Contract milestones definition

Contract milestones means the dates identified in the project schedule by which the design-builder must complete certain critical activities to advance the project.
Contract milestones means the dates identified in the contract by which the contractor must complete certain crit- ical activities to advance the project.
Contract milestones means the dates identified in the school facilities project schedule by

Examples of Contract milestones in a sentence

  • This schedule shall include and identify all tasks that are on the Project’s critical path with a specific determination of the start and completion of each critical path task as well as all Contract milestones and each milestone’s completion date(s) as may be required by the District.

  • Planned and actual start and completion dates of each work activity, including applicable:1.1. Submittal development.1.2. Submittal review and acceptance.1.3. Material procurement.1.4. Contract milestones and each required constraint.

  • If the Contractor, in the judgment of the Commission, is failing to meet the Target Schedule, including any Contract milestones, the Contractor, upon the written request of the Commission Representative, shall submit a recovery schedule.

  • Contractor shall also achieve any and all Contract milestones as described elsewhere in the Contract Documents.

  • The Proposer will suggest a payment schedule for the Contract, linked to unambiguous Contract milestones.

  • The Progress Schedule shall show as applicable, Contract milestones and other key milestones for significant project events.

  • Work shall be executed with such progress as required to prevent delay to other contractors working on other contracts at Site, if any, Contract milestones, or general completion of Contract.

  • Total float is not for the exclusive use of either the Trustees or Design-Builder, but is jointly owned by both and is a resource available to and shared by both parties as needed to meet Contract milestones and the Contract completion date.

  • In the event that the Contractor, in the judgment of the Engineer, is failing to meet the approved CPM schedule including any Contract milestones, the Contractor shall submit a recovery schedule.

  • The bidder will suggest a payment schedule for the Contract, linked to unambiguous Contract milestones.


More Definitions of Contract milestones

Contract milestones means the dates identified in the school facilities project schedule by which the de- sign-builder must complete certain critical activities to advance the project.

Related to Contract milestones

  • Project Milestones means the project milestones set forth in Schedule-G;

  • Project Milestone means the project milestone set forth in Schedule-J;

  • Milestones means control points in the project that help to chart progress. Milestones may correspond to the completion of a key deliverable, allowing the next phase of the work to begin. They may also be needed at intermediary points so that, if problems have arisen, corrective measures can be taken. A milestone may be a critical decision point in the project where, for example, the consortium must decide which of several technologies to adopt for further development.

  • Milestone means an event or task described in the Implementation Plan which must be completed by the corresponding date set out in such plan;

  • Development Milestone Payment shall have the meaning set forth in Section 9.2(a).

  • Performance Milestone means an act or event specified in section 5.1 and described in section 9 of the EPLA.

  • Milestone Schedule means Seller’s milestone schedule, the form of which is attached to this Agreement as Exhibit Q.

  • Milestone 2 means achievement of annual Net Sales of at least $35,000,000 during any Calendar Year ending on or before December 31, 2024.

  • Development Milestone Event shall have the meaning set forth in Section 9.2(a).

  • Milestone Dates means the dates for completion of specified Project activities as contained in the Project Schedule.

  • Milestone 1 means achievement of annual Net Sales of at least $20,000,000 during the Calendar Year ending on December 31, 2021.

  • Milestone Events has the meaning set forth in Section 3.3 (Milestone Payments).

  • Sales Milestone Payment shall have the meaning set forth in Section 8.4.

  • Milestone Date means the date set against the relevant Milestone in the Implementation Plan;

  • Milestone Event has the meaning set forth in Section 8.4.

  • Contract Specific Goals means the subcontracting goals for MBE and WBE participation established for a particular contract.

  • Milestone Payment means a payment identified in the Implementation Plan to be made following the issue of a Satisfaction Certificate in respect of Achievement of the relevant Milestone;

  • Product Schedule means PTC’s standard order form entitled “PTC Product Schedule” (including all schedules, attachments and other document(s) specifically referenced therein) or such alternative order form as may be submitted by Customer and accepted by PTC, in each case that specifies (i) the Licensed Products and/or Services ordered; and (ii) for Licensed Products, the installation address (including the Designated Country) and the Licence Term.

  • Service Levels means the service levels to be met by the Services as referenced in the Contract Letter and set out in the Specification Schedule.

  • Project Deliverables means the Project deliverables set out in Schedule 2. Project Material means all the material including but not limited to documents, computer software, and data stored by any means which is created by the Fellow in the course of undertaking the Project.

  • Timeline means the list of critical dates and actions included in the Introductory Materials.

  • Deliverables means the work product and other output of the Services required to be delivered by Contractor as part of the Services, as specified in the relevant section of the Contract.

  • MSAA Indicator Technical Specifications document means, as the context requires, either or both of the document entitled “Multi-Sector Service Accountability Agreement (MSAA) 2019-20 Indicator Technical Specifications November 5, 2018 Version 1.3” and the document entitled “Multi-Sector Service Accountability Agreement (MSAA) 2019-20 Target and Corridor-Setting Guidelines” as they may be amended or replaced from time to time;

  • Design Criteria Package means concise, performance-oriented drawings or specifications for a public construction project. The purpose of the Design Criteria Package is to furnish sufficient information to permit Design-Build Firms to prepare a bid or a response to the District’s Request for Proposals, or to permit the District to enter into a negotiated Design- Build Contract. The Design Criteria Package must specify performance- based criteria for the public construction project, including the legal description of the site, survey information concerning the site, interior space requirements, material quality standards, schematic layouts and conceptual design criteria of the project, cost or budget estimates, design and construction schedules, site development requirements, provisions for utilities, stormwater retention and disposal, and parking requirements applicable to the project. Design Criteria Packages shall require firms to submit information regarding the qualifications, availability, and past work of the firms, including the partners and members thereof.

  • Development Schedule shall have the meaning set forth in Section 1.1.

  • Milestone Payment Date has the meaning set forth in Section 2.4(a).