Delay definition

Delay means: a delay in the Achievement of a Milestone by its Milestone Date; or a delay in the design, development, testing or implementation of a Deliverable by the relevant date set out in the Implementation Plan;

Delay means the non-performance of the Supplier with regard to Delivery in accordance with the Delivery Time, or when a substantial part of the Deliverables is not delivered in the agreed quality, and this is not due to force majeure or to circumstances for which the Buyer is responsible.

Delay means delay in the completion of the Service in accordance with the terms and conditions set forth in the Contract;

Examples of Delay in a sentence

• For avoidance of doubt, if the decision is determined to be arbitrary and capricious and causes delay, it will constitute and be treated as a TxDOT- Caused Delay.

• If approval is subject to the sole, absolute or unfettered discretion of TxDOT, then its decision shall be final, binding and not subject to dispute resolution, and such decision shall not constitute a TxDOT-Caused Delay, TxDOT Change, Relief Event, Compensation Event or other basis for any Claim.

• In the event that any Party is delayed in, or prevented from, performing or carrying out its obligations under this Contract by reason of any event of Excusable Delay, such circumstance will not constitute an Event of Default, and such Party will be excused from performance hereunder and will not be liable to the other Party for or on account of any loss, damage, injury or expense resulting from, or arising out of, such delay or prevention.

• If during construction any Manhattan Beach USD Person requests changes and/or modifications to the Scope of Work and/or an Excusable Delay occurs, the Parties agree that an equitable extension of time to complete the Work may be necessary.

• In the event of an Excusable Delay, the duties and obligation of the party seeking to have the failure, default, or delay excused shall be extended for a commercially reasonable time.

More Definitions of Delay

Delay means any delay or interruption in the progress of the Trade Contractor Work as anticipated on the approved Construction Schedule.

Delay means the time difference between the time the passenger was scheduled to arrive in accordance with the published timetable and the time of his or her actual or expected arrival at the station of final destination;

Delay means any delay on the Critical Path of the Schedule.

Delay has the meaning set forth in Section 1.2.1.

Delay means a Permitting Delay or Transmission Delay, as set forth in Section 3.9(c).

Delay means any delay, inability or failure (for any reason, including breach of this Agreement or negligence) to Ship or Handle Coal in the tonnages and at the rates contemplated in this Agreement. For the User, this includes a failure to deliver Coal to the Terminal or an inability to schedule vessels to load Coal. For DBCT Management, this includes the inability to provide Services at the Terminal (in whole or part) for any reason when Coal would otherwise have been made available by the User.

Delay. (a) a delay in the Achievement of a Milestone by its Milestone Date; or (b) a delay in the design, development, testing or implementation of a Deliverable by the relevant date set out in the Implementation Plan;