Construction Professionals definition

Construction Professionals. As defined in Section 12.1(a)(ii).
Sample 1Sample 2Sample 3
Construction Professionals. As defined in Schedule 1.7(j)(ii)B.2.
Sample 1Sample 2Sample 3
Construction Professionals means technical professionals with educational level of degree, diploma or certificate in engineering related technical courses and want to take part in construction works or professionals who are certified for the different levels in the occupational standard for construction.
Sample 1

Examples of Construction Professionals in a sentence

  • The Professional shall conduct pre-contract meetings with responsive, responsible qualified construction Bidder(s) to review the following items: (1) Understanding of the design intent of the Contract Documents; and (2) To advise and assist the Construction Professional(s) in understanding the requirements of the Department’s standard form of Construction Contract Documents, Project scope of work, and its Construction Contract award procedures.

  • These problem- solving meetings shall be scheduled as the construction field conditions and the Project may require, and/or shall be at such time as the Construction Professional(s), the Professional, the Department, the Project Director, Department Field Representative and any construction manager agree is appropriate to the Project construction work progress.

  • Task 705 PROGRESS MEETINGS: Conduct and record monthly scheduled Project construction progress meetings with the Project Director, Department Field Representative, the State/Client Agency, the Construction Professional(s), and any construction manager.

  • Notify the Construction Professional(s), in writing, (copy to the Department) of delinquent submittals, the consequences of such delays, and prescribe a time schedule for their submittal/resubmittal, which will not jeopardize the Construction Contract completion date.

  • In observed cases which may involve danger to human life, immediate safety hazards to personnel, existing or impending damage to the Project, to State/Client Agency property or to other property; as may be impacted by the Project, the Professional shall inform the Construction Professional(s) of the situation and their observations.

  • Task 603 PAYMENT PROCEDURES: Monitor, evaluate, and provide timely administrative action, as necessary, to certify or reject, as appropriate, and process the Construction Professional's schedule of costs and monthly submitted payment requests.

  • The Professional shall have access to the Construction Professional(s) work at all times.

  • Maintain all necessary Project records, provide on-site visitation reports, and provide all administrative office action as may be necessary to inform the Construction Professional(s), in writing, with respect to their compliance with the design intent of the Contract Documents.

  • In addition to all other functions, the Professional’s approval of shop drawings shall verify the submittals furnished by the Construction Professional(s) conforms to the design intent of the Professional’s Contract Documents/architectural and/or engineering drawings and specifications requirements.

  • Advise and assist the Department in taking all practical steps necessary to address and complete the Project in the event of performance delays or defaults by the Construction Professional(s).


More Definitions of Construction Professionals

Construction Professionals means consultants, architects, engineers and designers and other professionals engaged by the Developer or the Contractor for carrying out the Works; “Contractor” means the company appointed by the Developer to construct the Resort; “Conveyance” means a conveyance of the Fractional Estate substantially in the form set out in Appendix 3 hereto but with such amendments as the parties may agree;
Sample 1

Related to Construction Professionals

  • Licensed Professional Engineer means a person acceptable to Buyer in its reasonable judgment who (a) is licensed to practice engineering in California, (b) has training and experience in the power industry specific to the technology of the Project, (c) has no economic relationship, association, or nexus with Seller or Buyer, other than to meet the obligations of Seller pursuant to this Agreement, (d) is not a representative of a consultant, engineer, contractor, designer or other individual involved in the development of the Project or of a manufacturer or supplier of any equipment installed at the Project, and (e) is licensed in an appropriate engineering discipline for the required certification being made.

  • Design Professional means architect or engineer.

  • Licensed site remediation professional means an individual who is licensed by the Site Remediation Professional Licensing Board pursuant to section 7 of P.L.2009, c.60 (C.58:10C-7) or the department pursuant to section 12 of P.L.2009, c.60 (C.58:10C-12).

  • Design Criteria Professional means a firm who holds a current certificate of registration under Chapter 481 of the Florida Statutes, to practice architecture or landscape architecture, or a firm who holds a current certificate as a registered engineer under Chapter 471 of the Florida Statutes, to practice engineering, and who is employed by or under contract to the District to provide professional architect services, landscape architect services, or engineering services in connection with the preparation of the Design Criteria Package.

  • Agent Professionals means attorneys, accountants, appraisers, auditors, environmental engineers or consultants, and other professionals and experts retained by the Administrative Agent.

  • Retained Professional means an Entity: (a) employed in the Chapter 11 Cases pursuant to a Final Order in accordance with sections 327 and 1103 of the Bankruptcy Code and to be compensated for services rendered prior to the Effective Date, pursuant to sections 327, 328, 329, 330, or 331 of the Bankruptcy Code; or (b) for which compensation and reimbursement has been allowed by the Bankruptcy Court pursuant to section 503(b)(4) of the Bankruptcy Code.

  • Registered professional engineer means a person who is registered as a professional engineer pursuant to s. 443.04, Stats.

  • Paraprofessional means a person who does not have an academic degree related to the scope of treatment or support services being provided but performs prescribed functions under the general supervision of that discipline.

  • Professional Engineer means a person entitled to practise as a Professional Engineer in the Province of Ontario under a licence issued under the Professional Engineers Act;

  • Multiphase professional services contract means a contract for the providing of professional

  • Licensed professional means a professional registered in the Commonwealth of Virginia pursuant to Article 1 (§ 54.1-400 et seq.) of Chapter 4 of Title 54.1 of the Code of Virginia. For purposes of these Standards and Specifications a licensed professional is one that is certified by DPOR as an Architect, Professional Engineer, Land Surveyor, or Landscape Architects.

  • Construction Activities means the disturbance of soils associated with clearing, grading, excavation activities or other construction-related activities.

  • Health professional means an individual licensed or otherwise authorized to engage in a health profession under article 15 of the public health code, 1978 PA 368, MCL 333.16101 to 333.18838, and whose scope of practice includes the diagnosis and treatment of individuals with a substance use disorder.

  • Medical professional means a person licensed to practice

  • Professionals means those Persons (a) employed pursuant to an order of the Bankruptcy Court in accordance with Sections 327 or 1103 of the Bankruptcy Code and to be compensated for services pursuant to Sections 327, 328, 329, 330 and 331 of the Bankruptcy Code, or (b) for which compensation and reimbursement has been allowed by the Bankruptcy Court pursuant to Section 503(b)(4) of the Bankruptcy Code.

  • Qualified professional means, for the purposes of OAR 411-320- 0080, any of the following licensed professionals trained to make a diagnosis of a specific intellectual or developmental disability:

  • Substance Abuse Professional (SAP) means a qualified person who evaluates employees who have violated a DOT drug and alcohol regulation and makes recommendations concerning education, treatment, follow-up testing, and aftercare.

  • Architects means any Architect whom the Vendors and the Builder have appointed as the Architects for the Project / Buildings time to time.

  • Substance use disorder professional means a person

  • Professional service or professional services means a professional service or professional services as defined in the Health Insurance Act 1973. This is important information. Please read and retain for future reference.30 / Latrobe Health Services Member Guide – 1 July 2022

  • Uniform Standards of Professional Appraisal Practice means the current standards of the appraisal profession, developed for appraisers and users of appraisal services by the Appraisal Standards Board of the Appraisal Foundation.

  • Professional Engineer or Professional Certificated Engineer means a person holding registration as either a Professional Engineer or Professional Certificated Engineer in terms of the Engineering Profession Act, 2000 (Act No. 46 of 2000);

  • Architect/Engineer or “A/E” means the Person identified in the Agreement responsible for providing professional design services and construction contract administration for the Project. The A/E shall be (1) a registered architect holding a license and certificate of authorization issued by the Ohio Architects Board pursuant to ORC Chapter 4703, (2) a landscape architect holding a license and certificate of authorization issued by the Ohio Landscape Architects Board pursuant to ORC Chapter 4703, or (3) a professional engineer or professional surveyor holding a license and certificate of authorization issued by the Ohio Engineers and Surveyors Board pursuant to ORC Chapter 4733. As used in the Agreement, the term A/E may include a criteria architect or engineer for a Design-Build project.

  • Professional Fee Order means the order entered by the Bankruptcy Court on July 16, 2001, authorizing the interim payment of Professional Claims, as may be amended from time to time prior to the entry on the docket of the Confirmation Order.

  • Project Architect means the architect retained by Lessee to design and supervise construction of the Improvements.

  • Contractor Project Manager means the employee identified in a Statement of Work as the Contractor project manager.