Final Project Completion Date definition

Final Project Completion Date means the date which is twenty-four (24) months after the Commencement Date.
Sample 1Sample 2Sample 3
Final Project Completion Date means the date by which all Components of the Project are expected to be completed;
Sample 1Sample 2Sample 3
Final Project Completion Date shall be: Sixty (60) days after the Substantial Completion Date. The Final Project Completion Date occurs when the Project is 100% completed.
Sample 1

Examples of Final Project Completion Date in a sentence

  • The Final Project Completion Date set forth in Appendix No. 11 shall anticipate reasonable work delays.

  • The removal of existing Public Safety Answering Point Furniture and fabrication, delivery, and installation of the Products and performance of the services under this Agreement shall be commenced immediately upon execution of this Agreement, and shall be completed no later than the Final Project Completion Date set forth in Appendix No. 11, unless extended by BRETSA in writing.

  • The Selected Respondent shall maintain Products Completed Operations liability coverage for a period of at least twenty-four (24) months following the Final Project Completion Date.

  • Provisioning of the Services and Products to be provided pursuant to this Agreement shall be commenced immediately upon execution of this Agreement, and shall be completed no later than the Final Project Completion Date set forth in Appendix No. 13, unless extended by BRETSA in writing.

  • Unless otherwise provided, Contract Time is the period of time, including authorized adjustments, allotted in the Contract Documents for completion of the Work by the Final Project Completion Date as set forth in the Project Schedule.

  • Prior to Final Project Completion Date, Contractor will perform the following tasks: • Complete all unfinished work described on a punch list approved by Agency in a timely manner.

  • Punch List items will be completed no later than the Final Project Completion Date.

  • The term (the “Term”) of this Agreement shall begin on the date that Final Project Completion occurs for the Energy System and shall terminate on the date that is twenty (20) years after such Final Project Completion Date.

  • After Contractor’s achievement of Substantial Completion and Contractor’s completion of all Punch List items and those items set forth in Article 7 of Exhibit B, Owner shall acknowledge, accept and confirm final inspection and completion of the Project by delivering a written notice of acceptance (“Certificate of Acceptance”) to Contractor setting forth the Final Project Completion Date, and thereafter recording a Notice of Completion in accordance with the General Conditions.

  • Effective July 8, 2018, any Delivery Driver, Class Code 1121, employed with the Department of General Services and required by Management to wear a specific safety type work boot or a uniform boot, shall receive a cash allowance of $200 for the purchase, repair, and maintenance of the work boot or a uniform boots provided they are on active payroll status each January 1 during term of this MOU.


More Definitions of Final Project Completion Date

Final Project Completion Date has the meaning given to such term in Paragraph B.1 of Appendix I (Construction Covenants and Disbursement Procedures).
Sample 1
Final Project Completion Date means the date by which Borrower shall cause to occur the completion of the Guaranteed Scope of Work, in accordance with the Design/Build Agreement and PAL Lease but no later than the earlier of (i) subject to extension for Force majeure and Excusable Delay, the day prior to the thirty-seventh (37th) month anniversary of the date of this Agreement; provided, however, that such date shall be extended every month thereafter (but in no event beyond September 1, 2013) by Borrower, so long as cash flow derived from the Project and paid in accordance with the Lock Box Agreement is sufficient to satisfy Borrower’s payment obligations under the Senior Note and Junior Note as determined by Lender in its sole discretion; and (ii) September 1, 2013.
Sample 1
Final Project Completion Date has the meaning set forth in the Lease.
Sample 1

Related to Final Project Completion Date

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Final Completion Date means the date on which Final Completion occurs.

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Scheduled Completion Date shall be the date set forth in Clause 10.3;

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Phase 1 means the first implementation phase of this section, beginning June 1, 2018 and ending May 31, 2022.

  • Construction Completion Certificate means a document:

  • Project Commencement Date means the commencement date notified to the Minister pursuant to clause 4(1);

  • Completion Rate means the percentage of an apprenticeship cohort who receives a certificate of apprenticeship completion within 1 year of the projected completion date. An apprenticeship cohort is the group of individual apprentices registered to a specific program during a 1 year time frame, except that a cohort does not include the apprentices whose apprenticeship agreement has been cancelled during the probationary period or who have transferred.

  • Completion Schedule means the fulfilment of the Related Services by the Supplier in accordance with the terms and conditions set forth in the Contract;

  • Project Implementation Unit or “PIU” means the unit referred to in Section I.A.1 of Schedule 2 to this Agreement.

  • Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.

  • Construction project means the same as that term is defined in Section 38-1a-102.

  • Project Schedule means a document that, with respect to each Phase of the Project, identifies, coordinates and integrates the anticipated design and construction schedules, the Contracting Authority’s and Owner's responsibilities, government authority reviews and other activities as are necessary for the timely completion of the Work.

  • Outside Completion Date shall have the meaning assigned to such term in Section 6.3(d).

  • Construction Budget means the fully-budgeted costs for the acquisition and construction of a given parcel of real property (including, without limitation, the cost of acquiring such parcel of real property, reserves for construction interest and operating deficits, tenant improvements, leasing commissions, and infrastructure costs) as reasonably determined by the Parent in good faith.

  • Improvement completion assurance means a surety bond, letter of credit,