual Auction or an Incremental Auction.

  • Servicing Fee Percentage With respect to each Mortgage Loan, the percentage specified on the Servicer Mortgage Loan Schedule.

  • Dilution Reserve Percentage means, on any day, the product of (a) the sum of (i) 2.25 times the average of the Dilution Ratios for the twelve most recent Fiscal Months, plus (ii) the Dilution Volatility Component, multiplied by (b) the Dilution Horizon Ratio.