Guaranteed Commercial Operations Date definition

Guaranteed Commercial Operations Date. The date specified as such in Attachment K (Guaranteed Project Milestones) of this Agreement, by which Seller guarantees that it will achieve the Commercial Operations Date.
Sample 1Sample 2Sample 3
Guaranteed Commercial Operations Date or “GCOD” means the date on which a Facility first achieves Commercial Operations.
Sample 1Sample 2Sample 3

Examples of Guaranteed Commercial Operations Date in a sentence

  • Seller's inability to achieve Commercial Operations by the Guaranteed Commercial Operations Date may cause Company to not meet applicable RPS requirements and require Company to devote substantial additional resources for administration and oversight activities.

  • Notwithstanding any other provision of this Article 15 (Events of Default) to the contrary, any failure of Seller to achieve any of the Guaranteed Project Milestones by the applicable Guaranteed Project Milestone Date, including Commercial Operations by the Guaranteed Commercial Operations Date, shall be governed by Article 13 (Guaranteed Project Milestones Including Commercial Operations) in lieu of this Article 15 (Events of Default).

  • If the Commercial Operations Date is not achieved by the Guaranteed Commercial Operations Date, as such date may be extended as provided in Section 13.3 (Guaranteed Project and Reporting Milestone Dates), the listing of the Company-Owned Interconnection Facilities required in this Agreement and the cost-estimates for such Company-Owned Interconnection Facilities are subject to review and revision.

  • The Parties shall have the rights and obligations set forth in Article 13 (Guaranteed Project Milestones Including Commercial Operations) in the event a condition or event of Force Majeure affects the achievement of a Guaranteed Project Milestone Date, including the Guaranteed Commercial Operations Date.

  • To guarantee undertaking the performance of Seller’s obligations under the Agreement for the period prior to the Commercial Operations Date (including but not limited to Seller’s obligation to meet the Guaranteed Commercial Operations Date), Seller shall provide satisfactory development period security to Company in the amount equal to $75 for each kilowatt of the Contract Capacity (the “Development Period Security”).

  • Proposals that will require system upgrades and the construction of which, in the reasonable judgment of the Company (in consultation with the Independent Observer), creates a significant risk that their Project’s Guaranteed Commercial Operations Date (“GCOD”) will not be met will not be considered in this RFP.

  • If the Commercial Operations Date is not achieved by the Guaranteed Commercial Operations Date, as such date may be extended as provided in 11.4 (Milestone Dates), the listing of the Company-Owned Interconnection Facilities required in this Agreement and the cost-estimates for such Company-Owned Interconnection Facilities are subject to review and revision.

  • To guarantee undertaking the performance of Seller's obligations under the Agreement for the period prior to the Commercial Operations Date (including but not limited to Seller's obligation to meet the Guaranteed Commercial Operations Date), Seller shall provide Development Period Security to Company within ten (10) Days of Execution Date of the Agreement.

  • Without limiting the generality of the preceding sentence, the earliest Day upon which a termination of this Agreement can be effective as a result of a failure to achieve Commercial Operations by the Guaranteed Commercial Operations Date would be the Day following expiration of the COD Xxxxx XX Period.

  • Page C-B-2) Entergy requires the Guaranteed Commercial Operations Date to be no later than 90 days from the Expected Commercial Operations Date.

Related to Guaranteed Commercial Operations Date

  • Guaranteed Commercial Operation Date has the meaning set forth in Section 3.9(c)(i).

  • Commercial Operations Date or "COD": The date on which Facility first achieves Commercial Operations.

  • Scheduled Commercial Operation Date shall have the meaning ascribed to it in Clause 5.4.1;

  • Commercial Operation Date means the date on which a Material Project is substantially complete and commercially operable.

  • Commercial Operation means the condition of operation in which the complete equipment covered under the Contract is officially declared by the Owner to be available for continuous operation at different loads up to and including rated capacity. Such declaration by the Owner, however, shall not relieve or prejudice the Contractor of any of his obligations under the Contract.

  • Commence commercial operation means, with regard to a unit that serves a generator, to have begun to produce steam, gas, or other heated medium used to generate electricity for sale or use, including test generation subject to the following:

  • Commercial Operations Upon satisfaction of the following conditions, the Facility shall be considered to have achieved Commercial Operations on the Day specified in Seller's written notice described below: (i) the Acceptance Test has been passed, (ii) all generating units have passed Control System Acceptance Tests, (iii) the Transfer Date has occurred, (iv) Seller has (1) provided to Company the Required Models (as defined in Section 6(a) (Seller's Obligation to Provide Models) of Attachment B (Facility Owned by Seller)) in the form of Source Code, (2) placed the current version of the Source Code for the Required Models with the Source Code Escrow Agent as required in Section 6(b)(i)(A) (Establishment of Source Code Escrow) of Attachment B (Facility Owned by Seller), or (3) if Seller is unable to arrange for the placement of the appropriate Source Code into the Source Code Escrow account, placed the required funds with the Monetary Escrow Agent as required in Section 6(b)(ii)(A) (Establishment of Monetary Escrow) of Attachment B (Facility Owned by Seller), and (v) Seller provides Company with written notice that (aa) Seller is ready to declare the Commercial Operations Date and (bb) the Commercial Operations Date will occur within 24 hours (i.e., the next Day).

  • Commercial Operator means the person appointed by MDL as commercial operator of the Maui Pipeline from time to time.

  • Date of Commercial Operation or “COD” means

  • Commercial Operation Date (COD) means the date certified by the DISCOM’s committee upon successful commissioning (as per provisions of the PPA) of the project when all equipments as per rated capacity have been installed and energy has flown into the grid.

  • Guaranteed Substantial Completion Date or “Guaranteed Substantial Completion Dates” has the meaning set forth in Section 5.3B.

  • Loan Commencement Date means, with respect to each Loan, the first Business Day of the calendar month following the Funding Date of such Loan.

  • Billing Commencement Date means the earlier of:

  • Project Commencement Date means the commencement date notified to the Minister pursuant to clause 4(1);

  • Lease Commencement Date has the meaning specified in Section 3.2 of the Master Lease.

  • Initial Operation means the first integral operation of the complete equipment covered under the Contract with the sub-system and supporting equipment in service or available for service.

  • Amortization Commencement Date means the date on which an Amortization Event is deemed to occur pursuant to Section 20 hereof.

  • Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.

  • Payment Commencement Date means the date payments of amounts deferred begin pursuant to Article III, Section 6.

  • Accumulation Commencement Date means January 1, 2021, or such later date as the Calculation Agent on behalf of the Issuer determines in accordance with Section 2.11 hereof.

  • Revenue Operations Date (ROD) means the date of operation of Metro

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Distribution Commencement Date means the Issue Date or such other date as may be specified as the Distribution Commencement Date on the face of such Perpetual Security;