Force Majeure Cause definition

Force Majeure Cause has the meaning as defined in Section 3.5.1 to this Agreement;
Sample 1Sample 2Sample 3
Force Majeure Cause is any cause that is beyond the reasonable control of that party. Such causes include, but are not limited to: power failure, internet service provider failure, industrial action, civil unrest, fire, flood, storms, earthquakes, acts of terrorism, acts of war, governmental action or any other event that is beyond the control of the party in question.
Sample 1
Force Majeure Cause means any one or more events or circumstances beyond the reasonable control of the Party whose performance is affected thereby that, alone or in combination, adversely and materially affects the operation of the Hotel whether or not such events or circumstances occur geographically in a location remote from the Hotel, including, without limitation, casualties, war, invasion, insurrection, acts of terrorism, sabotage, failure of transportation, outbreak of disease, inability to procure or general shortage of labor, equipment, facilities, materials or supplies in the open market, actions of labor unions, and governmental actions (but excluding (i) causes which can be controlled by the reasonable expenditure of money in accordance with usual business practices, (ii) any conditions precipitated by Manager, and (iii) any conditions precipitated by Owner). MANAGEMENT FEES AND REMITTANCES TO OWNER Reserved – to come from selected proposal Basic Fee Reserved to come from selected proposal Incentive Fee Reserved to come from selected proposal BOOKS AND RECORDS; GROSS RECEIPTS; FF&E FUND
Sample 1

Examples of Force Majeure Cause in a sentence

  • This is the only section which is so responsive to all lame excuses in the system for non- collection of evidence and missed prosecution of the offenders.

  • In the event the Conference has commenced, at the time of the Force Majeure Cause, or SAP has incurred expenses which under the Agreement are the responsibility of Exhibitor, then for the period of use until the time of termination, and to the extent SAP has incurred such expenses, Exhibitor shall be liable to SAP, unless reimbursement is waived by SAP.

  • Tenant and its employees shall have reasonable access to the Premises 24 hours per day, 7 days per week (and access to such portions of the Building as required in order to access the Premises on a 24 hour per day, 7 day per week basis), except due to any Force Majeure Cause (as described in Section 28.7 below) or emergencies preventing such access.

  • Licensor shall have, and hereby reserves, the right to use the Stadium for any purpose, other than professional baseball, with the consent of Licensee during any period that Licensee is prevented by any Force Majeure Cause or War Cause from playing Home Games in the Stadium.

  • Nothing in this Paragraph 27.1 shall operate to obligate either Party to perform any act after the expiration of this License, except where such Party owes the other Party a payment delayed by a Force Majeure Cause or War Cause.

  • Except as otherwise expressly provided in this License, this License shall not terminate by reason of the occurrence of any Force Majeure Cause or War Cause, irrespective of whether or not the Stadium becomes untenantable, provided, however, that in the event of the duration of any Force Majeure Cause or War Cause in excess of one year, Licensor and Licensee shall each have the option to terminate this License upon forty-five (45) days prior written notice.

  • Licensee’s obligations hereunder, including its obligations to pay any amounts, shall xxxxx with respect to Home Games played in other stadiums and Licensor shall refund to Licensee an aliquot portion of fees already paid by Licensee based on the rights lost by Licensee as a result of the Force Majeure Cause or War Cause.

  • In the event the Event has commenced, at the time of the Force Majeure Cause, or Celonis has incurred expenses which under this Agreement are the responsibility of Sponsor, then for the period of use until the time of termination, and to the extent Celonis has incurred such expenses, Sponsor shall be liable to Celonis, unless reimbursement is waived by Xxxxxxx.

  • The contained data should be carefully maintained so that they can be reused as much as possible in all life phases.

  • In no event shall lack of funds be deemed a Force Majeure Cause, nor shall any matter be deemed to be beyond Tenant's reasonable control if the same could be remedied by the satisfaction of a lien, judgment or other monetary obligation.


More Definitions of Force Majeure Cause

Force Majeure Cause means circumstances beyond the control of the party affected thereby (including its subcontractors) including, but not limited to, act of God, declared or undeclared war, riot, pandemic, civil commotion, restrictions or directions from any government or governmental body or authority, peril of the sea, earthquakes, explosion, fire, flood, storm, riot, strike or other industrial action (including without limitation strike or other industrial action by the employees of the party claiming the benefit of this clause), failure by any statutory undertaker, utility company, local authority or like body to provide services, any failure, shortage of power, fuel, raw material, goods bought from third parties or transport, and any act or omission of any third party to the extent that performance of any obligation of the party claiming the benefit of the clause relies thereon.
Sample 1
Force Majeure Cause means a cause that falls within Clause 7 of this Agreement;
Sample 1
Force Majeure Cause means a cause falling within the meaning of that expression in Sub-Clause 7.1 above.
Sample 1
Force Majeure Cause means any one or more events or circumstances beyond the reasonable control of the party whose performance is affected thereby that, alone or in combination, adversely affects the operation of the Hotel whether or not such events or circumstances occur geographically in a location remote from the Hotel, including, without limitation, casualties, war, invasion, insurrection, acts of terrorism, sabotage, failure of transportation, inability to procure or general shortage of labor, equipment, facilities, materials or supplies in the open market, actions of labor unions, and governmental actions (but excluding causes which can be controlled by the reasonable expenditure of money in accordance with usual business practices).
Sample 1
Force Majeure Cause means any cause beyond Landlord's control, including but not limited to, acts of God, strikes or labor troubles, inclement weather, fuel or energy shortages, utility failures, or governmental preemption or curtailment in connection with a national emergency or in connection with any rule, order, guideline or regulation of any department or governmental agency. If Tenant shall fail to exercise its right to terminate this Lease within ten (10) days following any date on which such right may first be exercised, Tenant shall be deemed to have waived its right of termination with respect to such date as granted by this Section.
Sample 1
Force Majeure Cause has the meaning as stated in section 4.7 of this Agreement;
Sample 1

Related to Force Majeure Cause

  • Force Majeure Period has the meaning specified in Section 13.1.

  • Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.

  • Force Majeure means an event beyond the control of the supplier and not involving the supplier’s fault or negligence and not foreseeable. Such events may include, but is not restricted to, acts of the purchaser in its sovereign capacity, wars or revolutions, fires, floods, epidemics, quarantine restrictions and freight embargoes.

  • Force Majeure Delays means any actual delay in the construction of the Tenant Improvements, which is beyond the reasonable control of Landlord or Tenant, as the case may be, as described in Paragraph 33 of the Lease.

  • Force Majeure Notice means a notice to be given by the Affected Party to the other party stating that a Force Majeure Event has occurred;

  • Force Majeure Event means an event, or a series of related events, that is outside the reasonable control of the party affected (including failures of the internet or any public telecommunications network, hacker attacks, denial of service attacks, virus or other malicious software attacks or infections, power failures, industrial disputes affecting any third party, changes to the law, disasters, explosions, fires, floods, riots, terrorist attacks and wars);

  • Force Majeure Exception means any failure or delay in the performance of the Issuer's reporting obligation pursuant to Section 2.4 arising out of or caused, directly or indirectly, by circumstances beyond its reasonable control, including, without limitation, acts of God; earthquakes; flood; terrorism; wars and other military disturbances; sabotage; epidemics; riots; loss or malfunctions of utilities, computer (hardware or software) or communication services; accidents; acts of civil or military authority and governmental action. The Issuer shall use commercially reasonable efforts to commence performance of its obligations during any of the foregoing circumstances.

  • Force Majeure Failure has the meaning set forth in Section 8.1(d).

  • Force Majeure Events means acts of war, domestic and/or international terrorism, civil riots or rebellions, quarantines, embargoes and other similar unusual governmental actions, extraordinary elements of nature or acts of God.

  • Force Majeure Report means a report to be given by the Affected Party to the other party following the giving of a Force Majeure Notice;

  • Relevant Force Majeure Event means a Force Majeure Event in relation to which an Affected Party is claiming relief under this Clause 17; and

  • Event of Force Majeure means one of the following events:

  • Excused Outage means any disruption to or unavailability of Services caused by or due to (i) Scheduled Maintenance,

  • Unavoidable Delay means an event which delays Closing which is a strike, fire, explosion, flood, act of God, civil insurrection, act of war, act of terrorism or pandemic, plus any period of delay directly caused by the event, which are beyond the reasonable control of the Vendor and are not caused or contributed to by the fault of the Vendor. “Unavoidable Delay Period” means the number of days between the Purchaser’s receipt of written notice of the commencement of the Unavoidable Delay, as required by paragraph 5(b), and the date on which the Unavoidable Delay concludes.

  • Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.

  • Unavoidable Delays means delays due to any of the following, and only the following, (provided that such delay is beyond Construction Manager’s reasonable control): war, insurrection, civil commotion, strikes, slowdowns, lock outs, riots, flood, earthquakes, fires, casualties, acts of God, acts of a public enemy, acts of terrorism, epidemics, quarantine restrictions, freight embargoes, lack of transportation, governmental moratoriums, unusually severe or abnormal weather conditions, failure of utilities, or a court order which causes a delay (unless resulting from a wrongful act of Construction Manager). In no event shall the application to Construction Manager of any applicable law, regulation, rule or other governmental requirement constitute an Unavoidable Delay. Contractor shall use reasonable good faith efforts to notify Owner not later than five (5) days after Construction Manager knows of the occurrence of an Unavoidable Delay. An extension of time for an Unavoidable Delay shall only be for the period of the Unavoidable Delay, which period shall commence to run from the time of the commencement of the cause of the Unavoidable Delay.

  • Excusable Delays means delays due to acts of terrorism, acts of war or civil insurrection, strikes, riots, floods, earthquakes, fires, tornadoes, casualties, acts of God, labor disputes, governmental restrictions or priorities, embargoes, national or regional material shortages, failure to obtain regulatory approval from any Federal or State regulatory body, unforeseen site conditions, extraordinary rainfall or snowfall, or any other condition or circumstances beyond the reasonable or foreseeable control of the applicable Party using reasonable diligence to overcome which prevents such Party from performing its specific duties or obligation hereunder in a timely manner; provided, however, Excusable Delay does not include lack of financing, unanticipated or unexpected increases in the costs of construction, or errors in business judgment by a Party; and provided further that Excusable Delay shall only extend the time of performance for the period of such Excusable Delay, which shall begin on the date which the event of Excusable Delay first occurs and extend until the date which the event which has caused the Excusable Delay has been corrected or performed, or reasonably should have been corrected or performed.

  • Interruption Period shall have the meaning set forth in Section 5 hereof.

  • Tenant Delay as used in the Lease or this Agreement shall mean any delay that Landlord may encounter in the performance of Landlord’s obligations under the Lease or this Agreement because of any act or omission of any nature by Tenant or its agents or contractors, including any: (1) delay attributable to changes in or additions to the Approved Plans or to the Landlord’s Work requested by Tenant; (2) delay attributable to the postponement of any Landlord’s Work at the request of Tenant; (3) delay caused by a Change Order requested by Tenant; (4) delay attributable to the failure of Tenant to pay, when due, any amounts required to be paid by Tenant pursuant to the Lease; or (5) delay attributable to a failure of Tenant to employ union labor for Tenant’s work at the Premises during the time the Landlord’s Work is being constructed. Tenant shall pay all actual costs and expenses incurred by Landlord which result from any Tenant Delay and the Commencement Date of the Lease shall be accelerated one (1) day for each day the Premises is not Ready for Occupancy as a result of a Tenant Delay. No Tenant Delay shall be deemed to have occurred unless Landlord gives Tenant prior written notice or written notice within five (5) days of the occurrence, as reasonable under the circumstances, specifying the claimed reasons for such Tenant Delay, and Tenant shall fail to promptly correct or cure such Tenant Delay. There shall be excluded from the number of days of any Tenant Delay, or any of the following events of force majeure: labor disputes, fire, unusual delay in transportation, adverse weather conditions not reasonably anticipatable, unavoidable casualties, delays in obtaining permits or governmental approvals or any other causes beyond Landlord’s or its contractor’s reasonable control (and other than for financial reasons) (collectively, “Force Majeure Delays”).

  • Tenant Delays means delays caused by: (i) requirements of the Plans and Specifications requested by Tenant that do not conform to Landlord’s building standards for office and lab build-out, or which contain long lead-time or non-standard items requested by Tenant; provided that Landlord has notified Tenant of such deviations upon execution of this Lease (ii) any material change in the Plans and Specifications requested by Tenant and agreed to by Landlord; (iii) any request by Tenant for a delay in the commencement or completion of the Initial Tenant Improvements for any reason; (iv) Tenant delay in finalizing and approving the design of the vivarium and value engineering of same or (v) any other act or omission of Tenant or its employees, agents or contractors which reasonably inhibits the Landlord from timely completing the Initial Tenant Improvements including, without limitation any delays caused by Tenant’s presence in the Premises prior to the Term Commencement Date. The Premises shall not be deemed to be incomplete if only minor or insubstantial details of construction, decoration or mechanical adjustments remain to be done which do not unreasonably interfere with Tenant’s occupancy of the Premises. If as a result of Tenant Delays the Premises are deemed ready for Tenant’s occupancy, pursuant to the foregoing (and the term shall have commenced by reason thereof), but the Premises are not in fact actually ready for Tenant’s occupancy, Tenant shall not (except with Landlord’s consent not to be unreasonably withheld, conditioned or delayed) be entitled to take possession of the Premises for the permitted use until the Premises are in fact actually ready for such occupancy.

  • Excused Downtime means the number of minutes in the Charging Period, rounded to the nearest minute that the link state of Customer’s Port is ‘down’ due to:

  • Terminating Party As defined in Section 7.1(f).

  • Unplanned Service Interruption means any Service Interruption where events or circumstances prevent the timely communication of prior warning or notice to the Trader or any affected Customer;

  • Service Interruption means the cessation of electricity supply to an ICP for a period of 1 minute or longer, other than by reason of De-energisation of that ICP:

  • Third Party Terminating Carrier means a Telecommunications Carrier to which traffic is terminated when CLEC originates traffic that is sent through AT&T-TSP’s network, i.e., CLEC is using AT&T-TSP’s Transit Traffic Service.

  • Landlord Delay shall occur if either: (i) Landlord fails to complete the Base Building and/or other improvements on the Project that are required by the DDA, the Parking REA and/or the CC&Rs, and as a direct result of such failure Tenant is unable to obtain a temporary or permanent certificate of occupancy for the Premises upon substantial completion of the Tenant Improvements; or (ii) substantial completion of the Warm Shell Improvements or Tenant Improvements is delayed directly and solely as a result of any of the following and such delay could not have been mitigated by Tenant using commercially reasonable measures, which delay occurs after the Delivery Date and before the Commencement Date and does not result from Tenant's interference or delay in connection with completion of the Tenant Improvements or after a Tenant Default or Work Letter Draw Event: (a) subject to Paragraph 8 above, unreasonable interference by Landlord or Landlord's Contractor with the construction of the Warm Shell Improvements or the Tenant Improvements; (b) Landlord's failure to comply with any deadlines for response to, or submissions from, Tenant as required by this Work Letter; (c) any material Discretionary Changes to Landlord's Plans or the Warm Shell Plans after their final approval by applicable governmental entities (other than Tenant Modifications) that directly affect Tenant's Plans or the Tenant Improvements; and/or (d) Landlord failure to complete portions of the Base Building and/or other improvements on the Project that are Landlord's obligation to complete hereunder, and as a direct result of such failure Tenant and Tenant's contractors do not have access to the Premises to the extent required to complete the Warm Shell Improvements and/or Tenant Improvements. Tenant shall give Landlord at least five (5) days prior notice if Tenant becomes aware that Landlord is in danger of causing a Landlord Delay, and if Landlord takes appropriate measures to prevent such delay within such five (5) day period, no adjustment to the Commencement Date shall be made on account of such Landlord; provided, however, that if such delay was not reasonably foreseeable by Tenant, the five (5) day period for prior notice and opportunity to mitigate provided above shall be changed to forty-eight (48) hours after Tenant becomes aware of such delay or potential delay.