Final Approved Punch List definition

Final Approved Punch List means a list, approved pursuant to Article 14.2.2, specifying those items of Work to be completed by the Contractor after Substantial Completion and dates for the completion of each item of Work.
Sample 1Sample 2Sample 3
Final Approved Punch List means a list, approved in writing by the Project Manager, Engineer or Architect, specifying those items of Work to be completed by the Contractor after Substantial Completion and dates for the completion of each item of Work.
Sample 1Sample 2Sample 3
Final Approved Punch List means a list, approved in writing by the Engineer, specifying those items of Work to be completed by the Contractor after Substantial Completion and dates for the completion of each item of Work.
Sample 1Sample 2Sample 3

Examples of Final Approved Punch List in a sentence

  • The date of approval of the Final Approved Punch List, shall be the date of Substantial Completion.

  • Approval of Final Approved Punch List and Date for Final Acceptance: Following inspection of the Work, the Engineer shall furnish the Contractor with a final punch list, specifying all items of Work to be completed and proposing dates for the completion of each specified item of Work.

  • In addition to the right to declare the Contractor in default pursuant to this Chapter X, the Commissioner shall have the absolute right, in his/her sole discretion and without a hearing, to complete or cause to be completed in the same manner as described in Articles 51 and 53, any or all unsatisfactory or uncompleted punch list Work that remains after the completion date specified in the Final Approved Punch List.

  • Approval of Final Approved Punch List and Date for Final Acceptance: Following inspection of the Work, the Engineer/Resident Engineer shall furnish the Contractor with a final punch list, specifying all items of Work to be completed and proposing dates for the completion of each specified item of Work.

  • Determining the Date of Final Acceptance: The Work will be accepted as final and complete as of the date of the Engineer's inspection if, upon such inspection, the Engineer finds that all items on the Final Approved Punch List are complete and no further Work remains to be done.

  • Determining the Date of Final Acceptance: The Work will be accepted as final and complete as of the date of the Engineer’s/Resident Engineer’s inspection if, upon such inspection, the Engineer/Resident Engineer finds that all items on the Final Approved Punch List are complete and no further Work remains to be done.

  • If the Commissioner exercises his/her right to complete or cause to complete any or all unsatisfactory or uncompleted punch list Work that remains after the completion date specified in the Final Approved Punch List pursuant to Article 54, any such action shall be commenced within six (6) months from the date the Commissioner notifies the Contractor in writing that he/she has exercised such right.

  • Determining the Date of Final Acceptance: The Work will be accepted as final and complete as of the date of the Engineer's/Resident Engineer’s inspection if, upon such inspection, the Engineer/Resident Engineer finds that all items on the Final Approved Punch List are complete and no further Work remains to be done.

  • Determining the Date of Final Acceptance: The Work will be accepted as final and complete as of the date of City Engineer’s inspection if, upon such inspection, the City Engineer finds that all items on the Final Approved Punch List are complete and no further Work remains to be done.

  • The sub-contractor so proposed for the work possess the experience, qualification and equipment necessary for the job proposed to be entrusted to him in proportion o the Quantum of works to be sub-contracted.

Related to Final Approved Punch List

  • Final Approval means the Court’s order granting final approval of the Settlement.

  • Final Approval Order means the order and final judgment approving the Settlement Agreement, implementing the terms of this Settlement Agreement, and dismissing the Class Action with prejudice, to be proposed by the Settling Parties for approval by the Court, in substantially the form attached as Exhibit 5 hereto.

  • Final Approval Date means the date on which the Court enters the Final Order and Judgment.

  • Approved Project Budget means the most recent statement, approved by the FTA, of the costs of the Project, the maximum amount of Federal assistance for which the TJPA is currently eligible, the specific tasks (including specified contingencies) covered, and the estimated cost of each task.

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Punch List means the list of items, prepared in connection with the inspection of the Project by the Owner’s Representative or Architect in connection with Substantial Completion of the Work or a portion of the Work, which the Owner’s Representative or Architect has designated as remaining to be performed, completed or corrected before the Work will be accepted by the Owner.

  • Approved Project means the Scheme application of the Applicant approved by the CIC.

  • Plans and Specifications means the plans, drawings and specifications reasonably necessary to properly assess and review proposed Work prior to issuance of any approval that may be required under this Agreement;

  • Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;

  • Completion Schedule means the fulfilment of the Related Services by the Supplier in accordance with the terms and conditions set forth in the Contract;

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • MSAA Indicator Technical Specifications document means, as the context requires, either or both of the document entitled “Multi-Sector Service Accountability Agreement (MSAA) 2019-20 Indicator Technical Specifications November 5, 2018 Version 1.3” and the document entitled “Multi-Sector Service Accountability Agreement (MSAA) 2019-20 Target and Corridor-Setting Guidelines” as they may be amended or replaced from time to time;

  • Approved program or approved State means a State administered NPDES program which has been approved or authorized by EPA under 40 CFR Part 123.

  • Final Approval Order and Judgment means the order in which the Court certifies the Settlement Class, grants final approval of this Settlement Agreement, authorizes the entry of a final judgment, and dismisses the Action with prejudice.

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Improvement completion assurance means a surety bond, letter of credit,

  • Initial approval means authorization to admit students and enter into contractual agreements for clinical facilities. It is granted only after an application has been submitted, reviewed and a survey visit made by the Board. No students shall be admitted to the program until the institution has received written notification that initial approval has been granted. Failure to comply will delay initial approval.

  • Final Approval Hearing means the hearing before the Court where the Parties will request the Final Judgment to be entered by the Court approving the Settlement Agreement, the Fee Award, and the incentive award to the Class Representative.

  • Construction Budget means the fully-budgeted costs for the acquisition and construction of a given parcel of real property (including, without limitation, the cost of acquiring such parcel of real property, reserves for construction interest and operating deficits, tenant improvements, leasing commissions, and infrastructure costs) as reasonably determined by the Parent in good faith.

  • Wind-Down Budget means a budget to be prepared by the Debtors, and reasonably acceptable to the Deerfield Requisite Supporting Noteholders, the Unaffiliated Requisite Supporting Noteholders, and the Committee, which shall be filed with the Court as part of the Plan Supplement, and which may be amended from time to time after entry of the Confirmation Order, subject to the consent of the Oversight Committee, which consent shall not be unreasonably withheld, and which shall estimate the funds necessary to administer the Plan and wind down the Debtors’ affairs, including the costs of holding and liquidating the Estates’ remaining property, objecting to Claims, making the Distributions required by the Plan, prosecuting claims and Causes of Action that may be held by the Estates against third parties that are not released, waived or transferred pursuant to the Plan (including pursuant to Article X) or otherwise, paying Taxes, filing Tax returns, paying professionals’ fees and expenses, paying the fees and expenses of the Oversight Committee, funding payroll and other employee costs, providing for the purchase of errors and omissions insurance and/or other forms of indemnification for the Plan Administrator, and for all such items and other costs of administering the Plan, the Estates and the Liquidating Debtors (other than the Administrative and Priority Claims Reserve, the Disputed Claims Reserve, and the Professional Fee Reserve).

  • Construction Schedule means a construction schedule indicating the planned start and completion dates of the major activities of the Work as set out in Appendix [ ], a future Appendix;

  • Project Schedule means a document that, with respect to each Phase of the Project, identifies, coordinates and integrates the anticipated design and construction schedules, the Contracting Authority’s and Owner's responsibilities, government authority reviews and other activities as are necessary for the timely completion of the Work.

  • Punchlist means a list of items of Work to be completed or corrected by Contractor after Substantial Completion. Punchlists indicate items to be finished, remaining Work to be performed, or Work that does not meet quality or quantity requirements as required in the Contract Documents.

  • Proposed Change Order (PCO means a document that informs Contractor of a proposed change in the Work and appropriately describes or otherwise documents such change including Contractor’s response of pricing for the proposed change.

  • Project Improvements means site improvements and facilities that are:

  • Standard Specifications means a compilation in book form of specifica- tions approved for general application and repetitive use;