Construction Work Completion Date definition

Construction Work Completion Date means the date set out in the Addendum, if applicable, by which you must complete construction of the Hotel.
Sample 1Sample 2Sample 3
Construction Work Completion Date means the date set out in the Addendum, if applicable, by which you must complete construction of the Hotel. "Control" means the possession, directly or indirectly, of the power to direct or cause the direction of the management and policies of an entity, or of the power to veto major policy decisions of an entity, whether through the ownership of voting securities, by contract, or otherwise. "Controlling Affiliate' means an Affiliate that directly or indirectly Controls the Hotel and/or Controls the entity that Controls the Hotel. "Designs" means your plans, layouts, specifications, drawings and designs for the proposed furnishings, fixtures, equipment, signs and decor of the Hotel that use and incorporate the Standards. "Effective Date' means the date set out in the Addendum on which this Agreement becomes effective. "Entitles' means our present or future Affiliates and direct or indirect owners. "Equity Interest' means any direct or indirect legal or beneficial interest in the Franchisee, the Hotel and/or the Hotel Site. "Equity Owner' means the direct or indirect owner of an Equity Interest. "Expiration Date' has the meaning set forth in Section 3. "Force Majeure' means an event causing a delay in our or your performance that is not the fault of or within the reasonable control of the party claiming Force Majeure. Force Majeure includes fire, floods, natural disasters, Acts of God, war, civil commotion, terrorist acts, any governmental act or regulation beyond such party's reasonable control. Force Majeure does not include the Franchisee's financial inability to perform, inability to obtain financing, inability to obtain permits or any other similar events unique to the Franchisee or the Hotel or to general economic downturn or conditions. "General Manager' has the meaning set forth in Subsection 7.1. "Government or Government Entity" means: (i) any agency, instrumentality, subdivision or other body of any national, regional, local or other government; (ii) any commercial or similar entities owned or controlled by such government, including any state-owned and state-operated companies; (iii) any political party; and (iv) any public international organization. "Government Official' means the following: (i) officers and employees of any national, regional, local or other Government; (ii) officers and employees of companies in which a Government owns an interest; (iii) any private person acting in an official capacity for or on behalf of any Government or...
Sample 1
Construction Work Completion Date for the purposes of the Lease shall mean with the date appearing on the last certificate issued by the Port Authority pursuant to subparagraph (1) of this paragraph (i) after the substantial completion of the Construction Work.
Sample 1

Examples of Construction Work Completion Date in a sentence

  • If you fail to complete the Construction Work in accordance with this Agreement on or before the Construction Work Completion Date and this failure to meet the Construction Work Completion Date is due solely to Force Majeure, the Pre-Opening Termination Fee (as defined in Paragraph T below) will not be assessed.

Related to Construction Work Completion Date

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Construction Work means any work in connection with⎯

  • Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Construction Works means all works and things necessary to complete the Project in accordance with this Agreement;

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Final Completion Date means the date on which Final Completion occurs.

  • Construction Period means the period commencing from the Appointed Date and ending on the date of the Completion Certificate;

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Improvement completion assurance means a surety bond, letter of credit,

  • Construction Phase means that Phase of the Project which shall commence after the Authority provides the Trade Contractor with written Notice to Proceed with the Construction Phase.

  • Tenant Improvements Defined in Exhibit B, if any.

  • Construction Plant means appliances, machinery with necessary supply to up keep and maintenance of the works or temporary works but dose not include materials or other things intended to form part of the permanent work.

  • Construction project means the same as that term is defined in Section 38-1a-102.

  • construction site means a workplace where construction work is being performed;

  • demolition work means a method to dismantle, wreck, break, pull down or knock down of a structure or part thereof by way of manual labour, machinery, or the use of explosives;

  • construction work permit means a document issued in terms of regulation 3; "contractor" means an employer who performs construction work;

  • Construction Contractor means a person who undertakes to or offers to undertake to, or purports to have the capacity to undertake to, or submits a bid to, or does himself or by or through others, construct, alter, repair, add to, subtract from, improve, move, wreck, or demolish any building, highway, road, railroad, excavation, or other structure, project, development, or improvement to real property, or to do any part thereof. "Construction contractor" includes subcontractors, specialty contractors, prime contractors, and any person receiving consideration for the general supervision and/or coordination of such a construction project except for remediation contracting. This definition shall govern without regard to whether or not the construction contractor is acting in fulfillment of a contract.