Disposal Completion definition

Disposal Completion. ’ means completion of the Disposal
Disposal Completion means the completion of the sale and purchase of the Sale
Disposal Completion means completion of the Disposal;

Examples of Disposal Completion in a sentence

  • Upon the Disposal Completion, the Company will no longer hold any equity interest in the Target Company and the Target Company will cease to be an associate company of the Group.

  • Upon the Disposal Completion, the Target Company will cease to be an associate company of the Group.

  • The exercise period of the Uptodate DF Call Option shall commence immediately on the Disposal Completion Date and end on the earlier of (a) the first anniversary date of the Disposal Completion; and (b) the date of completion of the sale of the entire commercial and office tower of the West Site pursuant to the exit arrangement under the Shareholders’ Agreement.

  • Disposal Completion Completion shall take place on the day immediately upon the final completion of change update with respect to the total 100% of Equity Sale of the Disposal Company in the records of Administration Bureau for Industry and Commerce pursuant to the Equity Transfer Agreement.

  • Upon Disposal Completion, the Company will focus on its new energy operations in the PRC.

  • If the Client fails to notify Sunshine in writing of any changes in address at least 10 days before the change or move, Sunshine shall be held harmless by the client for any rent, room & board or other payments made by Sunshine on the Clients behalf.

  • PROPOSED DISTRIBUTION Conditional on the Disposal Completion, the Directors propose to pay a Distribution of not more than HK$0.24 per Share (totalling not more than HK$36 million on the basis of 150 million Shares in issue on the date hereof) for the year ending 31 December 2014 to Shareholders whose names appear on the register of members of the Company on a record date to be determined by the Board, such record date shall in any event precede the date of the Share Purchase Completion.

  • In this scenario, taking into consideration of the fair value gain of the Properties recognised in profit or loss immediately before the Disposal Completion amounting to approximately HK$15,000,000 per note 5 above and expenses directly attributable to the ES Acquisition of approximately HK$2,350,000 per note 3 above, the ES Acquisition and the subsequent disposal of the Properties together gives rise to a loss of approximately HK$7,175,000.

  • Acceptance of this Assurance by NYAG is not an approval or endorsement by NYAG of any of Respondent’s policies, practices, or procedures, and Respondent shall make no representation to the contrary.

  • Right of East Asia to terminate The Sale and Purchase Agreement contains provisions granting East Asia the right to terminate the Sale and Purchase Agreement by giving notice in writing in the event that Disposal Completion does not take place on the Completion Date due to a failure of MCE to comply with its obligations under the Sale and Purchase Agreement on Disposal Completion.


More Definitions of Disposal Completion

Disposal Completion the completion of the Disposal “Director(s)” the director(s) of the Company
Disposal Completion means the completion of the sale and purchase of the Sale Shares and the assignment and taking up of the Sale Loans pursuant to the Disposal Agreement
Disposal Completion completion of the Disposal in accordance with the terms and conditions of the Disposal Agreement

Related to Disposal Completion

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Testson Completion means the tests which are specified in the Contractor agreed by both Parties or instructed as a Variation, and which are carried out under Clause 9 [Tests on Completion] before the Works or a Section (as the case may be) are taken over by the Procuring Entity.

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.

  • Virtual Completion means the premise is in the opinion of the Employer fit for occupation.

  • Tests on Completion means the tests which are specified in the Contract or agreed by both Parties or instructed as a Variation, and which are carried out under Clause 9 [Tests on Completion] before the Works or a Section (as the case may be) are taken over by the Procuring Entity.

  • Final Completion Date means the date on which Final Completion occurs.

  • Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Tests after Completion means the tests (if any) which are specified in the Contract and which are carried out in accordance with the Specification after the Works or a Section (as the case may be) are taken over by the Procuring Entity.

  • Mechanical Completion means that (a) all components and systems of the Project have been properly constructed, installed and functionally tested according to EPC Contract requirements in a safe and prudent manner that does not void any equipment or system warranties or violate any permits, approvals or Laws; (b) the Project is ready for testing and commissioning, as applicable; (c) Seller has provided written acceptance to the EPC Contractor of mechanical completion as that term is specifically defined in the EPC Contract.

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Practical Completion means that stage in the execution of a Named Project when the Works have been completed in accordance with the terms of the relevant Building Contract and/or the terms of this Agreement such that the AHP Dwellings comprised within the Named Project are fit for beneficial occupation as a residential development in accordance with applicable NHBC or equivalent requirements current at the date of inspection subject only to the existence of minor defects and/or minor omissions at the time of inspection which are capable of being made good or carried out without materially interfering with the beneficial use and enjoyment of the Named Project and which would be reasonable to include in a snagging list, and Practically Complete shall be construed accordingly; Process has the meaning ascribed to it in the DPA; Procurement Law means (as the case may be):

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Completion means the fulfilment of the Related Services by the Supplier in accordance with the terms and conditions set forth in the Contract.

  • Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.

  • Construction Period means the period commencing from the Appointed Date and ending on the date of the Completion Certificate;

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Phase 2 means the second implementation phase of this section, beginning June 1, 2022 and continuing thereafter.

  • Construction Plant means appliances, machinery with necessary supply to up keep and maintenance of the works or temporary works but dose not include materials or other things intended to form part of the permanent work.

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Study Completion means the database for the Study has been locked and all Essential Documents have been provided to the Sponsor, including a copy of the letter from the Reviewing HREC acknowledging receipt of the final report and/or closure letter from the Principal Investigator.

  • Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.

  • Guaranteed Substantial Completion Date or “Guaranteed Substantial Completion Dates” has the meaning set forth in Section 5.3B.