Governmental Force Majeure Event definition

Governmental Force Majeure Event means to the extent they satisfy the criteria for a Force Majeure Event, an event, circumstance or condition which occurs inside or directly involves the Relevant Jurisdiction and consists of the following: acts of war (whether declared or not), armed conflict, invasion, act of foreign enemy, blockade or embargo, in each case occurring within or involving the Relevant Jurisdiction; boycott, embargo, penalty or other restrictions imposed directly on the Relevant Jurisdiction; acts of rebellion, riot, civil commotion, strikes of a political nature, act or campaign of terrorism or sabotage of a political nature, in each case occurring within the Relevant Jurisdiction;
Sample 1Sample 2
Governmental Force Majeure Event means, to the extent they satisfy the criteria for a Force Majeure Event, an event, circumstance or condition, which occurs inside or directly involves the Relevant Jurisdiction consists of the following: acts of war (whether declared or not), armed conflict, invasion, act of foreign enemy, blockade or embargo, in each case occurring within or involving the Relevant Jurisdiction; boycott, embargo, penalty or other restrictions imposed directly on the Relevant Jurisdiction; acts of rebellion, riot, civil commotion, strikes of a political nature, act or campaign of terrorism, or sabotage of a political nature in each case occurring within the Relevant Jurisdiction; a Lapse of Authorisation; any strikes, lock-outs or other industrial disturbances or restraints of labour (whether or not involving employees of the Affected Party) occurring within the Relevant Jurisdiction, but not including industrial action specific to the Affected Party, the Project or the Site; a Frustrating Change in Law occurs; any Expropriation; the discovery on the Site of Artefacts or geological conditions that could not reasonably have been expected to be discovered through an inspection on or prior to date of execution of the Implementation Agreement; radioactive contamination or ionising radiation originating from a source in the Relevant Jurisdiction; or a Grid Event.
Sample 1
Governmental Force Majeure Event means to the extent an event, circumstance or condition satisfies the criteria for a Force Majeure Event, an event, circumstance or condition, which consists of the following: acts of war (whether declared or not), armed conflict, invasion, act of foreign enemy, blockade or embargo, in each case occurring within or involving the Relevant Jurisdiction; boycott, embargo, penalty or other restrictions imposed directly on the Relevant Jurisdiction; acts of rebellion, riot, civil commotion, strikes of a political nature, act or campaign of terrorism or sabotage of a political nature in each case occurring within the Relevant Jurisdiction; a Lapse of Authorisation; any strikes, lock-outs or other industrial disturbances or restraints of labour (whether or not involving employees of the Affected Party) occurring within the Relevant Jurisdiction, but not including industrial action specific to the Affected Party, the Project or the Site; a Frustrating Change in Law; any Expropriation;
Sample 1

Examples of Governmental Force Majeure Event in a sentence

  • In the event that the BOT Contract is terminated (regardless of whether such termination is due to a BOT Company Event of Default, a MOIT Event of Default or an Extended Non- Governmental Force Majeure Event thereunder), this Agreement shall automatically terminate and the sole and exclusive remedies available shall be those set out in Articles 4.7 and 4.8 above and Article 21 of the BOT Contract.

  • Notwithstanding the above, if the event constituting a Non-Governmental Force Majeure Event results in a breakdown of communications rendering it not reasonably practicable to give notice within the applicable time limit specified herein, then the Party affected by the Non- Governmental Force Majeure Event shall give such notice as soon as reasonably practicable after the reinstatement of communications, but not later than one (1) Business Day after such reinstatement.

  • The Party affected by a Non- Governmental Force Majeure Event shall give the other Party regular reports on the progress of those remedial measures and such other information as the other Party may reasonably request.

Related to Governmental Force Majeure Event

  • Force Majeure Event means an event, or a series of related events, that is outside the reasonable control of the party affected (including failures of the internet or any public telecommunications network, hacker attacks, denial of service attacks, virus or other malicious software attacks or infections, power failures, industrial disputes affecting any third party, changes to the law, disasters, explosions, fires, floods, riots, terrorist attacks and wars);

  • Force Majeure Events means acts of war, domestic and/or international terrorism, civil riots or rebellions, quarantines, embargoes and other similar unusual governmental actions, extraordinary elements of nature or acts of God.

  • Relevant Force Majeure Event means a Force Majeure Event in relation to which an Affected Party is claiming relief under this Clause 17; and

  • Force Majeure means an event beyond the control of the supplier and not involving the supplier’s fault or negligence and not foreseeable. Such events may include, but is not restricted to, acts of the purchaser in its sovereign capacity, wars or revolutions, fires, floods, epidemics, quarantine restrictions and freight embargoes.

  • Force Majeure Exception means any failure or delay in the performance of the Issuer's reporting obligation pursuant to Section 2.4 arising out of or caused, directly or indirectly, by circumstances beyond its reasonable control, including, without limitation, acts of God; earthquakes; flood; terrorism; wars and other military disturbances; sabotage; epidemics; riots; loss or malfunctions of utilities, computer (hardware or software) or communication services; accidents; acts of civil or military authority and governmental action. The Issuer shall use commercially reasonable efforts to commence performance of its obligations during any of the foregoing circumstances.

  • Force Majeure Failure has the meaning set forth in Section 8.1(d).

  • Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.

  • Force Majeure Period has the meaning specified in Section 13.1.

  • Force Majeure Delays means any actual delay in the construction of the Tenant Improvements, which is beyond the reasonable control of Landlord or Tenant, as the case may be, as described in Paragraph 33 of the Lease.

  • Event of Force Majeure means one of the following events:

  • Force Majeure Report means a report to be given by the Affected Party to the other party following the giving of a Force Majeure Notice;

  • Force Majeure Notice means a notice to be given by the Affected Party to the other party stating that a Force Majeure Event has occurred;

  • Unavoidable Delay means an event which delays Closing which is a strike, fire, explosion, flood, act of God, civil insurrection, act of war, act of terrorism or pandemic, plus any period of delay directly caused by the event, which are beyond the reasonable control of the Vendor and are not caused or contributed to by the fault of the Vendor. “Unavoidable Delay Period” means the number of days between the Purchaser’s receipt of written notice of the commencement of the Unavoidable Delay, as required by paragraph 5(b), and the date on which the Unavoidable Delay concludes.

  • Unavoidable Delays means delays due to any of the following, and only the following, (provided that such delay is beyond Construction Manager’s reasonable control): war, insurrection, civil commotion, strikes, slowdowns, lock outs, riots, flood, earthquakes, fires, casualties, acts of God, acts of a public enemy, acts of terrorism, epidemics, quarantine restrictions, freight embargoes, lack of transportation, governmental moratoriums, unusually severe or abnormal weather conditions, failure of utilities, or a court order which causes a delay (unless resulting from a wrongful act of Construction Manager). In no event shall the application to Construction Manager of any applicable law, regulation, rule or other governmental requirement constitute an Unavoidable Delay. Contractor shall use reasonable good faith efforts to notify Owner not later than five (5) days after Construction Manager knows of the occurrence of an Unavoidable Delay. An extension of time for an Unavoidable Delay shall only be for the period of the Unavoidable Delay, which period shall commence to run from the time of the commencement of the cause of the Unavoidable Delay.

  • Environmental Activity means any use, storage, holding, existence, Release, emission, discharge, generation, processing, abatement, removal, disposition, handling or transportation of any Hazardous Substance.

  • Governmental Action means any authorization, application, approval, consent, exemption, filing, license, notice, registration, permit or other requirement of, to or with any Governmental Authority.

  • Governmental Actions means any and all consents, approvals, permits, orders, authorizations, waivers, exceptions, variances, exemptions or licenses of, or registrations, declarations or filings with, any Governmental Authority required under any Governmental Rules.

  • Environmental Violation means, with respect to the Property, any activity, occurrence or condition that violates or results in non-compliance with any Environmental Law.

  • Natural Disaster means a flood, hurricane, tornado, earthquake, volcanic eruption, fire, wildfire or blizzard that is due to natural causes.

  • Environmental Activities means the use, generation, transportation, handling, discharge, production, treatment, storage, release or disposal of any Hazardous Materials at any time to or from any portion of the Premises or located on or present on or under any portion of the Premises.

  • Act of God means a cataclysmic phenomenon of nature, including earthquake, flood or cyclone. Rain, snow, wind, high water or any other natural phenomenon, which might reasonably have been anticipated from historical records of the general locality of the City, shall be deemed not to be acts of God;

  • Material of Environmental Concern means and includes pollutants, contaminants, hazardous wastes, and toxic, radioactive, caustic or otherwise hazardous substances, including petroleum, its derivatives, by-products and other hydrocarbons, or any substance having any constituent elements displaying any of the foregoing characteristics.

  • Disaster means a sudden emergency occurrence beyond the control of the licensee, whether natural, technological, or man-made, that renders the licensee unable to operate the facility or makes the facility uninhabitable.

  • Technical violation means a noncriminal violation of the conditions of parole. This rule is intended to implement Iowa Code section 905.7.

  • Tenant Delay as used in the Lease or this Agreement shall mean any delay that Landlord may encounter in the performance of Landlord’s obligations under the Lease or this Agreement because of any act or omission of any nature by Tenant or its agents or contractors, including any: (1) delay attributable to changes in or additions to the Approved Plans or to the Landlord’s Work requested by Tenant; (2) delay attributable to the postponement of any Landlord’s Work at the request of Tenant; (3) delay caused by a Change Order requested by Tenant; (4) delay attributable to the failure of Tenant to pay, when due, any amounts required to be paid by Tenant pursuant to the Lease; or (5) delay attributable to a failure of Tenant to employ union labor for Tenant’s work at the Premises during the time the Landlord’s Work is being constructed. Tenant shall pay all actual costs and expenses incurred by Landlord which result from any Tenant Delay and the Commencement Date of the Lease shall be accelerated one (1) day for each day the Premises is not Ready for Occupancy as a result of a Tenant Delay. No Tenant Delay shall be deemed to have occurred unless Landlord gives Tenant prior written notice or written notice within five (5) days of the occurrence, as reasonable under the circumstances, specifying the claimed reasons for such Tenant Delay, and Tenant shall fail to promptly correct or cure such Tenant Delay. There shall be excluded from the number of days of any Tenant Delay, or any of the following events of force majeure: labor disputes, fire, unusual delay in transportation, adverse weather conditions not reasonably anticipatable, unavoidable casualties, delays in obtaining permits or governmental approvals or any other causes beyond Landlord’s or its contractor’s reasonable control (and other than for financial reasons) (collectively, “Force Majeure Delays”).

  • Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.