Date for Commencement of the Works definition

Date for Commencement of the Works means the date stated in the Particular Specification included in the Specification for the commencement of the Works;
Sample 1Sample 2Sample 3
Date for Commencement of the Works means the Contract Date;
Sample 1

Examples of Date for Commencement of the Works in a sentence

  • The Contractor shall not commence the execution of the Works before the Date for Commencement of the Works.

  • The Contractor shall from the Date for Commencement of the Works proceed with the execution of the Works with due diligence and expedition.

  • The Contractor shall pay the premium and the Statutory Employee's Compensation Levy, and any adjustment thereof as determined by the PWEC Insurer, on production of an invoice by the Employer's appointed broker and in any event the Contractor shall provide a premium receipt issued by the Employer's appointed broker within 30 days from the Date for Commencement of the Works or within 30 days of the date of the invoice for any adjustment.

  • In accordance with the provisions of Clause 33.1 (g) of the General Conditions, the Contractor shall procure insurance for itself and for its sub-contractors of every tier from the Date for Commencement of the Works until the date of issue of the Defects Liability Certificate through the PWEC under procedures to be promulgated by the Employer before the Date of Commencement of the Works.

  • In accordance with the provisions of Clause SC38 (f) of the Special Conditions, the Contractor shall procure insurance for itself and for its sub-contractors of every tier from the Date for Commencement of the Works until the date of issue of the Defects Liability Certificate through the PWEC under procedures to be promulgated by the Employer before the Date of Commencement of the Works.

  • The Contractor shall notify the Engineer within 21 days after the Date for Commencement of the Works of those items of the Reuse Equipment which the Contractor proposes to incorporate into the Permanent Works or utilize in connection with the execution of the Works.

Related to Date for Commencement of the Works

  • Date for Completion means the date for Completion specified in the Contract Specifics.

  • Date of commencement of the project means the date of the agreement.

  • Service Commencement Date in respect of a Service or a particular instance of a Service means the date on which that particular Service or particular instance of a Service is first provided to the Customer, or as otherwise explicitly set out in this Agreement;

  • Date of Commencement means the date designated in the Notice to Proceed for Contractor to commence the Work.

  • Commencement Date means the date of this Agreement.

  • Time for Completion means the time for completing the Works as stated in the Contract Data (or as extended under Sub-Clause 7.3), calculated from the Commencement Date.

  • the commencement date means the date on which the Contract shall take effect, as notified by the Authority to the Contractor in a letter awarding the Contract.

  • Employment Commencement Date means the date on which the Employee first performs an Hour of Service.

  • Implementation Period means the period from the date of signing of the Agreement and up to the issuance of Final Acceptance Certificate for the project.

  • Term Commencement Date shall be the later of (i) November 1, 2006 or (ii) the date on which Landlord’s Work is Substantially Complete (or the date on which Landlord’s Work would have been Substantially Complete absent Tenant Delay or Force Majeure (as defined below)); provided, however, that if the Term Commencement Date is not the first day of a calendar month, then the first lease year shall be extended through the last day of the calendar month in which the first 12-month period expires, and Rent for the additional period at the end of the first lease year shall be payable at the rate for the 12th month of the Term. “Force Majeure” means accident; breakage; repair; governmental regulation, moratorium or other governmental action. The “Term Expiration Date” shall be the day immediately preceding the seventh (7th) anniversary of the Term Commencement Date, provided that if such preceding day is not the last day of a calendar month, then the Term Expiration Date shall be the last date of the calendar month in which such preceding day occurs. Landlord and Tenant shall each execute and deliver to the other written acknowledgment of the actual Term Commencement Date and the Term Expiration Date when such are established, and shall attach it to this Lease as Exhibit B. Failure to execute and deliver such acknowledgment, however, shall not affect the Term Commencement Date or Landlord’s or Tenant’s liability hereunder. Failure by Tenant to obtain validation by any medical review board or other similar governmental licensing of the Premises required for the Permitted Use by Tenant shall not serve to extend the Term Commencement Date.

  • COMMENCEMENT OF SERVICE means the actual date of placement of the first Vehicle(s) under this Agreement.

  • Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.

  • Commencement of Commercial Production means the first occurrence of Commercial Production in an Area.

  • Loan Commencement Date means, with respect to each Loan, the first Business Day of the calendar month following the Funding Date of such Loan.

  • Accumulation Commencement Date means January 1, 2021, or such later date as the Calculation Agent on behalf of the Issuer determines in accordance with Section 2.11 hereof.

  • Date of Practical Completion means the date certified in the QBCC Form 7 - Certificate of Practical Completion in accordance with Condition 28.

  • Commencement of Development means the date on which any material operation (as defined in Section 56(4) of the Act) forming part of the Development is begun other than (for the purposes of this Deed and for no other purpose) operations consisting of site clearance, demolition work, archaeological investigations for the purpose of assessing ground conditions, remedial work in respect of any contamination or other adverse ground conditions, diversion and laying out of services, erection of any temporary display of site notices or advertisements and “Commence Development” shall be construed accordingly

  • Distribution Commencement Date means the Issue Date or such other date as may be specified as the Distribution Commencement Date on the face of such Perpetual Security;

  • Project Start Date means the first Milestone Start Date specified in Schedule B;

  • Plan Implementation Date means the Business Day on which all of the conditions precedent to the implementation of the Plan have been fulfilled, or, to the extent permitted pursuant to the terms and conditions of the Plan, waived, as evidenced by the Monitor’s Plan Implementation Date Certificate to be filed with the Court;

  • Reemployment Commencement Date means the first day following a One-Year Period of Severance on which an Employee is entitled to be credited with an Hour of Service described in Paragraph (a)(1) of the definition of “Hour of Service” in this Article.

  • Date of Commencement of Risk means the date specified in the Schedule (unless the Policyholder is informed otherwise by the Company) from which the risk cover of the Life Assured commences under the Policy.

  • Services Commencement Date means the date delivery of the Services shall commence as specified in the Key Provisions. If no date is specified in the Key Provisions this date shall be the Commencement Date;

  • Extended Use Period means the period beginning on the 1st day in the compliance period on which such building is part of a qualified low-income housing project, and ending on the later of the date specified by such agency in such agreement, or the date which is 15 years after the close of the compliance period.

  • Continuous Improvement Plan means a plan for improving the provision of the Goods and/or Services and/or reducing the Charges produced by the Supplier pursuant to Framework Schedule 12 (Continuous Improvement and Benchmarking);

  • Commencement Date or Handover Date means the date on which the Licensed Space of first lot of stations as per Annexure 1 is handed over by DMRC to the Selected Bidder, in accordance with the terms of this agreement.