Guaranteed Dates definition

Guaranteed Dates means the ‘No Later Than’ dates for delivery of the Goods to the Site and for Substantial Completion as guaranteed by Supplier in Exhibit 1.
Sample 1Sample 2Sample 3
Guaranteed Dates means the ‘No Later Than’ dates as guaranteed by Contractor in Exhibit 1.
Sample 1Sample 2Sample 3
Guaranteed Dates mean the Guaranteed Mechanical Completion Date and the Guaranteed Final Completion Date.
Sample 1Sample 2

Examples of Guaranteed Dates in a sentence

  • As used herein, the term “Owner Caused Delay” shall mean a delay that will adversely and materially affect the critical path of the Work or Contractor’s timely completion of its Guaranteed Dates, which delay was caused primarily as a result of Owner’s unexcused delay or failure to perform its obligations hereunder.

  • Contractor shall promptly notify Owner in writing of any occurrence that Contractor has reason to believe will adversely affect the completion of the Work by the Guaranteed Dates or materially adversely affect completion of the Work in accordance with the Project Schedule.

  • In the event Contractor desires to claim an Owner Caused Delay, it must submit a request for Changes pursuant to Section 7.02(c), and Contractor shall be entitled to suspension of performance or extension of time (including an extension of any Guaranteed Dates) together with demonstrated reasonable extended Job Site overhead, standby labor or other costs, including but not limited to, idle equipment costs, incurred by reason of such delay pursuant to the terms of this Section and Section 7.02(c).

  • The CPM Schedule shall represent Contractor's best judgment as to how it shall complete the Work in compliance with the Schedule Milestones including the Phase Substantial Completion Guaranteed Dates, the PV Power Plant Substantial Completion Guaranteed Date, and the Final Completion Guaranteed Date.

  • The CPM Schedule shall be consistent with the Key Dates and shall represent Contractor’s best judgment as to how it shall complete the Work in compliance with the Guaranteed Dates.

  • The only Guaranteed Dates for such Units are as designated in Section 4.1(a).

  • The CPM Schedule shall be consistent with the Project Schedule, including the Milestone Schedule Dates and the Guaranteed Dates and shall represent Contractor’s best judgment as to how it shall complete the Work in compliance with the Project Schedule, including the Milestone Schedule Dates and the Guaranteed Dates.

  • Owner's review of the CPM Schedule shall not relieve Contractor of any obligations for the performance of the Work, change the Phase Substantial Completion Guaranteed Dates, the PV Power Plant Substantial Completion Guaranteed Dates, or the Final Completion Guaranteed Dates.

  • Notwithstanding anything to the contrary in the foregoing, Contractor shall remain solely responsible for performing the Work in accordance with this Agreement, including Contractor’s obligation to achieve Substantial Completion of each Unit by the applicable Substantial Completion Guaranteed Dates.

  • Failure by Owner to pay any amount reasonably in dispute that is identified in accordance with Section 6.5 until resolution of such dispute in accordance with this Agreement shall not alleviate, diminish, modify nor excuse the performance of, Contractor’s obligations to perform hereunder in any respect, including Contractor’s obligation to meet the Project Guaranteed Dates.


More Definitions of Guaranteed Dates

Guaranteed Dates mean the Guaranteed Substantial Completion Dates and the Final Completion Date.
Sample 1
Guaranteed Dates means Guaranteed Interim Completion Date, Guaranteed Substantial Completion Date, Guaranteed FBG Mechanical Completion Date, and Final Acceptance Date.
Sample 1
Guaranteed Dates means the Guaranteed XXXX Slab Completion Date, the Guaranteed XXXX Mechanical Completion Date, Guaranteed HV Mechanical Completion Date, the Guaranteed In-Service Completion Date, and the Guaranteed Substantial Completion Date, in each case as set forth in Exhibit H-2, as such dates may be adjusted pursuant to this Agreement.
Sample 1
Guaranteed Dates means the guaranteed delivery date(s) set forth in the
Sample 1
Guaranteed Dates mean the Guaranteed Substantial Completion Dates. The Guaranteed Dates shall only be adjusted by Change Order as provided under this Agreement.
Sample 1

Related to Guaranteed Dates

  • Settlement Dates As determined pursuant to Section 9.4 of the Equity Definitions, subject to Section 9(k)(i) hereof.

  • fixed date means the date fixed in terms of section 1(2) as the date of commencement of this Act;

  • Payment Dates means, with respect to any Receivable, the date a payment is due in accordance with the Receivable Agreement with respect to such Receivable as in effect as of the date of determination.

  • Redemption Dates means, collectively, the Event of Default Redemption Dates, and the Optional Redemption Dates, each of the foregoing, individually, a Redemption Date.

  • Compounded Daily €STR means, with respect to any Interest Period, the rate of return of a daily compound interest investment (with the daily euro short-term rate as reference rate for the calculation of interest) as calculated by the Calculation Agent as at the relevant Interest Determination Date in accordance with the following formula (and the resulting percentage will be rounded if necessary to the nearest fifth decimal place, with 0.000005 being rounded upwards):

  • Compounded Daily SONIA means with respect to an Interest Accrual Period, the rate of return of a daily compound interest investment during the Observation Period corresponding to such Interest Accrual Period (with the daily Sterling overnight reference rate as reference rate for the calculation of interest) and will be calculated by the Calculation Agent (or such other party responsible for the calculation of the Rate of Interest, as specified in the Final Terms or Pricing Supplement) on the relevant Interest Determination Date, as follows, and the resulting percentage will be rounded, if necessary, to the fifth decimal place, with 0.000005 being rounded upwards: Where:

  • Compounded Daily SOFR means, in relation to a Floating Rate Interest Period, the rate of return of a daily compound interest investment (with SOFR as reference rate for the calculation of interest) during the related Observation Period and will be calculated by the Calculation Agent on the related Interest Determination Date as follows: Where:

  • Specified Date means any Redemption Date, any Payment Date for an Offer to Purchase or any date on which the Notes first become due and payable after an Event of Default.

  • Quarterly Payment Dates means each March 31, June 30, September 30 and December 31.

  • Vesting Dates means, as determined by the Board or by the Committee, the date as of which the Optionee shall be entitled to exercise the Options or part of the Options, as set forth in section 11 of the ISOP.

  • Repayment Dates means, subject to clause 7.3, each of the dates falling at six (6) monthly intervals after the Drawdown Date up to and including the date falling one hundred and forty four (144) months after the Drawdown Date;

  • Scheduled Issued Date or "SID" means the date the order is entered into Qwest's order distribution system.

  • Compounded Daily XXXXX means the rate of return of a daily compound interest investment (with the daily Sterling Overnight Index Average as the Reference Rate for the calculation of interest) and will be calculated by the Principal Paying Agent (or such other party responsible for the calculation of the Rate of Interest, as specified in the applicable Final Terms Document) on the Interest Determination Date, as follows, and the resulting percentage will be rounded if necessary to the fourth decimal place, with 0.00005 being rounded upwards: where:

  • Scheduled Completion Date shall be the date set forth in Clause 10.3;

  • Dates for this Program are defined as:

  • Performance Date means December 31, 2025. If the Locality, in consultation with VEDP, deems that good faith and reasonable efforts have been made and are being made by the Company to achieve the Targets, on or before the Performance Date the Locality may request an extension of the Performance Date by up to 15 months. Any extension of the Performance Date shall require the prior approval of the Company and the Board of Directors of VEDP (the “Board”). If the Performance Date is extended, the Locality shall send written notice of the extension to the Authority, the Company and VEDP and the date to which the Performance Date has been extended shall be the “Performance Date” for the purposes of this Agreement.

  • Required Date means the date given a Registered Entity in a notice from the Compliance Enforcement Authority by which some action by the Registered Entity is required.

  • Milestone Dates means the dates for completion of specified Project activities as contained in the Project Schedule.

  • Reset Dates The first day of each Calculation Period.

  • Settlement Cycle means the period of Clearance System Business Days following a transaction on the Relevant Exchange in the Underlying, during which period settlement will customarily take place according to the rules of such Relevant Exchange.

  • Quarterly Dates means the last Business Day of March, June, September and December in each year, the first of which shall be the first such day after the date hereof.

  • Performance Cycle means one or more periods of time, which may be of varying and overlapping durations, as the Administrator may select, over which the attainment of one or more Performance Criteria will be measured for the purpose of determining a grantee’s right to and the payment of a Restricted Stock Award, Restricted Stock Units, Performance Share Award or Cash-Based Award, the vesting and/or payment of which is subject to the attainment of one or more Performance Goals. Each such period shall not be less than 12 months.

  • Contract Price(s) means the price(s) tendered by the contractor and accepted by the Council for the execution of the contract.

  • Amortization Commencement Date means the date on which an Amortization Event is deemed to occur pursuant to Section 20 hereof.