Extraordinary Measures definition

Extraordinary Measures shall have the meaning given to such term in Section 5.4.1.
Sample 1Sample 2Sample 3
Extraordinary Measures means measures that may be taken by the Secretary of the Treasury in the event of a breach of the debt limit by the United States to prolong the function of United States Government in the absence of a debt limit increase.
Sample 1Sample 2
Extraordinary Measures means measures implemented by Contractor at HACLA's direction to expedite the progress of construction of all or a portion of the Work, including, without limitation, (i) working additional shifts or overtime, (ii) supplying additional manpower, equipment, and facilities, and
Sample 1Sample 2

Examples of Extraordinary Measures in a sentence

  • Such Extraordinary Measures shall continue until the progress of the Services complies with the stage of completion required by the Schedule.

  • If the Engineer fails to implement or commence Extraordinary Measures within ten (10) calendar days of Owner’s written demand, Owner shall have the right to terminate the Engineer for cause.

  • Such Extraordinary Measures shall continue until the progress of the Trade Contractor Work complies in the Authority’s reasonable judgment with the stage of completion required by the approved Construction Schedule.

  • The Engineer shall not be entitled to an adjustment in compensation in connection with the Extraordinary Measures required by the Owner pursuant to this Section.

  • Such Extraordinary Measures shall continue until the progress of the Work complies with the stage of completion required by the Contract Documents.

  • To the extent that the need for Extraordinary Measures is the responsibility or fault of the Trade Contractor, the Trade Contractor shall not be entitled to an adjustment in the Trade Contract Amount or Contract Time in connection with Extraordinary Measures pursuant to this Paragraph 2.11.

  • The Authority’s right to require Extraordinary Measures is solely for the purpose of ensuring the Trade Contractor’s compliance with the Construction Schedule or as required by this Paragraph 2.11.

  • The City's right to require Extraordinary Measures is solely for the purpose of ensuring the Design-Builder's compliance with the Project Schedule.

  • The Parties hereto acknowledge and agree, in accordance with Paragraph 4.10 of Exhibit 6 to the Construction Services Agreement, that the Construction Manager will undertake Extraordinary Measures if the Authority determines that the performance of the Work has not progressed or reached the level of completion required by the Contract Documents.

  • The Customer's right to require Extraordinary Measures is solely for the purpose of ensuring the ESCO's achievement of Substantial Completion in accordance with the Construction Schedule.


More Definitions of Extraordinary Measures

Extraordinary Measures means medical or surgical measures that prolong life, or are intended to prolong life, by supplanting or maintaining the operation of bodily functions that are temporarily or permanently incapable of independent operation:
Sample 1Sample 2
Extraordinary Measures is defined in Section 1.6.
Sample 1

Related to Extraordinary Measures

  • Noise Control Measures means measures to reduce the noise emissions from the Facility and/or Equipment

  • Supportive measures means individualized services that are offered to the complainant or the respondent designed to restore or preserve equal access to the District’s education program or activity without unreasonably burdening the other party. The supportive measures must be non-disciplinary and non-punitive in nature; offered before or after the filing of a formal complaint or where no formal complaint has been filed; and offered to either party as appropriate, as reasonably available, and without fee or charge. Examples of supportive measures include, but are not limited to: measures designed to protect the safety of all parties or the District’s educational environment, or deter sexual harassment; counseling; extensions of deadlines or other course-related adjustments; modifications of work or class schedules; campus escort services; mutual restrictions on contact between the parties; changes in work or class locations; leaves of absence; and increased security and monitoring of certain areas of the campus.

  • Extraordinary Event means any event, circumstance or cause which Royal Bank determines has or will have a material adverse effect on the ability of Royal Bank to perform its obligations under the Notes or to hedge its position in respect of its obligation to make payment of amounts owing thereunder, including as a result of any of Royal Bank’s internal policies, and more specifically includes a Market Disruption Event in respect of any Share or Hedging Event.

  • Extraordinary General Meeting means an Extraordinary General Meeting of the Members duly called and constituted and any adjourned holding thereof.

  • reasonable measures means appropriate measures which are commensurate with the money laundering or terrorism financing risks;

  • COVID-19 Measures means any quarantine, “shelter in place”, “stay at home”, workforce reduction, social distancing, shut down, closure or sequester order, guideline, recommendation or Law, or any other applicable Laws, guidelines or recommendations by any Governmental Entity in connection with or in response to COVID-19.

  • Measures means any measures proposed by the Supplier or any Sub-contractor within the meaning of regulation 13(2)(d) of TUPE;

  • Extraordinary Dividend means any cash dividend or distribution (or portion thereof) that the Calculation Agent determines, in its sole discretion, is extraordinary or special; and

  • Extraordinary Adjustment Event means any of the following events as they relate to the Reference In- strument: